Effect of Delays. Failure or unreasonable delay by Licensor to exercise its rights of termination hereunder by reason of any default by Licensee in carrying out any obligation imposed upon it by this agreement shall not operate to prejudice Licensor’s right of termination for any other subsequent default by Licensee.
Effect of Delays. Any delay in any of the Work Deadlines (including any item that must be redone due to Tenant’s disapproval) shall automatically delay all subsequent deadlines by the same amount of time. To the extent that any delay constitutes a Tenant Delay, the Commencement Date for all purposes under the Lease shall be the date the Commencement Date would have occurred absent the Tenant Delay.
Effect of Delays. 3.4.1. If Amdocs or any Primary Subcontractor fails, or is likely to fail, to timely, diligently and properly perform its obligations under this Agreement, including, but not limited to, meeting a Milestone (other than to the extent caused by or as the result of an Amdocs Excused Delay), Amdocs shall, at its own expense, cure such failure as promptly as reasonably possible, including, but not limited to, at Company’s request, providing that number and type of additional Amdocs Personnel as are reasonably necessary to timely achieve the Milestone. Any failure by Amdocs to fulfill any of its responsibilities (to the extent not caused by or as the result of an Amdocs Excused Delay) shall result in an automatic day-for-day extension of any Company’s specific obligation or scheduled deadline that is dependent upon the specific, unfulfilled Amdocs responsibility, except as may be otherwise agreed by the Parties. Company’s rights and Amdocs’ obligations pursuant to this Section 3.4 are in addition to Company’s other rights and remedies and Amdocs’ other obligations under this Agreement.
3.4.2. In the event Amdocs requires performance of a Company task and Company is unable to perform or complete such task designated as Company’s responsibility pursuant to a schedule (or otherwise under this Agreement) due to a Company Excused Delay, or because such task requires an increased level of effort by Company not previously anticipated or discussed in connection with this Agreement, then Company shall so notify Amdocs and the Parties shall use good faith efforts to reschedule such Company task. In addition, Amdocs shall use commercially reasonable efforts to reallocate in good faith its resources to minimize the impact of such Company task [***] by Company. As part of the PMO, Amdocs shall keep Company timely apprised in writing of any delays by Company that Amdocs believes to be impeding Amdocs’ performance of its obligations, including the date on which Amdocs’ believes such delay by Company began and the reasonably anticipated impacts of such delay. In the event of delays in the performance of Company’s obligations hereunder, or the inability to perform such obligations that are required to be performed in order for Amdocs to perform its obligations, to the extent not caused by or the result of a Company Excused Delay or a rescheduled Company task as described above, Amdocs will have an automatic extension of time to perform its effected obligations that are dependent...
Effect of Delays. Except as provided in Article 9, failure to consummate ---------------- the Closing on the date and time and at the place selected pursuant to this Article 3 shall not result in any termination of this Agreement and shall not relieve any party to this Agreement of any obligation hereunder.
Effect of Delays. Landlord shall use reasonable efforts to deliver ---------------- possession of the entirety of the Premises with the Landlord's Work Substantially Completed on or before the Projected Commencement Date, subject to Permitted Delays. It is acknowledged that time is of the essence of the completion of the Landlord's Work and that Tenant will suffer financial loss if the Landlord's Work is not Substantially Completed by August 31, 1999 (the "Required Completion Date"). The parties also recognize that delay, expense and difficulty would be involved in proving in a legal or arbitration proceeding the actual loss suffered by Tenant if Landlord's Work is not Substantially Completed by the Required Completion Date. Accordingly, in the event Landlord's Work is not Substantially Completed on or before the Required Completion Date, subject to Permitted Delays, Landlord and Tenant agree that the following is a reasonable approximation of the damages that Tenant would incur and Tenant shall be entitled, as liquidated damages for such delay and not as a penalty, to the following:
(i) In the event that the Landlord's Work is Substantially Completed in the period between the Required Completion Date, as extended by Permitted Delays, and February 29, 2000, which date shall be extended only by Tenant's Delay, Tenant shall be entitled to a credit (the "Delay Credit") in an amount equal to the greater of (i) the amount which Landlord actually collects from its contractor for failing to have Substantially Completed the Landlord's Work on or before the Required Completion Date, as extended by Permitted Delays, after recovery of Landlord's costs and expenses incurred in connection with such collection, or (ii) $1,500 multiplied by the number of days that elapse between the day following the Required Completion Date, as extended by Permitted Delays, and the date the Landlord's Work is Substantially Completed. Landlord shall make reasonable efforts to include in the construction contract for Landlord's Work a payment to Landlord equal to the product of $4,000, multiplied by the number of days that elapse between the day following the Required Completion Date, as extended by Permitted Delays, and the date the Landlord's Work is Substantially Completed, or as close thereto as is reasonably possible. In the event the Landlord's Work is not Substantially Completed on or before the Required Completion Date, as extended by Permitted Delays, Landlord shall use its reasonable efforts to e...
Effect of Delays. Any delays encountered in the construction or completion of the Tenant Improvements due to the failure to the Building or the common areas to comply with the ADA shall be Landlord's responsibility and shall not constitute City Delays.
Effect of Delays. Landlord presently estimates that the date of ---------------- substantial completion of the Premises will be March 1, 2000. If substantial completion of the Premises shall occur at a later date, or if Landlord shall be delayed in the delivery of possession of the Premises to Tenant, or if repairs or improvements of the Premises to be performed by Landlord are not completed, or for any other reason, whether or not within Landlord's control, Landlord shall not be subject to any liability to Tenant. Under such circumstances, but subject to the provisions of Section 4(e) concerning delays attributable to Tenant, the rent reserved and covenanted to be paid herein shall not commence until possession of the Premises can be given to Tenant in the required state, and no such failure to give possession shall in any other respect affect the validity of this Lease or any obligation of the Tenant hereunder.
Effect of Delays. Tenant’s obligation to commence paying Base Rent for Expansion Space A shall be postponed by one (1) day for each day of Landlord Delay and non- concurrent Force Majeure Delay applicable to Expansion Space A, subject to this Section 6.3. Tenant’s obligation to commence paying Base Rent for Expansion Space B shall be postponed by one (1) day for each day of Landlord Delay and non-concurrent Force Majeure Delay applicable to Expansion Space B, subject to this Section 6.3. No Landlord Delay or Force Majeure Delay shall be deemed to have occurred unless and until Tenant has provided written notice to Landlord specifying the action, inaction or event that Tenant contends constitutes a Landlord Delay or Force Majeure Delay. If such action, inaction or event is not cured or terminated within one (1) business day after receipt of such notice, then a Landlord Delay or Force Majeure Delay, as applicable, shall be deemed to have occurred commencing as of the date such notice is received and continuing for the number of days that the Substantial Completion of the Premises was, in fact, delayed, as a result of such action, in action or event. Landlord Delays and Force Majeure Delays shall be recognized hereunder only to the extent the same are not concurrent with any other Landlord Delay or Force Majeure Delay which is effective hereunder. For example, if
Effect of Delays. Landlord presently estimates that the date of substantial completion of the Premises will be ninety (90) days after the date on which Tenant obtains the approvals required by Paragraph 49. If substantial completion of the Premises shall occur at a later date, or if Landlord shall be delayed in the delivery of possession of the Premises to Tenant, or if repairs or improvements of the Premises to be performed by Landlord are not completed, or for any other reason, whether or not within Landlord's control, Landlord shall not be subject to any liability to Tenant. Under such circumstances, but subject to the provisions of Section 4(e) concerning delays attributable to Tenant, the rent reserved and covenanted to be paid herein shall not commence until possession of the Premises can be given to Tenant in the required state, and no such failure to give possession shall in any other respect affect the validity of this Lease or any obligation of the Tenant hereunder.
Effect of Delays. No delay on the part of either party in exercising any of their respective rights hereunder or the failure to exercise the same, shall operate as a waiver of such rights except in the specific instance.
