Obligations of Client (a) The Client is bound by and must comply at all times with all rules, protocols, policies, procedures and induction requirements published by Viterra from time to time in the Pricing, Procedures and Protocols Manual, including those in relation to: (i) the terms and conditions of the Export Select and Purchase Option services offered by Viterra; (ii) health, safety and environment; (iii) site rules; (iv) labour ordering conditions for shipping; (v) operating conditions for Viterra's rail facilities; (vi) access and operating conditions for road movements at Viterra facilities, and must comply with all reasonable directions issued by Viterra. (b) While on any premises owned or operated by Viterra, the Client must (and must ensure that its employees, agents and contractors) comply with all reasonable directions given by Viterra's representatives, and do not create or bring on site any hazard or contamination.
Obligations of the Client 4.1. The client undertakes to inform the company in advance (meaning no later than 2 calendar days) about the dispatch of the goods, by entering the shipment into the Xxxxx.xxx software. 4.1.1. In case of non-compliance with subparagraph 3.2.1 of this agreement, the company has the right to refuse the client in accepting and placing his goods at the warehouse. 4.2. To send goods from the warehouse or to carry out other operations, the client is obliged to provide his client number (client ID) and data of the goods.
Obligations of the Customer 3.1 The Customer agrees to: (a) The Customer shall give the Company not less than 14 days prior written notice of any proposed change of ownership of the Customer and or any change in the Customer’s details (including but not limited to, changes in the customer’s name, address, contact phone/fax numbers or business practice). The Customer shall be liable for any loss incurred by the Company as a result of the Customers failure to comply with this clause. (b) Pay the Company the Price for carrying out the Works in accordance with this agreement; (c) Provide the Company with all necessary plans, specifications, services and amenities, so as to allow the Company to carry out the Works, provide access to the Location and ensure to the Company’s reasonable satisfaction that the Location remains in a state and condition that is safe for the Company and its employees and agents; (d) Ensure the Location complies with all necessary bylaws and restrictions is structurally sound (in accordance with all legislation governing safety in the workplace); (e) Not to cause any disruption or obstruction to the carrying out of any Works and to follow any reasonable instructions provided by the Company about the Works; (f) Where the Works requires co-ordination with other trades then the Customer will supply the Company with a schedule detailing all relevant information so as to allow the Company sufficient time to co-ordinate with the Customer’s other tradespersons; (g) Permit the Company to attach such reasonable signage as the Company may wish to any Works so as to identify that the Company is carrying out the Works; (h) In circumstances where it wishes to make a claim against the Company pursuant to the guarantee given in clause 13.2, exclusively permit the Company or its authorised representative to remedy or make good any defects in its Workmanship and not permit any other third party to do so. 3.2 Without prejudice to any other right or remedy of the Company, if the Customer fails to carry out or perform any of its obligations pursuant to this clause 3 (excepting clause 3.1(g)) then, in addition to any Additional Expenses Charge that may apply, the Company may charge the Customer a Services Delay Charge for each day (or part thereof) that the Company is, in its reasonable opinion, unable and/or not required to carry out or perform the Works as a result of such breach by the Customer. 3.3 Where the Customer requests any Related Work to be carried out, the Company will use its best endeavours to source suppliers and/or contractors to carry out the Related Work, but the Customer is responsible for the commissioning, controlling, and payment for such work. 3.4 The Customer acknowledges that unless otherwise agreed in writing between the Customer and the Company, the Customer shall be responsible for obtaining, paying for and maintaining in force all permits, approvals, authorisations, authorities, licences and consents of all regulatory authorities whatsoever which are or may be necessary or advisable in connection with the Works.
Obligations of Customer Axway’s indemnification obligation is contingent upon the Customer: (a) giving immediate written notice to Axway of any such Infringement Claim; (b) giving Axway control of the defense and related settlement negotiations, provided , however that Axway will obtain the Customer’s prior written consent, which shall not be unreasonably withheld or delayed, if any settlement of such an Infringement Claim requires Customer to admit liability, take or refrain from taking any particular action other than cessation of use of the infringing Services, Product, or Deliverable , and (c) assisting in the defense at Axway’s reasonable request, provided Axway agrees to pay Customer’s reasonable expenses in connection therewith. The Customer may participate in such defense and in any settlement discussions directly or through counsel of the Cus tomer’s choice, at the Customer’s expense, provided such participation does not materially prejudice Axway’s sole control of the defense or cause Axway to incur material additional costs in the conduct of such defense .
Obligations of Contractor 5.01 CONTRACTOR agrees to perform all Services in accordance with the terms and conditions of this Agreement and the Proposal. In the event that the terms of the Proposal shall conflict with the terms of this Agreement or contain additional terms that purport to bind the CITY other than the Services to be rendered and the price for the Services, the terms of this Agreement shall govern and said additional or conflicting terms shall be of no force or effect. 5.02 Except as otherwise agreed by the parties, CONTRACTOR will supply all personnel, materials and equipment required to perform the Services. CONTRACTOR shall provide its own offices, telephones, vehicles and computers and set its own work hours. CONTRACTOR will determine the method, details, and means of performing the Services under this Agreement. 5.03 CONTRACTOR shall keep CITY informed as to the progress of the Services by means of regular and frequent consultations. Additionally, when requested by CITY, CONTRACTOR shall prepare written status reports. 5.04 CONTRACTOR is responsible for paying, when due, all income and other taxes, fees and withholding, including withholding state and federal taxes, social security, unemployment and worker’s compensation, incurred as a result of the compensation paid under this Agreement. XXXXXXXXXX agrees to indemnify, defend and hold harmless CITY for any claims, costs, losses, fees, penalties, interest, or damages suffered by CITY resulting from CONTRACTOR’s failure to comply with this provision. 5.05 In the event CONTRACTOR is required to prepare plans, drawings, specifications and/or estimates, the same shall be furnished in conformance with local, state and federal laws, rules and regulations. 5.06 CONTRACTOR represents that it possesses all required licenses necessary or applicable to the performance of Services under this Agreement and the Proposal and shall obtain and keep in full force and effect all permits and approvals required to perform the Services herein. In the event CITY is required to obtain an approval or permit from another governmental entity, CONTRACTOR shall provide all necessary supporting documents to be filed with such entity. 5.07 CONTRACTOR shall be solely responsible for obtaining Employment Eligibility Verification information from CONTRACTOR’s employees, in compliance with the Immigration Reform and Control Act of 1986, Pub. L. 99-603 (8 U.S.C. 1324a), and shall ensure that CONTRACTOR’s employees are eligible to work in the United States. 5.08 In the event that CONTRACTOR employs, contracts with, or otherwise utilizes any CalPERS retirees in completing any of the Services performed hereunder, such instances shall be disclosed in advance to the CITY and shall be subject to the CITY’s advance written approval. 5.09 Drug-free Workplace Certification. By signing this Agreement, the CONTRACTOR hereby certifies under penalty of perjury under the laws of the State of California that the CONTRACTOR will comply with the requirements of the Drug-Free Workplace Act of 1990 (Government Code, Section 8350 et seq.) and will provide a drug- free workplace. 5.10 CONTRACTOR shall comply with all applicable local, state and federal laws, rules, regulations, entitlements and/or permits applicable to, or governing the Services authorized hereunder.
Obligations of the Contractor (i) Subject to and on the terms and conditions of this Agreement, the Contractor shall undertake the survey, investigation, design, engineering, procurement, construction, and maintenance of the Project Highway and observe, fulfil, comply with and perform all its obligations set out in this Agreement or arising hereunder. (ii) The Contractor shall comply with all Applicable Laws and Applicable Permits (including renewals as required) in the performance of its obligations under this Agreement. (iii) Subject to the provisions of Clauses 4.1 (i) and 4.1 (ii), the Contractor shall discharge its obligations in accordance with Good Industry Practice and as a reasonable and prudent person. (iv) The Contractor shall remedy any and all loss, defects, or damage to the Project Highway from the Appointed Date until the end of the Construction Period at the Contractor’s cost, save and except to the extent that any such loss, defect, or damage shall have arisen from any wilful default or neglect of the Authority. (v) The Contractor shall remedy any and all loss, defect or damage to the Project Highway during the Defects Liability Period at the Contractor’s cost to the extent that such loss, defect or damage shall have arisen out of the reasons specified in Clause 17.3. (vi) The Contractor shall remedy any and all loss or damage to the Project Highway during the Maintenance Period at the Contractor’s cost, including those stated in Clause 14.1 (ii), save and except to the extent that any such loss or damage shall have arisen on account of any wilful default or neglect of the Authority or on account of a Force Majeure Event. (vii) The Contractor shall, at its own cost and expense, in addition to and not in derogation of its obligations elsewhere set out in this Agreement: (a) make, or cause to be made, necessary applications to the relevant Government Instrumentalities with such particulars and details as may be required for obtaining Applicable Permits set forth in Schedule-F and obtain and keep in force and effect such Applicable Permits in conformity with the Applicable Laws; (b) procure, as required, the appropriate proprietary rights, licences, agreements and permissions for Materials, methods, processes and systems used or incorporated into the Project Highway; (c) make reasonable efforts to maintain harmony and good industrial relations among the personnel employed byit or its Sub-contractors in connection with the performance of its obligations under this Agreement; (d) ensure and procure that its Sub-contractors comply with all Applicable Permits and Applicable Laws in the performance by them of any of the Contractor’s obligations under this Agreement; (e) not do or omit to do any act, deed or thing which may in any manner violate any provisions of this Agreement; (f) support, cooperate with and facilitate the Authority in the implementation and operation of the Project in accordance with the provisions of this Agreement; (g) ensure that the Contractor and its Sub-contractors comply with the safety and welfare measures for labour in accordance with the Applicable Laws and Good Industry Practice; (h) keep, on Site, a copy of this Agreement, publications named in this Agreement, the Drawings, Documents relating to the Project, and Change of Scope orders and other communications given under this Agreement. The Authority’s Engineer and its authorised personnel shall have the right of access to all these documents at all reasonable times; (i) cooperate with other contractors employed by the Authority and personnel of any public authority; and (j) not interfere unnecessarily or improperly with the convenience of the public, or the access to and use and occupation of all roads and footpaths, irrespective of whether they are public or in the possession of the Authority or of others. (viii) The Contractor shall undertake all necessary superintendence to plan, arrange, direct, manage, inspect and test the Works. The Contractor shall provide all necessary superintendence of the Works for the proper fulfilling of the Contractor's obligations under the Agreement. Such superintendence shall be given by competent person having adequate knowledge of the operations to be carried out (including the methods and techniques required, the hazards likely to be encountered and methods of preventing accidents) for the satisfactory and safe execution of the Works. (ix) The Contractor shall obtain and maintain a project related bank account operational at site where all transactions related to the payment of work will be done. The Contractor shall submit a monthly account statement and a detailed report on utilization of funds transferred to this project related bank account to Authority’s Engineer. Notwithstanding anything contrary to this agreement, the authority, in the interest and to ensure timely completion of the work, reserves the right to audit such bank accounts to ensure that there is no diversion of funds from this project specific account to any other project being implemented by the Contractor. (x) The Contractor shall provide the documents of the Contractor specified in the Agreement, and all Contractors' personnel; Goods, consumables and other things and services, whether of a temporary or permanent nature, required in and for the execution, completion of Works and remedying defects. (xi) The Contractor shall perform the Works in conformity with the Project requirements and other requirements and standards prescribed under or pursuant to the Agreement. (xii) The Contractor shall carry out such work incidental and contingent to the original Scope of the Project to comply with Good Industry Practices. (xiii) The Contractor shall maintain required staff and necessary Contractor’s equipment and materials within the reach of the Site during the Defects Liability Period so that any defects arising are promptly attended.
Obligations of the Consultant Conduct of the Services
Obligations Continuing The obligations of each Guarantor hereunder shall be continuing and shall remain in full force and effect until all the obligations have been paid and satisfied in full. Each Guarantor agrees with the Trustee that it will from time to time deliver to the Trustee suitable acknowledgments of this continued liability hereunder and under any other instrument or instruments in such form as counsel to the Trustee may advise and as will prevent any action brought against it in respect of any default hereunder being barred by any statute of limitations now or hereafter in force and, in the event of the failure of a Guarantor so to do, it hereby irrevocably appoints the Trustee the attorney and agent of such Guarantor to make, execute and deliver such written acknowledgment or acknowledgments or other instruments as may from time to time become necessary or advisable, in the judgment of the Trustee on the advice of counsel, to fully maintain and keep in force the liability of such Guarantor hereunder.
Obligations of the Licensee 5.1.1. The Licensee’s Responsibilities and Duties shall include the following, in addition to and without prejudice to other obligations under this Agreement: a. to obtain due permits, necessary approvals, clearances and sanctions from Maha-Metro and all other competent authorities for all activities or infrastructure facilities including interior decoration, power, water supply, drainage & sewerage, telecommunication, etc.; b. to comply and observe at all times with all Applicable Permits, approvals and Applicable Laws in the performance of its obligations under this Agreement including those being performed by any of its contractors; c. to develop, operate and maintain the Licensed Area at all times in conformity with this Agreement; d. to furnish Maha-Metro with the “As built” Drawings of the Licensed Space(s) within the Moratorium Period; e. to ensure that no structural damage is caused to the existing buildings and other permanent structures at the station as a result of his activities or any of its agents, contractors etc.; f. to take all reasonable steps to protect the environment (both on and off the property business space) and to limit damage and nuisance to people and property resulting from construction and operations, within guidelines specified as per Applicable Laws and Applicable Permits; g. to duly supervise, monitor and control the activities of contractors, agents, etc., if any, under their respective License Agreements as may be necessary; h. to take all responsible precautions for the prevention of accidents on or about the property business space and provide all reasonable assistance and emergency medical aid to accident victims; i. not to permit any person, claiming through or under the Licensee, to create or place any encumbrance or security interest over whole or any part of the Licensed premises and/or other installed assets, or on any rights of the Licensee therein or under this Agreement, save and except as expressly permitted in this Agreement; j. to keep the Licensed Space free from all unnecessary obstruction during execution of works and store the equipment or surplus materials, dispose of such equipment or surplus materials in a manner that causes least inconvenience to the Xxxxx Xxxxxxx, metro commuters or Maha-Metro’s activities. k. at all times, to afford access to the Licensed Property Business Space to the authorised representatives of Maha-Metro, other persons duly authorised by any Governmental Agency having jurisdiction over the business of Licensed Property Business Space, to inspect the Licensed Property Business Space and to investigate any matter within their authority and upon reasonable notice; and l. use non-combustable material in the allotted space for creation/erection/installation of any kind of furniture, fixtures and or partitions within the space. Use of combustable material within the property business space shall not be permitted under any circumstances. m. to comply with the divestment requirements and hand over the Licensed Property Business Space to Maha-Metro upon Termination of the Agreement; 5.1.2. The Licensee shall be solely and primarily responsible to Maha-Metro for observance of all the provisions of this License Agreement on behalf of its employees and representatives and agents and any person acting under or for and on behalf of the Licensee, contractor (s) appointed for the Licensed Space as fully as if they were the acts or defaults of the Licensee, its agents or employees.