Prior Access. At such point as, in Landlord’s reasonable judgment, the Improvements if any have proceeded to such point where Tenant may install wires, cables, furniture, fixtures and equipment (“Tenant’s Work”) within the Leased Premises without interfering with the performance of the Improvements (approximately fifteen days prior to the Possession Date), Landlord shall so notify Tenant and, from and after such date of notification, Tenant and its contractors shall have access to the Leased Premises for the purposes of performing Tenant’s Work in preparation for Tenant’s occupancy of the Leased Premises. In connection with such access, Tenant agrees (a) to cease promptly upon notice from Landlord any activity or work which has not been approved by Landlord or is not in compliance with the provisions of this Lease or which shall interfere with or delay the performance of the Improvements, and (b) to comply promptly with all reasonable procedures and regulations prescribed by Landlord from time to time for coordinating work being performed by Landlord and work being performed by Tenant, each with the other and with any other activity or work in the Building, including, without limitation, the use of labor which shall work in harmony with all other contractors performing work at the Building. Such access by Tenant shall be deemed to be subject to all of the applicable provisions of the Lease, except that (x) there shall be no obligation on the part of Tenant solely because of such access to pay any Rent prior to the Original Completion Deadline, and (y) Tenant shall not be deemed thereby to have taken or accepted possession of the Leased Premises or any portion thereof. If Tenant fails or refuses to comply or cause its contractors to comply with, any of the obligations described or referred to above, then immediately upon notice to Tenant, Landlord may revoke Tenant’s rights of access to the Leased Premises. Landlord shall assume no responsibility for the quality or completion of Tenant’s work under this Section 35, and shall not be responsible for equipment or supplies left or stored on the Leased Premises by Tenant or Tenant’s contractors.
Prior Access. (a) During the time of performance of Landlord’s Work, (i) Tenant may install cabling and wiring at the Premises, including, without limitation, computer cabling, cable splicing, outlets, connectors and attachment (collective, the “Cabling Work”) at Tenant’s sole cost and expense, which Cabling Work shall be coordinated with Landlord and Building management and shall be subject to all terms of the Lease and (ii) Tenant may inspect the progress of Landlord’s Work at no cost or liability to Landlord and in accordance with all laws.
Prior Access. Subject to the terms of this Paragraph, Lessee shall have the right to access the Leased Premises two (2) weeks prior to occupancy for purpose of installing telephone and data lines and equipment, and furniture as mutually agreed. Such right to access shall be scheduled with Lessor so as not to cause a Lessee Delay, and shall not interfere with Lessor’s completion of the Tenant Improvements. Lessor shall assume no responsibility for the quality or completion of lessee’s work under this Paragraph, and shall not be responsible for equipment or supplies left or stored on the Leased Premises by Lessee or lessee’s contractors.
Prior Access. Lessee, its agents, contractors, architects, consultants, etc. shall be permitted access to the Premises, including access to and use of the loading docks, elevators, construction hoists, electrical service, etc. to allow Lessee to plan and commence its required work. There shall be no charge for the use of said facilities.
Prior Access. (a) So long as the applicable Expansion Space is vacant, Landlord grants to Tenant, along with its employees, agents, contractors, subcontractors, space planner/interior architect, engineers, consultants, suppliers and other representatives, and their respective employees, a license to enter any of such space at any time prior to the Scheduled Delivery Date for the purposes of inspecting same, and for the installing of "building standard" and non-"building standard" leasehold improvements therein, as well as the installing of furniture, fixtures and equipment (including telephone, communications and computer equipment, further including wiring and cabling for same). It is the intention of Landlord and Tenant that all Expansion Space be delivered to Tenant at the earliest possible date notwithstanding such date may be earlier than the Scheduled Delivery Date.
Prior Access. 14 3. Rent and Other Payments, Security Deposit..........................15 3.1
Prior Access. Tenant shall have access to the Premises effective August 31, 1999 for the purpose of making alterations and furniture and equipment installation; provided,
Prior Access. If this Lease has been duly executed by Tenant and Landlord, Tenant shall have access during the month preceding the Commencement Date to the Premises, for purposes of data and equipment installation. Tenant shall be liable for any damage to the Premises caused by Tenant, its agents, contractors and/or employees during these periods of construction and installation of data and equipment.
Prior Access. Tenant shall have access to the Premises effective as ------------ of the date this Lease has been executed by all parties thereto for the purpose of making alterations and furniture and equipment installation; provided, however, that any entry onto any portion of the Property or the Premises by the Tenant shall be subject to all of the terms and provisions of this Lease other than the provisions requiring the Tenant to pay Annual Fixed Rent, Tenant's Tax Expense Allocable to the Premises and Tenant's Operating Expenses Allocable to the Premises, or any other Additional Rent none of which shall be payable for the period prior to the Commencement Date. However, Tenant shall pay for all utility charges incurred in connection with the Premises commencing as of no later than the Commencement Date or such earlier date as of which it commences to perform improvement work in the Premises, which utilities shall include, , but not be limited to, electricity, HVAC and gas charges, if any..
Prior Access. Subject to Sublessee's reasonable notice to Sublessor and ------------ at Sublessee's own risk, Sublessee shall be entitled access to the Premises prior to the Commencement Date for the purposes of installing equipment and trade fixtures, provided Sublessee's access shall not interfere with Sublessor's ability to operate Sublessor's business or move-out process. Sublessee's access to the Premises shall comply with the provisions of the Lease, including but not limited to insurance requirements, indemnity, etc.