PROJECT PLANNING AND CONSTRUCTION Sample Clauses

PROJECT PLANNING AND CONSTRUCTION. A. The COUNTY will retain a professional engineering firm to perform the preliminary engineering for the PROJECT. The COUNTY will select and hire the firm from the STATE’S current consultant retainer list for the bridge design category of work. The requirements of the preliminary engineering services to be performed by the firm are identified in the attached Exhibit B. B. The COUNTY will select and hire a geotechnical firm to conduct the foundation investigation if the STATE’S Geotechnical Office is unable to meet the project timeline. The firm must be on the STATE’S current consultant retainer list for the local geotechnical services category of work. The COUNTY will submit a copy of the contract between the geotechnical firm and the COUNTY to the STATE. The requirements to be performed by the firm are identified in the attached Exhibit B. C. The COUNTY will require the design firm to submit plans, design calculations, and check design calculations to the STATE. D. The COUNTY will also require the design firm to load rate each structure, including culverts that are bridge length, in accordance with the edition of the AASHTO “Manual for Bridge Evaluation” with latest Interim Revisions using the LRFR method currently in place at the time of execution of the design engineering contract. The design firm will perform an HL-93 design load rating for each structure. The design firm will analyze the AASHTO HS20 vehicle for Inventory and Operating Ratings. The design firm will also perform a legal load rating for South Dakota legal trucks, the notional rating load, and the four specialized hauling vehicles. The design firm will submit a copy of the rating analyses to the STATE. The STATE will review load ratings and provide comments to the design firm. The design firm will address all STATE comments to the satisfaction of the STATE. The design firm will provide a separate summary table of all load ratings to be included in the STATE’S bridge inspection file. E. If applicable, the COUNTY will also require the bridge design engineering firm to submit scour analyses and develop a Quality Control/Quality Assurance (QC/QA) plan. The QC/QA plan must follow the format developed by the STATE. F. The parties recognize that unanticipated and time-sensitive work may be needed for completion of the PROJECT and that delays in completing such work could jeopardize the PROJECT schedule. The COUNTY authorizes the STATE to write work orders and hire consultants for the PROJECT for...
Sample 1See All (5)
AutoNDA by SimpleDocs
PROJECT PLANNING AND CONSTRUCTION. A. The CITY will select a professional engineering firm from the STATE’S current consultant retainer list for the bridge design category of work. B. The STATE will hire the professional engineering firm selected by the CITY to perform the preliminary engineering for the PROJECT. The requirements for the preliminary engineering services to be performed are identified in the attached Exhibit B. C. The STATE will invite the CITY, and the CITY will participate in, all planning, scoping, and inspection meetings held in connection with the PROJECT. D. The STATE will submit to the CITY a draft type, size, and location (TS&L) report for the PROJECT for the CITY’S review and comment. The CITY will review the TS&L and provide the CITY’S comments to the STATE. The STATE will address, in writing, all comments made by the CITY to the CITY’S satisfaction.
Sample 1Sample 2
PROJECT PLANNING AND CONSTRUCTION. 1. Party A shall design and construct the Project in satisfaction with the requirements and standards agreed in Appendices III, IV, V, VI, VII, VIII, IX and X hereto, and deliver the conceptual design and the design drawings of the Project to Party B for comment. Party B shall give written review comments thereupon within the time specified in Appendix VII. Party A shall conduct full communication with Party B within 7 days upon the review comments from Party B, and shall make adjustments and amendments to the conceptual design and the design plan according to the function requirements of Party B. Both parties shall give written confirmation of the conceptual design and the design plan so adjusted and modified by Party A and use them as the basis of project design and construction. Nevertheless, both parties agree that, if they fail to agree upon such review comments with said 7-day period, Party A shall prepare the final amendment opinion and give a written notice thereof to Party B based on standards not inferior to “Tower C, Raycom Information Plaza”, according to applicable requirements of Chinese laws, regulations and policies, and subject to satisfaction of the design requirements and covenants concerning material/equipment brand and specification as set forth in Appendices III, IV, V and VI, and carry out construction of the Project on the basis thereof. Both parties acknowledge that, in the event that any dispute occurs between both parties with regard to the design or construction standards of the Project during development and construction of the Project, Party A shall immediately provide Party B with the files and documents concerning the design and construction standards of “Tower C, Raycom Information Plaza” and unconditionally assist Party B in consulting relevant files and conducting verification on the site of the Project.
Sample 1
PROJECT PLANNING AND CONSTRUCTION. A. The STATE will prepare plans. advertise the PROJECT and RSI PROJECT for bids, award a contract to the lowest responsible bidder, be the contracting party for the PROJECT and RSI PROJECT, and administer construction of the PROJECT and RSI PROJECT, except for the tasks to be undertaken by the COUNTY as detailed in this Agreement. B. The COUNTY will sweep roadways to be striped in advance of the contractor's operations. C. The COUNTY will provide the PROJECT and RSI PROJECT inspection for that portion of the PROJECT and RSI PROJECT involving the COUNTY'S roads. D. The COUNTY will be solely responsible for ensuring that no passing zones are clearly marked for the
Sample 1
PROJECT PLANNING AND CONSTRUCTION. A. The CITY will provide any necessary public right-of-way for the PROJECT at the CITY’S sole expense. Right-of-way costs will not be eligible for funding disbursements under this Agreement. B. The CITY will obtain any required environmental clearances for the PROJECT at the CITY’S sole expense. Environmental costs will not be eligible for funding disbursements under this Agreement. C. The CITY will dedicate to public use the PROJECT’S roadway and right-of-way. D. The CITY will at all times maintain the PROJECT as a public street. E. The CITY will, at the CITY’S sole expense, obtain construction plans, specifications, and estimates for the PROJECT. The CITY will submit the plans, specifications and estimates to the STATE for the STATE’S review and comment prior to advertising the PROJECT for bids. The CITY will not proceed with advertising the PROJECT bid-letting until the CITY has received written notification from the STATE that all the STATE’S comments have been addressed to the STATE’S satisfaction. F. The CITY will manage and supervise the bid letting and construction of the PROJECT. G. The CITY will, at the CITY’S sole expense, advertise and conduct the bid-letting for the construction contract for the PROJECT. The CITY will not award the construction contract unless the STATE has concurred in writing to the award of the contract. H. Construction costs will be ineligible for funding disbursements if the costs are the result of a construction change order that exceeds the scope of work in the contract as originally awarded or if the costs are determined by the STATE to be unnecessary, unreasonable, or inconsistent with the requirements of the construction contract.
Sample 1

Related to PROJECT PLANNING AND CONSTRUCTION

  • Design and Construction In complying with the requirements of the specification both with respect to arrangement and detail, design is to conform to the best current engineering practice. Each of the several parts of the material is to be of the maker’s standard design provided that this design is in general accordance with the specification. The essence of design should be simplicity and reliability in order to give long continuous service with high economy and low maintenance cost. Particular attention should be paid to internal and external access in order to facilitate inspection, cleaning and maintenance. The design dimensions and materials of all parts are to be such that they will not suffer damage as a result of stresses under the most severe conditions. Fully detailed specifications of the several parts of the material are to be submitted describing particularly the materials to be used. The materials used in the construction of the material are to be of the highest quality and selected particularly to meet the duties required of them. Mechanisms are to be constructed to avoid sticking due to rust or corrosion. Workmanship and general finish are to be of the highest class throughout. All similar parts of the material are to be interchangeable. All equipment is to operate without undue vibration and with the least possible amount of noise and is not to cause a nuisance. All equipment is to be designed to minimize the risk of fire and any damage, which may be caused in the event of fire. The equipment is also to be designed to prevent ingress of all vermin, accidental contact with live parts and to minimize the ingress of dust and dirt. The use of materials, which may be liable to attack by termites or other insects, is to be avoided.

  • PRE-CONSTRUCTION PHASE SERVICES The Pre-Construction Phase shall be deemed to commence upon the date specified in a written Notice to Proceed with Pre-Construction Phase Services issued by Owner and shall continue through completion of the Construction Documents and procurement of all major Subcontractor agreements. Contractor is not entitled to reimbursement for any costs incurred for Pre-Construction Phase Services performed before issuance of the written Notice to Proceed. Pre-Construction Phase Services may overlap Construction Phase Services. Contractor shall perform the following Pre-Construction Phase Services:

  • Project Planning GOVERNMENTAL APPROVALS; ENVIRONMENTAL COMPLIANCE; PUBLIC INFORMATION 30 4.1 Planning and Engineering Activities 30 4.2 Site Conditions 30 4.3 Governmental Approvals 30 4.4 Environmental Compliance 34 4.5 Community Outreach and Public Information 35

  • Construction Phase Services 3.1.1 – Basic Construction Services

  • Project Construction The Contractor agrees to provide continuous on-site supervision on each Job Order, while progress on the project is being accomplished. The Contractor’s Project Manager will ensure: 1. Coordination and providing supervision to all Subcontractor and workers; 2. Posting of the prevailing wage scale; 3. Maintaining a copy of the Contractors safety program manual made available to all construction personnel; 4. Conducting weekly on-site safety meetings; 5. Completing the daily labor and construction progress log on a daily basis and submit copies to the County on a daily basis. Copies of the previous day’s reports must be submitted by 9:00AM of the following day. a. Daily labor log is to include a listing of Subcontractor(s) and a count of workers by trade providing services for the day. b. Construction progress log is to include a narrative of the Work provided by trade(s). Narrative agrees to include the various areas of the jobsite where Work was performed and any problems or conditions that were encountered. c. In the event the Contractor fails to provide a daily log and/or construction progress log, the County may impose damages against the Contractor in the amount of fifty dollars ($50.00) for each log and deduct from the Contractor’s payment request, for each day the Contractor does not provide the documentation. 6. County may suspend Contractor operations if no Contractor Superintendent is observed. All delays caused by the suspension will be the responsibility of the Contractor. No time extension or claims for cost(s) associated with the suspension will be granted by the County.

  • ADDITIONAL CONSTRUCTIONS The Promoter undertakes that it has no right to make additions or to put up additional structure(s) anywhere in the Project after the building plan has been approved by the competent authority(ies) except for as provided in the Act.

  • Interconnection Facilities Engineering Procurement and Construction Interconnection Facilities, Network Upgrades, and Distribution Upgrades shall be studied, designed, and constructed pursuant to Good Utility Practice. Such studies, design and construction shall be based on the assumed accuracy and completeness of all technical information received by the Participating TO and the CAISO from the Interconnection Customer associated with interconnecting the Large Generating Facility.

  • General Construction 20.2.1. Binding Nature.............................................. 20.2.2. Entire Agreement............................................ 20.2.3. Governing Law............................................... 20.2.4. Indulgences Not Waivers..................................... 20.2.5. Titles Not to Affect Interpretation......................... 20.2.6.

  • Information Systems Acquisition Development and Maintenance a. Client Data – Client Data will only be used by State Street for the purposes specified in this Agreement.

  • Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!