Requests for Time Extensions Sample Clauses

Requests for Time Extensions. If the project cannot be completed within the period of performance specified in the financial instrument, the agency must submit a written request to the SNPLMA Division for a project modification to extend 46 The decision memoranda approved by the EC on 9/3/10 regarding a one-time comprehensive time extension for multiple projects and the 9/3/10 decision memorandum for IA revisions both included a requirement that requests for time extensions include an updated workplan. This has proved to be impractical and unnecessary. This requirement was implemented prior to development of Appendix M which includes impacts on project deliverables. Modification of the workplan is best left until the decision is finalized so that revisions are sure to be consistent with what was/or was not approved.
Sample 1Sample 2
AutoNDA by SimpleDocs
Requests for Time Extensions. Re- quests for time extensions beyond the Grantee’s authority shall be submitted by the Grantee to the RD and shall in- clude the following: (1) The dates and provisions of all previous time extensions on the project; and (2) A detailed justification for the delay and a projected completion date. The RD shall review the request and make a determination. The Grantee shall be notified of the RD’s determina- tion in writing. If the RD approves the request, the letter shall reflect the ap- proved completion date and any other requirements the RD may determine necessary to ensure that the new com- pletion date is met. If the RD denies the time extension request, the grantee may, upon completion of the project, be reimbursed for eligible project costs incurred only up to the latest approved completion date. If the project is not completed, no Federal funding will be provided for that project.
Sample 1Sample 2
Requests for Time Extensions. In the event the Contractor believes it is entitled to an extension of the contract performance period, completion date, or any interim milestone date, furnish the following for a determination by the Contracting Officer: justification, project schedule data, and supporting evidence as the Contracting Officer may deem necessary. Submission of proof of excusable delay, based on revised activity logic, duration, and costs (updated to the specific date that the delay occurred) is a condition precedent to any approvals by the Government. In response to each Request For Proposal issued by the Government, submit a schedule impact analysis demonstrating whether or not the change contemplated by the Government impacts the critical path.
Sample 1
Requests for Time Extensions. If a contract has not been executed for the acquisition within the term of the task order (one year from the effective date of the task order), the agency must request an Amendment to extend the Task Order accompanied by a justification statement. The LSA Division can approve up to two time extensions of up to six months each for acquisitions as follows: (a) one time extension request of six months or less to allow additional time to execute a contract and/or (b) one extension of six months or less to allow time to complete the acquisition after a contract has been signed. The Executive Committee must approve (a) any single time extension request of greater than six months, (b) requests for a second 6-month extension when no contract has been signed following expiration of an initial 6-month extension by the LSA Division, and (3) requests for any extension beyond the two six-month extensions which can be authorized by the LSA Division. Approved requests will be documented in an Amendment to the Task Order. Failure to agree on price following receipt of a federally approved appraisal is not, in and of itself, sufficient justification for a time extension. Requests for Change in Scope. Lands and/or interests in land are evaluated, scored, ranked, and approved by the Secretary based on their resource values and public benefit. Changes in the acreage, parcels, or rights to be acquired could dramatically impact the values on which the ranking and approval were based. Any such changes should be identified and notification of the changes submitted in writing prior to or at the time a task order is requested, if possible, or as soon as circumstances develop which would prevent acquisition of the property as nominated and approved. The notification must include a description of the change in acreage, number of parcels, and/or rights being offered, and an explanation of how the change impacts the resource values on which approval of the acquisition was based. If the resources are negatively impacted or measurably reduced, but the agency believes the acquisition should move forward, provide a thorough justification for completing the acquisition in spite of the negative impact created by the change in scope.
Sample 1
Requests for Time Extensions. If the project cannot be completed by the date identified in the task order, the agency must request an Amendment to extend the Task Order. The request must be submitted to the NSO Division of Support Services and include a justification statement. The NSO Division can approve a one time extension request of six months or less for projects; however, the Tahoe Regional Executive Committee must rule on additional time extension requests and requests greater than six months.
Sample 1
Requests for Time Extensions. ‌ If the project cannot be completed within the period of performance specified in the financial instrument, the agency/entity must submit a written request in accordance with the instructions in the IA Part Two, Appendix L to the SNPLMA Division for a project modification to extend the project. Approved requests will be documented in a modification to the applicable financial instrument. (See Section XI.A. and B. regarding Projects of Concern for impact of time extensions.) Rules applicable to requests for and approval of time extensions are listed below.133 1. Requests for time extensions should be submitted at least 120 days in advance of the expiration of the period of performance (i.e., project expiration/end date) in the financial instrument as defined previously in Section VIII to ensure time extensions can be processed prior to project expiration.134 2. The SNPLMA Division may process and approve a one-time 90-day time extension135 over and above any previous time extensions (including ones approved by the EC) to cover unexpected circumstances where the agency needs just a short time to complete final steps of the project (e.g., close out a contract, conduct final inspection, receipt of “Notice of Completion and Release of Claims,” etc.) and prepare and submit a closeout package. • Requests for a one-time 90-day extension do not require submittal of a revised detailed cost estimate worksheet, map, or a revised work plan after approval. • Requests for a one-time 90-day extension should be submitted at least 30 days prior to expiration of the project to allow time for processing and modification of the project’s financial instrument. 3. If the period of performance in the current financial instrument (i.e., IAA, task order, assistance agreement, or the transfer authorization letter) expires before an amendment or new instrument extending the period of performance is executed, the recipient agency/entity shall not create new obligations or incur new expenses, and shall not be reimbursed/paid for new obligations or expenses incurred during the lapse in the period of performance. If a contract is awarded with a completion date past the SNPLMA project expiration date (end date of the period of performance in the financial instrument), SNPLMA will not be responsible for any costs.136 4. The category-specific standard project timeframes (See Section V. A. 9) are applied retroactively to all open projects when making a decision to recommend a time extension...
Sample 1
Requests for Time Extensions. If the project can not be completed within the term specified in the IGO/task order, the agency must submit a written request to the SNPLMA Division for an Amendment to extend the IGO/task order accompanied by a justification statement including the new estimated completion date. Approved requests will be documented in an Amendment to the IGO/task order. The consideration and approval process and thresholds are addressed in section XI below.
Sample 1
AutoNDA by SimpleDocs

Related to Requests for Time Extensions

  • Time Extensions 2.03.1 If Contractor requests an extension of time to complete its performance, then the Director, in consultation with the CPO, may, in his or her sole discretion, extend the time so long as the extension does not exceed 90 days. The extension must be in writing but does not require amendment of this Agreement. Contractor is not entitled to damages for delay(s) regardless of the cause of the delay(s).

  • Time Extension CONTRACTOR shall provide a time extension request on completion of Task Order for delays caused by others (Permitting Agencies, COUNTY or Contract Cities, or unforeseen conditions such as inclement weather, etc.) and at no fault by CONTRACTOR, subject to approval by COUNTY. COUNTY will review the request and determine in its sole discretion whether the situation warrant a time extension at no-cost or with costs. If CONTRACTOR completes the Task Order beyond the stipulated completion date without COUNTY’s specific written approval for time extension, CONTRACTOR will be subject to liquidated damages and may be construed as non-responsive, which may affect CONTRACTOR for considerations for future Task Orders or projects.

  • Requests for Extension The Borrower may, by notice to the Administrative Agent (who shall promptly notify the Lenders) not earlier than 90 days and not later than 35 days prior to an anniversary of the Closing Date (each, an “Applicable Anniversary Date”), request that each Lender extend such Lender’s Maturity Date for an additional year from the Maturity Date then in effect for such Lender hereunder (such Lender’s “Existing Maturity Date”). The Borrower may request such an extension no more than two times.

  • REQUESTS FOR FLEXIBLE WORKING ARRANGEMENTS 49.1 Employee may request change in working arrangements s.65 of the Act. Note 1: Section 65 of the Act provides for certain Employees to request a change in their working arrangements because of their circumstances, as set out in s.65(1A).

  • Requests for Leave Except as provided under Section B.3., Family Care/Medical Leave Notification, requests for leaves of absence and extensions, with or without pay, shall be submitted in writing to the University. Such requests shall be submitted sufficiently in advance of the requested leave date to provide the University time to assess the operational impact of granting the request. All requests for leaves of absence shall contain the requested beginning and end date of the leave, and any additional information as required.

  • Extension of time for completion (i) Without prejudice to any other provision of this Agreement for and in respect of extension of time, the Contractor shall be entitled to extension of time in the Project Completion Schedule (the “Time Extension”) to the extent that completion of any Project Milestone is or will be delayed by any of the following, namely: (a) delay in providing the Right of Way of Construction Zone, environmental clearances or approval of railway authorities, specified in Clause 3.1 (iv); (b) Change of Scope (unless an adjustment to the Scheduled Completion Date has been agreed under Article 13); (c) occurrence of a Force Majeure Event; (d) any delay, impediment or prevention caused by or attributable to the Authority, the Authority's personnel or the Authority's other contractors on the Site; and (e) any other cause or delay which entitles the Contractor to Time Extension in accordance with the provisions of this Agreement. (ii) The Contractor shall, no later than 15 (fifteen) business days from the occurrence of an event or circumstance specified in Clause 10.5 (i), inform the Authority’s Engineer by notice in writing, with a copy to the Authority, stating in reasonable detail with supporting particulars, the event or circumstances giving rise to the claim for Time Extension in accordance with the provisions of this Agreement. Provided that the period of 15 (fifteen) business days shall be calculated from the date on which the Contractor became aware, or should have become aware, of the occurrence of such an event or circumstance. Provided further that notwithstanding anything to the contrary contained in this Agreement, Time Extension shall be due and applicable only for the Works which are affected by the aforesaid events or circumstances and shall not in any manner affect the Project Completion Schedule for and in respect of the Works which are not affected hereunder. (iii) On the failure of the Contractor to issue to the Authority’s Engineer a notice in accordance with the provisions of Clause 10.5 (ii) within the time specified therein, the Contractor shall not be entitled to any Time Extension and shall forfeit its right for any such claims in future. For the avoidance of doubt, in the event of failure of the Contractor to issue notice as specified in this clause 10.5 (iii), the Authority shall be discharged from all liability in connection with the claim. (iv) The Authority’s Engineer shall, on receipt of the claim in accordance with the provisions of Clause 10.5 (ii), examine the claim expeditiously within the time frame specified herein. In the event the Authority’s Engineer requires any clarifications to examine the claim, the Authority’s Engineer shall seek the same within 15 (fifteen) days from the date of receiving the claim. The Contractor shall, on receipt of the communication of the Authority’s Engineer requesting for clarification, furnish the same to the Authority’s Engineer within 10 (ten) days thereof. The Authority’s Engineer shall, within a period of 30 (thirty) days from the date of receipt of such clarifications, forward in writing to the Contractor its determination of Time Extension. Provided that when determining each extension of time under this Clause 10.5, the Authority’s Engineer shall review previous determinations and may increase, but shall not decrease, the total Time Extension. (v) If the event or circumstance giving rise to the notice has a continuing effect: (a) a fully detailed claim shall be considered as interim; (b) the Contractor shall, no later than 10 (ten) days after the close of each month, send further interim claims specifying the accumulated delay, the extension of time claimed, and such further particulars as the Authority’s Engineer may reasonably require; and (c) the Contractor shall send a final claim within 30 (thirty) days after the effect of the event or the circumstance ceases. Upon receipt of the claim hereunder, the Authority’s Engineer shall examine the same in accordance with the provisions of Clause 10.5 (iv) within a period of 30 (thirty) days of the receipt thereof

  • Matters Applicable to All Requests for Compensation (a) Any Agent or any Lender claiming compensation under this Article III shall deliver a certificate to the Borrower setting forth the additional amount or amounts to be paid to it hereunder which shall be conclusive in the absence of manifest error. In determining such amount, such Agent or such Lender may use any reasonable averaging and attribution methods. (b) With respect to any Lender’s claim for compensation under Sections 3.01, 3.02, 3.03 or 3.04, the Borrower shall not be required to compensate such Lender for any amount incurred more than one hundred and eighty (180) days prior to the date that such Lender notifies the Borrower of the event that gives rise to such claim; provided that if the circumstance giving rise to such claim is retroactive, then such 180-day period referred to above shall be extended to include the period of retroactive effect thereof. If any Lender requests compensation by the Borrower under Section 3.04, the Borrower may, by notice to such Lender (with a copy to the Administrative Agent), suspend the obligation of such Lender to make or continue from one Interest Period to another applicable Eurocurrency Rate Loan, or, if applicable, to convert Base Rate Loans into Eurocurrency Rate Loans, until the event or condition giving rise to such request ceases to be in effect (in which case the provisions of Section 3.06(c) shall be applicable); provided that such suspension shall not affect the right of such Lender to receive the compensation so requested. (c) If the obligation of any Lender to make or continue any Eurocurrency Rate Loan, or to convert Base Rate Loans into Eurocurrency Rate Loans shall be suspended pursuant to Section 3.06(b) hereof, such Lender’s applicable Eurocurrency Rate Loans shall be automatically converted into Base Rate Loans (or, if such conversion is not possible, repaid) on the last day(s) of the then current Interest Period(s) for such Eurocurrency Rate Loans (or, in the case of an immediate conversion required by Section 3.02, on such earlier date as required by Law) and, unless and until such Lender gives notice as provided below that the circumstances specified in Sections 3.02, 3.03 or 3.04 hereof that gave rise to such conversion no longer exist: (i) to the extent that such Lender’s Eurocurrency Rate Loans have been so converted, all payments and prepayments of principal that would otherwise be applied to such Lender’s applicable Eurocurrency Rate Loans shall be applied instead to its Base Rate Loans; and (ii) all Loans that would otherwise be made or continued from one Interest Period to another by such Lender as Eurocurrency Rate Loans shall be made or continued instead as Base Rate Loans (if possible), and all Base Rate Loans of such Lender that would otherwise be converted into Eurocurrency Rate Loans shall remain as Base Rate Loans. (d) If any Lender gives notice to the Borrower (with a copy to the Administrative Agent) that the circumstances specified in Sections 3.02, 3.03 or 3.04 hereof that gave rise to the conversion of any of such Lender’s Eurocurrency Rate Loans pursuant to this Section 3.06 no longer exist (which such Lender agrees to do promptly upon such circumstances ceasing to exist) at a time when Eurocurrency Rate Loans made by other Lenders under the applicable Facility are outstanding, if applicable, such Lender’s Base Rate Loans shall be automatically converted, on the first day(s) of the next succeeding Interest Period(s) for such outstanding Eurocurrency Rate Loans, to the extent necessary so that, after giving effect thereto, all Loans held by the Lenders holding Eurocurrency Rate Loans under such Facility and by such Lender are held pro rata (as to principal amounts, interest rate basis, and Interest Periods) in accordance with their respective Commitments for the applicable Facility.

  • Amendments; Renewal Any amendments, consents to or waivers of the terms of this Contract must be in writing and signed by both parties. The parties may renew this Contract by their signed, written instrument.

  • Requests for Approval If the Administrative Agent requests in writing the consent or approval of a Lender, such Lender shall respond and either approve or disapprove definitively in writing to the Administrative Agent within ten Business Days (or sooner if such notice specifies a shorter period for responses based on Administrative Agent’s good faith determination that circumstances exist warranting its request for an earlier response) after such written request from the Administrative Agent. If the Lender does not so respond, that Lender shall be deemed to have approved the request.

  • Timely Written Requests for Extensions CHSI may, in advance of the due date, submit a timely written request for an extension of time to perform any act or file any notification or report required by this CIA. Notwithstanding any other provision in this Section, if OIG grants the timely written request with respect to an act, notification, or report, Stipulated Penalties for failure to perform the act or file the notification or report shall not begin to accrue until one day after CHSI fails to meet the revised deadline set by OIG. Notwithstanding any other provision in this Section, if OIG denies such a timely written request, Stipulated Penalties for failure to perform the act or file the notification or report shall not begin to accrue until three business days after CHSI receives OIG’s written denial of such request or the original due date, whichever is later. A “timely written request” is defined as a request in writing received by OIG at least five business days prior to the date by which any act is due to be performed or any notification or report is due to be filed.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!