Payment for Project Services As full consideration for the Services to be performed by Contractor, City agrees to pay Contractor as set forth in accordance with the bid and not to exceed fee of $696,243.00 for the project. A monthly progress payment in the amount of ninety-five percent (95%) of the value of the work completed may be made every thirty (30) days upon application by the Contractor and certification by the Project Manager that such work has been completed. Partial payments will be made once each month as the work satisfactorily progresses and after acceptance by the authorized City representative. The progress estimates shall be based upon materials in place, or on the job site and invoiced, and labor expended thereon. From the total of the amount ascertained will be deducted an amount equivalent to five percent (5%) of the whole, which five percent (5%) will be retained by the City until after completion of the entire Contract in an acceptable manner. Any time after fifty percent (50%) of the value of the work has been completed, the City will make any of the remaining partial payments in full. No such estimates or payments shall be required to be made, when, in the judgment of the City Project Manager, the work is not proceeding in accordance with the provision of the Contract, or when in his judgment the total value of the work done since last estimate amounts to less than Five Hundred Dollars ($500.00). The cost of materials conforming to the plans and specifications (materials being those which are required to be contained and incorporated in a finished contract bid item) delivered to the project and not at the time incorporated in the work, may also be included in the estimate for payment. No such estimate or payment shall be construed to be an acceptance of any defective work or improper material. The Contractor shall be responsible for, and shall not remove from the project any material that has been included in the estimate for payment. Final payment shall be made upon the Project Manager certifying that the Contractor has satisfactorily completed the work in conformity with the Contract Documents.
Project Staffing Prior to the start of any work under this Agreement, Consultant must submit to City detailed resumes of key personnel that will be involved in performing services prescribed in the Agreement. City hereby acknowledges its acceptance of such personnel to perform services under this Agreement. At any time hereafter that Consultant desires to change key personnel while performing under the Agreement, Consultant must submit the qualifications of the new personnel to City for prior approval. Key personnel include, but are not limited to, principals-in-charge, project manager, and project Consultant. Consultant will maintain an adequate and competent staff of qualified persons, as may be determined by City, throughout the performance of this Agreement to ensure acceptable and timely completion of the Scope of Services. If City objects, with reasonable cause, to any of Consultant’s staff, Consultant must take prompt corrective action acceptable to City and, if required, remove such personnel from the Project and replace with new personnel agreed to by City.
Requirement for Project Planning No physical work will begin on the construction site until the receipt of a Proceed Order issued by the Owner. The Contract assumes that a Proceed Order will be issued in not more than sixty days from the Effective Date of the Contract. Failure of the Contractor to provide the necessary documentation for the issuance of a Proceed Order shall not entitle the Contractor to any extension of time. If a Proceed Order is not issued within sixty days from the award of the Contract and non-issuance is due to nonperformance by the Contractor, the Contractor may be in default.
Project Staff Contractor shall appoint to the Project Staff: (i) individuals with suitable training and skills to provide the Work, and (ii) sufficient staffing to adequately provide the Work. Contractor shall make commercially reasonable efforts consistent with sound business practices to honor the specific request of the JBE with regard to assignment of its employees. The JBE may require Contractor to remove any personnel from the Project Staff that interact with any personnel of the Judicial Branch Entities or JBE Contractors (including, without limitation, the Contractor Project Manager) upon providing to Contractor a reason (permitted by law) for such removal. Contractor may, with the JBE’s consent, continue to retain such member of the Project Staff in a role that does not interact with any personnel of the Judicial Branch Entities or
Staffing Plan 8.l The Board and the Association agree that optimum class size is an important aspect of the effective educational program. The Polk County School Staffing Plan shall be constructed each year according to the procedures set forth in Board Policy and, upon adoption, shall become Board Policy.
Staffing Committee A. Responsibilities. The Nurse Staffing Committee (“NSC”) shall be responsible for determining the Institute’s staffing plan and resolving complaints raised by nurses regarding the implementation of the plan as well as those activities required of it under RCW 70.41, et seq and its successors.
Project Steering Committee (a) The Recipient shall establish and maintain at all times until the completion of the Project, the Project Steering Committee with a composition, mandate and resources satisfactory to the Association.
Clinical Management for Behavioral Health Services (CMBHS) System The CMBHS is the official record of documentation by System Agency. Grantee shall:
Design Development Phase Services 3.3.1 Based on the Owner’s approval of the Schematic Design Documents, and on the Owner’s authorization of any adjustments in the Project requirements and the budget for the Cost of the Work, the Architect shall prepare Design Development Documents for the Owner’s approval. The Design Development Documents shall illustrate and describe the development of the approved Schematic Design Documents and shall consist of drawings and other documents including plans, sections, elevations, typical construction details, and diagrammatic layouts of building systems to fix and describe the size and character of the Project as to architectural, structural, mechanical and electrical systems, and other appropriate elements. The Design Development Documents shall also include outline specifications that identify major materials and systems and establish, in general, their quality levels.
Local Professional Development Committee 1. The Local Professional Development Committee (LPDC) shall be established to oversee and review professional development plans pursuant to ORC 3319.22.
