Tenant Contractor Sample Clauses

Tenant Contractor. No work shall be done on the Premises by Tenant until Landlord has approved Xxxxxx’s plans and General Contractor in writing. In instances where Xxxxxx’s Work may coincide with Landlord’s completion of the Center (as is the case of new centers or new phases), Tenant’s General Contractor shall work in conjunction with Xxxxxxxx’s building contractor so that Xxxxxx’s General Contractor does not interfere or delay the construction process of Landlord’s building. Tenant’s General Contractor must perform the work in such a manner as not to cause harm to Landlord’s Work, delay the progress of Landlord’s Work or create conflicts with labor organizations. Landlord reserves the right to cause the removal of Xxxxxx’s General Contractor if any such labor problems arise. Tenant’s General Contractor must keep the area, HVAC system and restroom clean and free of dust and debris, with a minimum of noise and interruption to the Common Areas of the Center. Tenant’s General Contractor is responsible for keeping interior and exterior areas clean of construction debris at all times. If Xxxxxx’s General Contractor fails or refuses to keep these areas clean at all times, Landlord reserves the right to clean these areas at Tenant’s expense. Tenant’s General Contractor must contract with Landlord’s approved vendor for all trash removal. Tenant’s General Contractor shall erect temporary partitions, dust barriers, etc. as required by Landlord to minimize impact of construction activities on the Common Areas of the Center.
Sample 1Sample 2Sample 3See All (7)
AutoNDA by SimpleDocs
Tenant Contractor. Any independent contractor of Tenant (or any employee or agent of Tenant) performing Tenant’s Construction shall be a “Tenant Contractor” and shall be subject to all of the terms, conditions and requirements contained in the Lease. The identity and qualifications of each Tenant Contractor shall be subject to Landlord’s prior written approval, which shall not be unreasonably withheld, conditioned, or delayed. Without limitation, Tenant shall require each Tenant Contractor to adjust and coordinate Tenant’s Construction to meet the schedule or requirements of other work being performed by or for Landlord throughout the Building, which shall in all cases have precedence. Tenant shall insure that each Tenant Contractor shall take all reasonable steps to assure that any work is carried out without disruption from labor disputes arising from whatever cause, including, without limitation, disputes concerning union jurisdiction and the affiliation of workers employed by said Tenant Contractor or its subcontractors. Tenant shall be responsible for, and shall reimburse Landlord for, all costs and expenses, including, without limitation, attorney’s fees incurred by Landlord in connection with any breach by the contractor of such obligations. At all times while performing Tenant’s Construction, Tenant and each Tenant Contractor shall not discriminate against any individual because of race, color, sex, religion or national origin and will, as may be required by the municipality in which the Building is located or any other public authority having jurisdiction, comply with all applicable laws, regulations and equal opportunity policies generally adhered to by comparable office buildings in the same geographic area as the Building. In the event that special security arrangements must be made (e.g., in connection with work outside normal business hours), then the cost of such security must be paid by the Tenant Contractor requesting such security. Tenant must ensure that each Tenant Contractor and subcontractors use every effort to minimize noise caused by Tenant’s Construction. Work stoppage during Hours of Operation will be ordered if noise, in the sole judgment of the Building manager, disturbs other tenants of the Building, and Landlord shall have no liability therefor. In all events, Tenant shall indemnify the Indemnitees in the manner provided in Section 9.02 of the Lease against any claim, loss or cost arising out of any interference with, or damage to, any work in ...
Sample 1Sample 2See All (6)
Tenant Contractor. Any contractor of Tenant (or any employee or agent of Tenant) performing Tenant’s Initial Construction shall be subject to all of the terms, conditions and requirements contained in the Lease. Landlord shall have the right to review and approve the contract between Tenant and the general contractor performing Tenant’s Initial Construction, such approval not to be unreasonably withheld, conditioned or delayed.
Sample 1

Related to Tenant Contractor

  • Contractor If COUNTY elects to renegotiate this Agreement due to reduced or terminated 20 funding, CONTRACTOR shall not be obligated to accept the renegotiated terms.

  • General Contractor A building, construction, or contracting firm with whom Borrower has contracted or may in the future contract with for the construction of the Improvements pursuant to a certain construction contract between them (the "Construction Contract").

  • Tenant’s Work Landlord and Tenant acknowledge and agree that certain work required for Tenant's occupancy of the Leased Premises, including but not limited to the procurement and installation of furniture, fixtures, equipment, artwork and interior signage are beyond the scope of the Tenant Improvements and shall be performed by Tenant or its contractors at Tenant's sole cost and expense. All such work ("Tenant's Work") shall be subject to Landlord's prior written approval. Tenant shall adopt a construction schedule for Tenant's Work in conformance with the Contractor's schedule, and shall perform Tenant's Work in such a way as not to hinder or delay the operations of Landlord or the Contractor in the Building. Any costs incurred by Landlord as a result of any interference with Landlord's operations by Tenant or its contractors shall be promptly paid by Tenant to Landlord upon demand. Landlord shall make all reasonable efforts to notify Tenant of any such interference of which Landlord has actual knowledge, but failure to provide such notice shall in no way limit Landlord's right to demand payment for such costs. Tenant's contractors shall be subject to Landlord's prior written approval, and to the administrative supervision of the Contractor. Tenant's Work shall comply with all of the following requirements: (a) Tenant's Work shall not proceed until Landlord has approved in writing: (i) Tenant's contractors, (ii) proof of the amount and coverage of public liability and property damage insurance carried by Tenant's contractors in the form of an endorsed insurance certificate naming Landlord, the Contractor, and the agents of Landlord and the Contractor as additional insureds, in an amount not less than two million dollars, and (iii) complete and detailed plans and specifications for Tenant's Work. (b) Tenant's Work shall be performed in conformity with a valid permit when required, a copy of which shall be furnished to Landlord before such work is commenced. In any event, all Tenant's Work shall comply with all applicable laws, codes and ordinances of any governmental entity having jurisdiction over the Building. Landlord shall have no responsibility for Tenant's failure to comply with such applicable laws. Any and all delay in obtaining a certificate of occupancy due to Tenant's vendors is the responsibility of Tenant and shall be a Tenant Delay. (c) In connection with Tenant's Work (e.g., delivering or installing furniture or equipment to the second floor of the Leased Premises), Tenant or its contractors shall arrange for any necessary hoisting or elevator service with Landlord and shall pay such reasonable costs for such services as may be charged by Landlord. (d) Tenant shall promptly pay Landlord upon demand for any extra expense incurred by Landlord by reason of faulty work done by Tenant or its contractors, by reason of damage to existing work caused by Tenant or its contractors, or by reason of inadequate cleanup by Tenant or its contractors.

  • Tenant Work Before commencing any repair or Alteration (“Tenant Work”), Tenant shall deliver to Landlord, and obtain Landlord’s approval of, (a) names of contractors, subcontractors, mechanics, laborers and materialmen; (b) evidence of contractors’ and subcontractors’ insurance; and (c) any required governmental permits. Tenant shall perform all Tenant Work (i) in a good and workmanlike manner using materials of a quality reasonably approved by Landlord; (ii) in compliance with any approved plans and specifications, all Laws, the National Electric Code, and Landlord’s construction rules and regulations; and (iii) in a manner that does not impair the Base Building. If, as a result of any Tenant Work, Landlord becomes required under Law to perform any inspection, give any notice, or cause such Tenant Work to be performed in any particular manner, Tenant shall comply with such requirement and promptly provide Landlord with reasonable documentation of such compliance. Landlord’s approval of Tenant’s plans and specifications shall not relieve Tenant from any obligation under this Section 7.3. In performing any Tenant Work, Tenant shall not use contractors, services, labor, materials or equipment that, in Landlord’s reasonable judgment, would disturb labor harmony with any workforce or trades engaged in performing other work or services at the Project.

  • Tenant The complete name of every Tenant who will enter this lease with the intention of renting the Landlord’s property as a month-to-month rental is a necessary part of this document’s introduction.

  • Lessee The related Lessee is a Person other than MBFS USA, any Affiliate thereof or a Governmental Authority and, at the time of origination of the 201[__]-[__] Lease, based on information provided by the Lessee, the Lessee is located in and has a billing address within a State.

  • LANDLORD The covenants and obligations contained in this Lease on the part of Landlord are binding on Landlord, its successors, and assigns only during their respective period of ownership of an interest in the Building. In the event of any transfer or transfers of such title to the Building, Landlord (and, in the case of any subsequent transfers or conveyances, the then grantor) shall be concurrently freed and relieved from and after the date of such transfer or conveyance, without any further instrument or agreement, of all liability with respect to the performance of any covenants or obligations on the part of Landlord contained in this Lease thereafter to be performed.

  • THE WORK The Work comprises the completed construction required by the Contract Documents and includes all labor necessary to produce such construction, and all materials and equipment incorporated or to be incorporated in such construction.

  • Landlord Work Prior to the execution of this First Amendment, Landlord and Tenant have approved (i) a detailed space plan for the construction of Landlord’s Work in the Premises, which space plan has been prepared by Studio O + A (“Final Approved Plan”) and (ii) a bid proposal for the construction of Landlord’s Work in the Premises, which bid proposal has been prepared by XX Xxxx Construction and is dated June 2, 2011 (Rev-2) (“Bid Proposal”). The Final Approved Plan and Bid Proposal are approved by the parties as of the Effective Date, are attached hereto collectively, as Exhibit “D-1” and hereby replaces the original Approved Plan attached to the Lease as Exhibit “D-1”. Consequently, all references in the Work Letter to the “Approved Plan” shall mean and refer to the Final Approved Plan and Bid Proposal attached hereto as Exhibit “D-1”. Landlord agrees to construct the Landlord Work, pursuant to the terms and conditions set forth in the Work Letter and as depicted on the Approved Plan (as amended hereby). Landlord shall pay for the cost (including, the cost of obtaining all applicable building permits) of the design and construction of Landlord’s Work in an amount up to, but not exceeding, Two Hundred Twenty Two Thousand One Hundred Fifty and 00/100 Dollars ($222,150.00) plus any additional costs actually incurred by Landlord in excess of such $222,150.00 amount as a direct result of Landlord’s or Landlord’s contractor’s active negligence or willful misconduct or resulting from change order to the Approved Plans (as amended hereby) if such change order is initiated and executed by Landlord (the “Landlord’s Contribution”). Tenant shall pay for all costs in excess of the Landlord’s Contribution (“Over Allowance Amount”) which payment shall be made to Landlord in cash within thirty (30) days after Tenant’s receipt of invoice therefor from Landlord. Payment of the Over-Allowance Amount shall be in addition to Tenant’s obligation to pay to Landlord the cost of any Aggregate Extras as provided in Section 4 of the Work Letter.

  • Overtime Work A. Overtime pay is to be paid at the rate of one and one- half (1½) times the basic hourly straight-time rate. B. Overtime shall be paid to employees for work performed only after eight (8) hours on duty in any one (1) service day or forty (40) hours in any one (1) service week. Nothing in this Section shall be construed by the parties or any reviewing authority to deny the payment of overtime to employees for time worked outside of their regularly scheduled work week at the request of the Employer. C. Penalty overtime pay is to be paid at the rate of two

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!