Acquisition of the Project. The Borrower shall complete the Acquisition of the Project with all reasonable dispatch, delays incident to strikes, riots, acts of God or the public enemy or any delay beyond its reasonable control only excepted, in accordance with the Plans and Specifications; provided, however, that if completion of such Acquisition is delayed for any reason, there shall be no diminution in or postponement of the payments to be made by the Borrower pursuant to the Note or Section 5.1 hereof.
Acquisition of the Project. Section 3.1. Agreement to Undertake and Complete the Project....................................................9 Section 3.2. Disbursements from the Initial Fund........................9 Section 3.3. Establishment of Completion Date and Certificate as to Completion..............................10
Acquisition of the Project. 8 SECTION 4.01. Application of Proceeds of Bonds................ 8 -------------------------------- SECTION 4.02. Agreement to Acquire Project.................... 8 ---------------------------- SECTION 4.03. No Warranty of Suitability of Issuer............ 9 ------------------------------------ SECTION 4.04. Pursuit of Remedies Against Vendors Contractors ----------------------------------------------- and Subcontractors and Their Sureties........... 9 ------------------------------------- SECTION 4.05. Completion of the Project....................... 9 -------------------------
Acquisition of the Project. Section 3.1. Acquisition of the Project...................................10
Acquisition of the Project. Section 3.1.
Acquisition of the Project. Section 3.1 Changes to the Project 11 Section 3.2 Sale and Purchase of the Project 12 Section 3.3 Purchase and Sale of the Project 12 Section 3.4 Title 12 Section 3.5 Acquisition and Construction of the Project 12 ARTICLE IV SERIES 2022 INSTALLMENT PAYMENTS
Acquisition of the Project. Section 3.1. Sale of the Refunding Project to Authority 10 Section 3.2. Purchase and Sale of the 2020 Project and the Refunding Project 10 Section 3.3. Title 10 Section 3.4. Acquisition and Construction of the 2020 Project 10 Section 3.5. Changes to the 2020 Project 10 Section 3.6. Acquisition Fund 11 SERIES 2020A INSTALLMENT PAYMENTS
Acquisition of the Project. Section 3.1. Sale and Purchase of Project 9 Section 3.2. Purchase and Sale of Project 9 Section 3.3. Title 9 SERIES 2018A INSTALLMENT PAYMENTS
Acquisition of the Project. Not later than the delivery of this Lease the Issuer will have acquired the title in and to the Project which it warrants in Section 3.2 hereof. The Lessee agrees that, as principal, and not as agent for the Issuer, it will cause to be acquired or installed in the Improvements or on the Leased Land items of machinery, equipment and related property as in the Lessee’s judgment may be necessary or desirable for the operation of the Project, all of which acquisitions and installations shall be at all times subject to a first priority security interest in favor of the holder of a Superior Security Document at any time any such Superior Security Document is outstanding. Any changes to the Project Summary shall be made at the sole discretion of the Lessee and shall also be filed with the Secretary or Assistant Secretary of the Issuer and the Authorized Lessee Representative. The Issuer agrees that only such changes will be made in the Project Summary as may be specified by an Authorized Lessee Representative. The Lessee agrees to complete the acquisition of the Project in accordance with the Project Summary as promptly as practicable after the date of the execution and delivery of this Lease, but if said acquisition is not completed within the time herein contemplated there shall be no resulting diminution in or postponement of the rents required in Section 5.3 hereof to be paid by the Lessee. · The Issuer makes no warranty or representation, either express or implied, as to the suitability or fitness for a particular purpose of the Project or any portion thereof.
Acquisition of the Project. If the Lenders acquire the Project either by foreclosure or deed in lieu of foreclosure, then the Lenders agree to negotiate in good faith to reach agreement in writing relating to the ownership, operation, maintenance, marketing, and sale of the Project. The Lenders agree that such agreement shall be consistent with the following: