Building Renovations It is specifically understood and agreed that Landlord has made no representation or warranty to Tenant and has no obligation and has made no promises to alter, remodel, improve, renovate, repair or decorate the Premises, Building, or any part thereof and that no representations respecting the condition of the Premises or the Building have been made by Landlord to Tenant except as specifically set forth herein or in the Work Letter Agreement. However, Tenant hereby acknowledges that Landlord is currently renovating or may during the Lease Term renovate, improve, alter, or modify (collectively, the "Renovations") the Project, the Building and/or the Premises including without limitation the parking structure, common areas, systems and equipment, roof, and structural portions of the same, which Renovations may include, without limitation, (i) installing sprinklers in the Building common areas and tenant spaces, (ii) modifying the common areas and tenant spaces to comply with applicable laws and regulations, including regulations relating to the physically disabled, seismic conditions, and building safety and security, and (iii) installing new floor covering, lighting, and wall coverings in the Building common areas, and in connection with any Renovations, Landlord may, among other things, erect scaffolding or other necessary structures in the Building, limit or eliminate access to portions of the Project, including portions of the common areas, or perform work in the Building, which work may create noise, dust or leave debris in the Building. Tenant hereby agrees that such Renovations and Landlord's actions in connection with such Renovations shall in no way constitute a constructive eviction of Tenant nor entitle Tenant to any abatement of Rent. Landlord shall have no responsibility or for any reason be liable to Tenant for any direct or indirect injury to or interference with Tenant's business arising from the Renovations, nor shall Tenant be entitled to any compensation or damages from Landlord for loss of the use of the whole or any part of the Premises or of Tenant's personal property or improvements resulting from the Renovations or Landlord's actions in connection with such Renovations, or for any inconvenience or annoyance occasioned by such Renovations or Landlord's actions.
Premises Building Project and Common Areas 1.1 Premises, Building, Project and Common Areas.
MULTIPLE BUILDINGS If the Premises are part of a group of buildings controlled by Lessor, Lessee agrees that it will abide by, keep and observe all reasonable rules and regulations which Lessor may make from time to time for the management, safety, care, and cleanliness of the grounds, the parking and unloading of vehicles and the preservation of good order, as well as for the convenience of other occupants or tenants of such other buildings and their invitees, and that Lessee will pay its fair share of common expenses incurred in connection therewith.
Alterations to Premises Tenant shall make no structural or interior alterations to the Premises. If Tenant requests such alterations and such alterations are structural in nature, then Tenant shall provide Landlord with a complete set of construction drawings. If Landlord consents to the alterations, then the Landlord shall determine the actual cost of the work to be done. Tenant may then either agree to pay Landlord to have the work done or withdraw its request for alterations; provided, however, that at Tenant’s request, Landlord shall not unreasonably withhold its consent to allowing Tenant and/or Tenant’s contractors to perform such work. All such alterations are subject to the prior written approval of Landlord, which approval shall not be unreasonably withheld, conditioned or delayed. Subject to the terms of this paragraph, and notwithstanding any provision of this Lease to the contrary, Landlord agrees to allow Tenant to construct (i) a data center within the Premises and to install equipment (which may include generator, condensers, UPS, etc.) in the Building and around the land surrounding the Building necessary to facilitate the operation of Tenant’s data center, and (ii) an opening in the curtain wall of Floor 1 of Building C, to install two (2) four foot doors within such opening, to improve the outside area for delivery access and to install other improvements (which may include a large dumpster) to the Building and the land surrounding the Building necessary to facilitate the operation of Tenant’s Fulfillment Center. All such alterations shall be performed by Tenant’s contractors (which shall be subject to Landlord’s approval, not to be unreasonably withheld), at Tenant’s sole cost and expense. Notwithstanding the above paragraph, Tenant shall have the right to make nonstructural and nonsystems related alterations (“Tenant Alterations”) up to a value of $15,000.00 per occurrence (not to exceed $60,000 during any 12-month period) without Landlord’s prior written consent (which consent shall not be unreasonably withheld), provided Tenant shall provide notice to Landlord of its intent to make the Tenant Alterations. Such notice shall include a copy of plans and specifications (if such alterations are of a character that would reasonably require plans and specifications) and copies of all permits, if required by the appropriate municipality, and any contracts for such Tenant Alterations. All Tenant Alterations shall be performed by contractors approved by Landlord which approval shall not be unreasonably withheld, and in accordance with all applicable laws and the rules and regulations described in Section 12b.
Expansion Premises In addition to the Original Premises, commencing on the Expansion Premises Commencement Date (as defined below), Landlord leases to Tenant, and Tenant leases from Landlord, the Expansion Premises.
Building Signage 1. Tenant shall be entitled to the greater of: (i) one (1) exclusive tenant identification sign per Building that does not to exceed 75 square feet, or (ii) Tenant’s pro rata share of the maximum exterior signage permitted by applicable Laws that is allocated to the parcel on which the Building is located (the “Building Signage”). The exact location of the Building Signage shall be determined by Tenant, subject to all applicable Laws, any reasonable signage guidelines for the Project established by Landlord that are provided to Tenant prior to installation of the Building Signage, and Landlord’s prior written approval, which approval shall not be unreasonably withheld, conditioned or delayed. Such right to the Building Signage is personal to Tenant and is subject to the following terms and conditions: (a) Tenant shall submit plans and drawings for the Building Signage to Landlord and to the City of San Mateo and to any other public authorities having jurisdiction and shall obtain written approval from Landlord (not to be unreasonably withheld, conditioned or delayed) and, if applicable, each such jurisdiction prior to installation, and shall comply with all applicable Laws; (b) Tenant shall, at Tenant’s sole cost and expense, design, construct and install the Building Signage; (c) the size, color and design of the Building Signage shall be subject to Landlord’s prior written approval; and (d) Tenant shall maintain the Building Signage in good condition and repair, and all costs of maintenance and repair shall be borne by Tenant. Maintenance shall include, without limitation, cleaning and, if the Building Signage is illuminated, relamping at reasonable intervals. Tenant shall be responsible for any electrical energy used in connection with the Building Signage. Notwithstanding the foregoing, Tenant shall not be liable for any fee in connection with Tenant’s right to display the Building Signage in accordance with this Lease. At Landlord’s option, Tenant’s right to the Building Signage may be revoked and terminated upon occurrence of any of the following events: (i) Tenant shall be in default under this Lease beyond any applicable notice and cure periods; (ii) Tenant leases or occupies less than 75% of the Premises, or (iii) this Lease shall terminate or otherwise no longer be in effect.
2. Upon the expiration or earlier termination of this Lease or at such other time that Tenant’s signage rights are terminated pursuant to the terms hereof, if Tenant fails to remove the Building Signage and repair the Building in accordance with the terms of this Lease, Landlord shall cause the Building Signage to be removed from the Building and the Building to be repaired and restored to the condition which existed prior to the installation of the Building Signage (including, if necessary, the replacement of any precast concrete panels), all at the sole cost and expense of Tenant and otherwise in accordance with this Lease, without further notice from Landlord notwithstanding anything to the contrary contained in this Lease. Tenant shall pay all costs and expenses for such removal and restoration within fifteen (15) business days following delivery of an invoice therefor accompanied by reasonable supporting documentation. The rights provided in this Section 36.A shall be non-transferable (except with respect to a Permitted Transferee) unless otherwise agreed by Landlord in writing in its sole discretion.
Common Areas - Changes Lessor shall have the right, in Lessor's sole discretion, from time to time:
(a) To make changes to the Common Areas, including, without limitation, changes in the location, size, shape and number of driveways, entrances, parking spaces, parking areas, loading and unloading areas, ingress, egress, direction of traffic, landscaped areas, walkways and utility raceways;
(b) To close temporarily any of the Common Areas for maintenance purposes so long as reasonable access to the Premises remains available;
(c) To designate other land outside the boundaries of the Industrial Center to be a part of the Common Areas;
(d) To add additional buildings and improvements to the Common Areas;
(e) To use the Common Areas while engaged in making additional improvements, repairs or alterations to the Industrial Center, or any portion thereof; and
(f) To do and perform such other acts and make such other changes in, to or with respect to the Common Areas and Industrial Center as Lessor may, in the exercise of sound business judgment, deem to be appropriate.
Common Area Subject to the terms and conditions of this Lease and such rules and regulations as Landlord may from time to time reasonably prescribe, Tenant and Tenant’s employees, invitees and customers shall, in common with other occupants of the Parcel, and their respective employees, invitees and customers, and others entitled to the use thereof, have the non-exclusive right to use the access roads, parking areas and facilities provided and designated by Landlord for the general use and convenience of the occupants of the Parcel, which areas and facilities are referred to herein as “Common Area.” This right shall terminate upon the termination of this Lease. Landlord reserves the right from time to time to make changes in the shape, size, location, amount and extent of the Common Area; provided that no such changes shall prevent or materially diminish or adversely affect Tenant’s ability to have access to and use of the Premises or Tenant’s allocation of parking spaces. Landlord further reserves the right to promulgate such rules and regulations relating to the use of the Common Area, and any part or parts thereof, as Landlord may reasonably deem appropriate for the best interest of the occupants of the Building. The rules and regulations shall be binding upon Tenant upon delivery of a copy of them to Tenant, and Tenant shall abide by them and cooperate in their observance. Such rules and regulations may be reasonably amended by Landlord from time to time, with advance notice, and all amendments shall be effective upon delivery of a copy of them to Tenant. Tenant shall have the exclusive use of Tenant’s Pro Rata Share of the parking spaces in the Common Area on a “first-come, first served” basis at no cost to Tenant during the Term or any extension or renewal of the Term. Tenant shall not at any time park or permit the parking of Tenant’s trucks or other vehicles, or the trucks or other vehicles of others, adjacent to loading areas so as to interfere in any way with the use of such areas, nor shall Tenant at any time park or permit the parking of Tenant’s vehicles or trucks, or the vehicles or trucks of Tenant’s suppliers or others, in any portion of the Common Area not designated by Landlord for such use by Tenant. Tenant shall not abandon any inoperative vehicles or equipment on any portion of the Common Area. Tenant shall make no alterations, improvements or additions to the Common Area without prior written approval of Landlord. Landlord shall at all times operate, manage, insure, maintain and repair the Common Area in good order, condition and repair. The manner in which the Common Area shall be maintained and the expenditures for such maintenance shall be at the unfettered discretion of Landlord. Except as excluded herein or in Addendum One, the cost of such repair, maintenance, operation, insurance and management, including without limitation, maintenance and repair of landscaping, irrigation systems, paving, sidewalks, fences, and lighting, shall be a Common Area Charge and Tenant shall pay to Landlord Tenant’s Pro Rata Share of such costs as provided in Paragraph 12 below.
Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).
Premises Parking and Common Areas 2.1 Letting Lessor hereby leases to Lessee, and Lessee hereby leases from Lessor, the Premises, for the term, at the rental, and upon all of the terms covenants and conditions set forth in this Lease. Unless otherwise provided herein, any statement of square footage set forth in this Lease, or that may have been used in calculating rental and/or Common Area Operating Expenses, is an approximation which Lessor and Lessee agree is reasonable and the rental and Lessee's Share (as defined in Paragraph 1.6(b)) based thereon is not subject to revision whether or not the actual square footage is more or less.
