Compliance Schedule. A. Each of the Respondents shall comply with the requirements and reporting deadlines set forth in this Order on Consent and, according to the designation of responsible parties in the Compliance Schedule in Appendix B, once approved, the construction project milestones contained in such Appendix. The Compliance Schedule shall set forth the deadlines and milestones with which designated Respondents must comply in implementing the LTCP. The Compliance Schedule shall consist of, and the designated Respondents shall comply with, the final compliance schedule contained in an approved LTCP which compliance schedule shall include design, construction, post-construction monitoring, and operation deadlines and milestones and shall be appended hereto and incorporated herein as the Compliance Schedule in Appendix B to this Order on Consent. The Compliance Schedule may be developed with the expectation that the Department’s review of Completed Plans and Specifications would occur within sixty (60) days.
1. Respondents may revise the designations of responsible parties in the Compliance Schedule in Appendix B at their discretion and without modification of this Order on Consent on the condition that (1) the revised designation identifies one of Respondents; (2) every project listed in Appendix B shall have one or more designated responsible parties at all times during the term of this Order on Consent; (3) no revised designation shall become effective until notice of the same is provided to the Department under Article XIII (Communications) of this Order on Consent along with a certification by the Respondents to this Order on Consent that the revised designation has the consent of all Respondents to this Order on Consent and is in compliance with the applicable inter-municipal agreement(s) in effect between the parties concerning this LTCP; (4) such revised designation is accepted by the Department, which written acceptance shall not be unreasonably withheld, and a written denial, if any, will indicate the rationale therefore; (5) no such revised designation purports to change or has the effect of changing any deadline or milestone in the LTCP Compliance Schedule, once approved, or Appendix B hereto; and (6) within ten days of the Department’s written acceptance of the revised designation of responsible parties, a revised LTCP Compliance Schedule and Appendix B to this Order on Consent shall be prepared to conform to the revised designation of responsible parties and...
Compliance Schedule. If additional pretreatment and/or O&M will be required to meet the pretreatment standards, the shortest schedule by which the user will provide such additional treatment. The completion date in this schedule shall not be later than the compliance date established for the applicable pretreatment standard.
Compliance Schedule. The state agrees to maintain procedures to receive, evaluate, retain and investigate all notices and reports that are required by permit compliance schedules and program regulations. These procedures shall also include the necessary elements to investigate the failure of persons required to submit such notices and reports. The state shall initiate appropriate compliance actions when required information is not received or when the reports are not submitted.
Compliance Schedule. Upon determination that a food service establishment is noncompliant with the terms and conditions specified in its permit or any provision of these regulations or needs to construct and/or acquire and install a FOG interceptor, the FOG control program manager may also issue and require the food service establishment to abide by a compliance schedule. The issuance of a compliance schedule may contain terms and conditions including, but not limited to, requirements for installation of a FOG interceptor and facilities, submittal of drawings or reports, audit of waste hauling records, best management and waste minimization practices, payment of fees, or other provisions to ensure compliance with these regulations.
Compliance Schedule. The require- ments of paragraph (a) of this section are subject to the following compliance schedule:
(1) For purposes of paragraph (a)(1) of this section, each swap dealer and major swap participant entering into a swap transaction that is or involves a credit swap or interest rate swap with a counterparty that is a swap dealer or major swap participant shall execute a confirmation for the swap transaction as soon as technologically practicable, but in any event by:
(i) The end of the second business day following the day of execution for the period from the effective date of this section to February 28, 2014; and
(ii) The end of the first business day following the day of execution from and after March 1, 2014.
(2) For purposes of paragraph (a)(1) of this section, each swap dealer and major swap participant entering into a swap transaction that is or involves an equity swap, foreign exchange swap, or other commodity swap with a counterparty that is a swap dealer or major swap participant shall execute a confirmation for the swap transaction as soon as technologically practicable, but in any event by:
(i) The end of the third business day following the day of execution for the period from the effective date of this section to August 31, 2013;
(ii) The end of the second business day following the day of execution for the period from September 1, 2013 to August 31, 2014; and
(iii) The end of the first business day following the day of execution from and after September 1, 2014.
(3) For purposes of paragraph (a)(2) of this section, each swap dealer and major swap participant entering into a swap transaction that is or involves a credit swap or interest rate swap with a counterparty that is not a swap deal- er or a major swap participant shall send an acknowledgment of such swap transaction as soon as technologically practicable, but in any event by:
(i) The end of the second business day following the day of execution for the period from the effective date of this section to February 28, 2014; and
(ii) The end of the first business day following the day of execution from and after March 1, 2014.
(4) For purposes of paragraph (a)(2) of this section, each swap dealer and major swap participant entering into a swap transaction that is or involves an equity swap, foreign exchange swap, or other commodity swap with a counterparty that is not a swap dealer or a major swap participant shall send an acknowledgment of such swap transaction as soon as technologically ...
Compliance Schedule. Monitoring and Recordkeeping for an AO Compression-Ignited Engine Subject to Section 5.1 and Section 5.7 On and after June 1, 2006, the owner of an engine that is subject to Section 5.1 and Section 5.7 of Rule 4702 shall be in compliance with the requirements of Section 5.7, Section 6.2.1.1, and Section 6.2.1.2.
Compliance Schedule. Monitoring and Recordkeeping for an AO Spark- Ignited Engine Subject to Section 5.1 and Section 5.7 On and after June 1, 2006, the owner of an engine that is subject to Section 5.1 and Section 5.7 of Rule 4702 shall be in compliance with the requirements of Section 5.7.3 through Section 5.7.5, Section 6.2.1.1, and Section 6.2.1.2.
Compliance Schedule. Emission Limits for a Non-AO Spark-Ignited Engine The owner of a non-AO spark-ignited engine subject to the requirements of Rule 4702 shall not operate the engine unless the owner demonstrates and maintains the engine in compliance with the applicable requirements of Rule 4702 by the indicated dates below. Compliance Schedule 1 – Non-AO Spark-Ignited Engine Quantity of Non-AO Spark-Ignited Engines to be in Compliance at a Stationary Source Compliance Date
a. 25% or more of the total number of non-AO spark- ignited engines at a stationary source on June 1, 2005 6/1/05
b. 62.5% or more of the total number of non-AO spark- ignited engines at a stationary source on June 1, 2006 6/1/06
c. 100% of the total number of non-AO spark-ignited engines at a stationary source on June 1, 2007 6/1/07 For the purposes of Section 7.6, the total number of non-AO spark-ignited engines at a stationary source on a specified date includes those non-AO spark-ignited engines subject to Rule 4702 pursuant to Section 2.0 and excludes any engines exempt from Rule 4702 pursuant to Section 4.1 on the specified date.
Compliance Schedule. General for a Non-AO Spark-Ignited Engine
7.6.3.1 On and after January 1, 2006, unless otherwise specified, the owner of an engine that is subject to the requirements of Section
4.1 of Rule 4702 shall be in full compliance with Rule 4702.
7.6.3.2 Unless otherwise specified, the owner of an engine subject to the requirements of Rule 4702 shall be in full compliance with Rule 4702 by the applicable compliance date pursuant to Section 7.6.2.
7.6.3.3 The owner of an engine that is subject to the requirements of Rule 4701 shall no longer be subject to the requirements of Rule 4701 pursuant to the following requirements:
7.6.3.3.1 For an engine that is subject to the requirements of Section 4.1 of Rule 4702, the requirements of Rule 4701 shall not apply effective on and after January 1, 2006, or
7.6.3.3.2 For an engine that is subject to the requirements of Section 4.2, Section 4.3, or Section 5.1 of Rule 4702, the requirements of Rule 4701 shall not apply effective on the date that such engine is required to be in full compliance with Rule 4702.
Compliance Schedule. The measures described in this plan will be conducted over the next ten years according to the following schedule.
