CONTRACTOR’S RESPONSIBILITY FOR THE WORK Sample Clauses

CONTRACTOR’S RESPONSIBILITY FOR THE WORK. 15.1 CONTRACTOR shall accept full responsibility for the Work against all loss or damage of whatsoever nature sustained until final acceptance by CITY, and shall promptly repair any damage done from any cause whatsoever. 15.2 CONTRACTOR shall be responsible for all materials, equipment and supplies pertaining to the Project. In the event any such materials, equipment and supplies are lost, stolen, damaged or destroyed prior to final acceptance by CITY; CONTRACTOR shall replace it without cost to CITY. CONTRACTOR shall be responsible to protect all materials, equipment and supplies, keeping them free from deterioration, weathering, rusting or other action detrimental to the materials. 15.3 CITY reserves the right to award other contracts in connection with this Project. CONTRACTOR shall afford other persons or contractors reasonable opportunity for the introduction and storage of materials and the execution of Work under such separate contracts. CONTRACTOR shall properly connect and coordinate this Work with the Work of any other persons or contractors that might contract separately with CITY. 15.4 If any part of CONTRACTOR’s Work depends on proper execution or results upon the Work of any other persons, CONTRACTOR shall inspect and promptly report to CONSULTANT any defects in such Work that render it unsuitable for such proper execution and results. CONTRACTOR’s failure to so inspect and report shall constitute an acceptance of the other person’s Work as fit and proper for the reception of CONTRACTOR’s Work, except as to defects which may develop in other CONTRACTOR’S Work after the execution of CONTRACTOR’s Work. 15.5 CONTRACTOR shall conduct its operations and take all reasonable steps to coordinate the prosecution of the Work so as to create no interference or impact on any other contractor on the site. Should such interference or impact occur, and the CONTRACTOR did not take reasonable steps, the CONTRACTOR shall be liable to the affected contractor for the cost of such interference or impact. 15.6 To ensure the proper execution of subsequent Work, CONTRACTOR shall inspect the Work already in place and shall at once report to CONSULTANT any discrepancy between the executed Work and the requirements of the Contract Documents.
Sample 1See All (4)
AutoNDA by SimpleDocs
CONTRACTOR’S RESPONSIBILITY FOR THE WORK. The Contractor shall be responsible to the University for all Work performed under this Contract. For purposes of assessing responsibility to the Contractor by the University, all persons engaged in the Work shall be considered employees of the Contractor. The Contractor shall give its personal attention to the fulfillment of the Contract and keep all phases of the Work under its control.
Sample 1Sample 2Sample 3
CONTRACTOR’S RESPONSIBILITY FOR THE WORK. The Contractor shall be responsible and accountable for the accuracy, completeness, clarity, and adequacy of the work, and shall perform the work in a professional manner. The Contractor shall be solely responsible for all actions and/or omissions of its agents, employees, representatives and subcontractors.
Sample 1Sample 2
CONTRACTOR’S RESPONSIBILITY FOR THE WORK. Until Acceptance of the ADD:
Sample 1
CONTRACTOR’S RESPONSIBILITY FOR THE WORK. Until Acceptance, the Contractor shall protect the Work against all injury and damage and shall solely bear the risk of any injury or damage which may occur to the Work except for events or conditions constituting Force Majeure. In the event the Work is injured or damaged prior to Acceptance, the Contractor shall rebuild, repair, restore, or replace all Work that is injured or damaged prior to Acceptance, at no additional cost to the Authority. During periods that Work is suspended, the Contractor shall protect the Work performed from injury or damage. Contractor shall solely bear the risk of any injury or damage which may occur to the Work during any suspension period, regardless of the cause of such injury, damage, or suspension period.
Sample 1
CONTRACTOR’S RESPONSIBILITY FOR THE WORK. 7.1 Time is of the essence on this Contract. Contractor shall perform the Work promptly and efficiently and in accordance with the provisions set forth in Attachment A. Contractor shall provide all labor, materials, tools, equipment and incidentals that are necessary for proper performance of the Work, including items that may be inferred from the specifications or from prevailing custom or trade usage as being necessary to produce the intended results. 7.2 Unless the specifications require certain means or methods, Contractor shall be responsible for the means and methods used for the Services. 7.3 Materials provided by Contractor must be of good quality and will be subject to the warranties provided by ORS 72.3120, ORS 72.3130, ORS 72.3140 and ORS 72.3150. 7.4 Contractor shall provide and properly supervise qualified workers. Workers must have any licenses and certificates required by applicable laws. 7.5 Contractor shall not assign any interest in this Contract or enter into subcontracts for the Services without the prior written approval of the City.
Sample 1
CONTRACTOR’S RESPONSIBILITY FOR THE WORK. From the first day the Contractor begins work, or from the date Contract Time commences, whichever occurs first, until written final acceptance of the project by the Engineer, the Contractor shall have the charge and care thereof and shall take every precaution against injury or damage to any part thereof by the action of the elements or from any other cause, whether arising from the execution or from the non-execution of The Work. The Contractor shall rebuild, repair, restore, and make good all injuries or damages to any portion of The Work occasioned by any of the above causes before final acceptance and shall bear the expense thereof except that the Department may, in its discretion, reimburse the Contractor for the repair of damage to The Work due to unforeseeable causes beyond the control of and without the fault or negligence of the Contractor, including but not restricted to acts of God, of the public enemy or of governmental authorities. The Contractor’s responsibility for damages and injuries is defined in Subsection 104.05.A. In case of suspension of work from any cause whatsoever, the Contractor shall be responsible for the Project and shall take such precautions as may be necessary to prevent damage to the Project, provide for normal drainage and shall erect any necessary temporary structures, signs, or other facilities at his expense.
Sample 1
AutoNDA by SimpleDocs
CONTRACTOR’S RESPONSIBILITY FOR THE WORK. Until formal written acceptance by the City, the work shall be under the charge and care of the Contractor. The Contractor shall take every necessary precaution to prevent injury or damage to the work or any part thereof by the action of the elements or any other cause whatsoever, whether arising from the execution or non-execution of the work. The Contractor shall at his own expense rebuild, repair, restore, and make good all injuries or damage to any portion of the work occasioned by any of the forgoing causes before formal acceptance of the work by the City.
Sample 1
CONTRACTOR’S RESPONSIBILITY FOR THE WORK. CONTRACTOR shall accept full responsibility for the Work against all loss or damage of whatsoever nature sustained until final acceptance by CITY, and shall promptly repair any damage done from any cause whatsoever.
Sample 1

Related to CONTRACTOR’S RESPONSIBILITY FOR THE WORK

  • CONTRACTOR'S RESPONSIBILITY 1.1. The Basic Services to be performed by CONTRACTOR hereunder is the Citywide Landscape Maintenance. 1.2. The CONTRACTOR agrees to obtain and maintain throughout the period of this Agreement all such licenses as are required to do business in the State of Florida, the City of Naples, and in Xxxxxxx County, Florida, including, but not limited to, all licenses required by the respective state boards and other governmental agencies responsible for regulating and licensing the professional services to be provided and performed by the CONTRACTOR pursuant to this Agreement. 1.3. The CONTRACTOR agrees that, when the services to be provided hereunder relate to a professional service which, under Florida Statutes, requires a license, certificate of authorization or other form of legal entitlement to practice such services, it shall employ and/or retain only qualified personnel to provide such services. 1.4. CONTRACTOR agrees to employ and designate, in writing, within five (5) calendar days after receiving its Notice to Proceed, a qualified licensed professional to serve as the CONTRACTOR's project manager (hereinafter referred to as the "Project Manager"). The Project Manager shall be authorized and responsible to act on behalf of the CONTRACTOR with respect to directing, coordinating and administering all aspects of the services to be provided and performed under this Agreement. 1.5. The CONTRACTOR has represented to the OWNER that it has expertise in the type of professional services that will be required for the Project. The CONTRACTOR agrees that all services to be provided by CONTRACTOR pursuant to this Agreement shall be subject to the OWNER's review and approval and shall be in accordance with the generally accepted standards of professional practice in the State of Florida, as well as in accordance with all published laws, statutes, ordinances, codes, rules, regulations and requirements of any governmental agencies which regulate or have jurisdiction over the Project or the services to be provided and performed by CONTRACTOR hereunder. In the event of any conflicts in these requirements, the CONTRACTOR shall notify the OWNER of such conflict and utilize its best professional judgment to advise OWNER regarding resolution of the conflict. 1.6. CONTRACTOR agrees not to divulge, furnish or make available to any third person, firm or organization, without OWNER's prior written consent, or unless incident to the proper performance of the CONTRACTOR's obligations hereunder, or in the course of judicial or legislative proceedings where such information has been properly subpoenaed, any non-public information concerning the services to be rendered by CONTRACTOR hereunder, and CONTRACTOR shall require all of its employees, agents, subconsultants and subcontractors to comply with the provisions of this paragraph.

  • Contractor’s Responsibilities Unless stated specifically to the contrary in the tender with full supporting explanations, the contractor will be deemed to have concurred as a practical manufacturer with the design and layout of the works as being sufficient to ensure reliability and safety in operation, freedom from undue stresses and satisfactory performance in all other essentials as a working material.

  • Buyer’s Responsibility Buyer shall obtain and maintain all distribution, transmission and interconnection rights and agreements (including all Governmental Authority approvals) required to enable transmission and delivery of electric energy at and after the Delivery Point.

  • Seller’s Responsibility If the Seller determines that the Interface Problem is primarily attributable to the design of a Warranted Part, the Seller shall, if so requested by the Buyer and pursuant to the terms and conditions of Clause 12.1, correct the design of such Warranted Part to the extent of the Seller’s obligation as defined in Clause 12.1.

  • Engineers Responsibility The Engineer shall be responsible for the accuracy of its work and shall promptly make necessary revisions or corrections resulting from its errors, omissions, or negligent acts without compensation. The Engineer will not be relieved of the responsibility for subsequent correction of any such errors or omissions or for clarification of any ambiguities until after the construction phase of the project has been completed.

  • Customer’s Responsibility The policies in this document apply to the use of Data by Customers, Redistributors and their End Customers. Customers are responsible for compliance with this policy by all members of the Customer’s Group and by all persons to whom they distribute Data where authorised to do so. Turquoise recommends that Customers make this Schedule available to all Subscribers to their services having access to Data which is subject to Charges, reporting requirements or usage restrictions.

  • ARCHITECT’S RESPONSIBILITIES § 2.1 The Architect shall provide professional services as set forth in this Agreement. The Architect represents that it is properly licensed in the jurisdiction where the Project is located to provide the services required by this Agreement, or shall cause such services to be performed by appropriately licensed design professionals. § 2.2 The Architect shall perform its services consistent with the professional skill and care ordinarily provided by architects practicing in the same or similar locality under the same or similar circumstances. The Architect shall perform its services as expeditiously as is consistent with such professional skill and care and the orderly progress of the Project. § 2.3 The Architect shall identify a representative authorized to act on behalf of the Architect with respect to the Project. § 2.4 Except with the Owner’s knowledge and consent, the Architect shall not engage in any activity, or accept any employment, interest or contribution that would reasonably appear to compromise the Architect’s professional judgment with respect to this Project. § 2.5 The Architect shall maintain the following insurance until termination of this Agreement. If any of the requirements set forth below are in addition to the types and limits the Architect normally maintains, the Owner shall pay the Architect as set forth in Section 11.9. § 2.5.1 Commercial General Liability with policy limits of not less than « » ($ « » ) for each occurrence and « » ($ « » ) in the aggregate for bodily injury and property damage. § 2.5.2 Automobile Liability covering vehicles owned, and non-owned vehicles used, by the Architect with policy limits of not less than « » ($ « » ) per accident for bodily injury, death of any person, and property damage arising out of the ownership, maintenance and use of those motor vehicles, along with any other statutorily required automobile coverage. § 2.5.3 The Architect may achieve the required limits and coverage for Commercial General Liability and Automobile Liability through a combination of primary and excess or umbrella liability insurance, provided such primary and excess or umbrella liability insurance policies result in the same or greater coverage as the coverages

  • Supplier’s Responsibilities 14.1 The Supplier shall supply all the Goods and Related Services included in the Scope of Supply in accordance with GCC Clause 12, and the Delivery and Completion Schedule, as per GCC Clause 13.

  • Owner’s Responsibility Proper preventative maintenance of the exterior and interior of the vehicle is the responsibility of the owner. See the owner’s manual(s) for proper care instructions. Defects or damage as a result of improper care or maintenance are not covered by this warranty agreement.

  • Contractor Responsibility (a) The Contractor shall be responsible for the entire Performance under the Contract regardless of whether the Contractor itself performs. The Contractor shall be the sole point of contact concerning the management of the Contract, including Performance and payment issues. The Contractor is solely and completely responsible for adherence by the Contractor Parties to all applicable provisions of the Contract. (b) The Contractor shall exercise all reasonable care to avoid damage to the State's property or to property being made ready for the State's use, and to all property adjacent to any work site. The Contractor shall promptly report any damage, regardless of cause, to the State.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!