Quality control system (i) The Contractor shall establish a quality control mechanism to ensure compliance with the provisions of this Agreement (the “Quality Assurance Plan” or “QAP”).
(ii) The Contractor shall, within 30 (thirty) days of the Appointed Date, submit to the Authority’s Engineer its Quality Assurance Plan which shall include the following:
(a) organisation, duties and responsibilities, procedures, inspections and documentation;
(b) quality control mechanism including sampling and testing of Materials, test frequencies, standards, acceptance criteria, testing facilities, reporting, recording and interpretation of test results, approvals, check list for site activities, and proforma for testing and calibration in accordance with the Specifications for Road and Bridge Works issued by MORTH, relevant IRC specifications and Good Industry Practice; and
(c) internal quality audit system. The Authority’s Engineer shall convey its approval to the Contractor within a period of 21 (twenty-one) days of receipt of the QAP stating the modifications, if any, required, and the Contractor shall incorporate those in the QAP to the extent required for conforming with the provisions of this Clause 11.2.
(iii) The Contractor shall procure all documents, apparatus and instruments, fuel, consumables, water, electricity, labour, Materials, samples, and qualified personnel as are necessary for examining and testing the Project Assets and workmanship in accordance with the Quality Assurance Plan.
(iv) The cost of testing of Construction, Materials and workmanship under this Article 11 shall be borne by the Contractor.
Quality Control Program Engineer shall have a quality control program in place that ensures that all deliverable work is of high quality. Engineer shall submit a plan detailing its program to the Inspection Branch of the TxDOT Bridge Division for review and approval prior to beginning work. State may review or audit the programs.
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE
1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State.
1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent.
1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State.
1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress.
1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER.
1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period.
1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State.
1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work.
1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon.
1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval.
1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6.
1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover.
1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions.
1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment.
1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
Quality Control A. Controlled Affiliate agrees to use the Licensed Marks and Name only in connection with the licensed services and further agrees to be bound by the conditions regarding quality control shown in attached Exhibit A as they may be amended by BCBSA from time-to-time.
B. Controlled Affiliate agrees to comply with all applicable federal, state and local laws.
C. Controlled Affiliate agrees that it will provide on an annual basis (or more often if reasonably required by Plan or by BCBSA) a report or reports to Plan and BCBSA demonstrating Controlled Affiliate’s compliance with the requirements of this Agreement including but not limited to the quality control provisions of this paragraph and the attached Exhibit A.
D. Controlled Affiliate agrees that Plan and/or BCBSA may, from time-to-time, upon reasonable notice, review and inspect the manner and method of Controlled Affiliate’s rendering of service and use of the Licensed Marks and Name.
E. As used herein, a Controlled Affiliate is defined as an entity organized and operated in such a manner, that it meets the following requirements:
(1) A Plan or Plans authorized to use the Licensed Marks in the Service Area of the Controlled Affiliate pursuant to separate License Agreement(s) with BCBSA, other than such Controlled Affiliate’s License Agreement(s), (the “Controlling Plan(s)”), must have the legal authority directly or indirectly through wholly-owned subsidiaries to select members of the Controlled Affiliate’s governing body having not less than 50% voting control thereof and to:
(a) prevent any change in the articles of incorporation, bylaws or other establishing or governing documents of the Controlled Affiliate with which the Controlling Plan(s) do(es) not concur;
(b) exercise control over the policy and operations of the Controlled Affiliate at least equal to that exercised by persons or entities (jointly or individually) other than the Controlling Plan(s); and Notwithstanding anything to the contrary in (a) through (b) hereof, the Controlled Affiliate’s establishing or governing documents must also require written approval by the Controlling Plan(s) before the Controlled Affiliate can:
(i) change its legal and/or trade names;
(ii) change the geographic area in which it operates;
(iii) change any of the type(s) of businesses in which it engages;
(iv) create, or become liable for by way of guarantee, any indebtedness, other than indebtedness arising in the ordinary course of business;
(v) sell any assets, except for sales in the ordinary course of business or sales of equipment no longer useful or being replaced;
(vi) make any loans or advances except in the ordinary course of business;
(vii) enter into any arrangement or agreement with any party directly or indirectly affiliated with any of the owners or persons or entities with the authority to select or appoint members or board members of the Controlled Affiliate, other than the Plan or Plans (excluding owners of stock holdings of under 5% in a publicly traded Controlled Affiliate);
(viii) conduct any business other than under the Licensed Marks and Name;
(ix) take any action that any Controlling Plan or BCBSA reasonably believes will adversely affect the Licensed Marks and Name. In addition, a Plan or Plans directly or indirectly through wholly owned subsidiaries shall own at least 50% of any for-profit Controlled Affiliate.
(2) A Plan or Plans authorized to use the Licensed Marks in the Service Area of the Controlled Affiliate pursuant to separate License Agreement(s) with BCBSA, other than such Controlled Affiliate’s License Agreement(s), (the “Controlling Plan(s)”), have the legal authority directly or indirectly through wholly-owned subsidiaries to select members of the Controlled Affiliate’s governing body having more than 50% voting control thereof and to:
(a) prevent any change in the articles of incorporation, bylaws or other establishing or governing documents of the Controlled Affiliate with which the Controlling Plan(s) do(es) not concur;
(b) exercise control over the policy and operations of the Controlled Affiliate. In addition, a Plan or Plans directly or indirectly through wholly-owned subsidiaries shall own more than 50% of any for-profit Controlled Affiliate.
Use; Quality Control a. Neither party may alter the other party’s trademarks from the form provided and must comply with removal requests as to specific uses of its trademarks or logos.
b. Each party agrees to use, and to cause its Permitted Sublicensees to use, the other party’s trademarks only in good faith and in a dignified manner consistent with such party’s use of the trademarks. Upon written notice to the breaching party, the breaching party has 30 days of the date of the written notice to cure the breach or the license will be terminated.
Quality Assurance/Quality Control Contractor shall establish and maintain a quality assurance/quality control program which shall include procedures for continuous control of all construction and comprehensive inspection and testing of all items of Work, including any Work performed by Subcontractors, so as to ensure complete conformance to the Contract with respect to materials, workmanship, construction, finish, functional performance, and identification. The program established by Contractor shall comply with any quality assurance/quality control requirements incorporated in the Contract.
Servicing and Maintenance Standards On behalf of the Issuer, the Servicer shall (a) manage, service, administer, bill, collect and calculate Securitized Utility Tariff Charges in accordance with the Securitization Law and post collections in respect of the Securitized Utility Tariff Property with reasonable care and in material compliance with applicable Requirements of Law, including all applicable MPSC Regulations and guidelines, using the same degree of care and diligence that the Servicer exercises with respect to similar assets for its own account and, if applicable, for others; (b) follow customary standards, policies and procedures for the industry in Missouri in performing its duties as Servicer; (c) use all reasonable efforts, consistent with its customary servicing procedures, to enforce, and maintain rights in respect of, the Securitized Utility Tariff Property and to bill and collect the Securitized Utility Tariff Charges; (d) comply with all Requirements of Law, including all applicable MPSC Regulations and guidelines, applicable to and binding on it relating to the Securitized Utility Tariff Property; (e) file all MPSC notices described in the Securitization Law and file and maintain the effectiveness of UCC financing statements with respect to the property transferred under the Sale Agreement, and (f) take such other action on behalf of the Issuer to ensure that the Lien of the Indenture Trustee on the Securitized Utility Tariff Collateral remains perfected and of first priority. The Servicer shall follow such customary and usual practices and procedures as it shall deem necessary or advisable in its servicing of all or any portion of the Securitized Utility Tariff Property, which, in the Servicer’s judgment, may include the taking of legal action, at the Issuer’s expense but subject to the priority of payments set forth in Section 8.02(e) of the Indenture.
Trunk Group Architecture and Traffic Routing 5.2.1 The Parties shall jointly establish Access Toll Connecting Trunks between CLEC and CBT by which they will jointly provide Tandem-transported Switched Exchange Access Services to Interexchange Carriers to enable such Interexchange Carriers to originate and terminate traffic from and to CLEC's Customers.
5.2.2 Access Toll Connecting Trunks shall be used solely for the transmission and routing of Exchange Access and non-translated Toll Free traffic (e.g., 800/888) to allow CLEC’s Customers to connect to or be connected to the interexchange trunks of any Interexchange Carrier that is connected to the CBT access Tandem.
5.2.3 The Access Toll Connecting Trunks shall be one-way or two-way trunks, as mutually agreed, connecting an End Office Switch that CLEC utilizes to provide Telephone Exchange Service and Switched Exchange Access Service in the given LATA to an access Tandem Switch CBT utilizes to provide Exchange Access in the LATA.
Selection of Subcontractors, Procurement of Materials and Leasing of Equipment The contractor shall not discriminate on the grounds of race, color, religion, sex, national origin, age or disability in the selection and retention of subcontractors, including procurement of materials and leases of equipment. The contractor shall take all necessary and reasonable steps to ensure nondiscrimination in the administration of this contract.
a. The contractor shall notify all potential subcontractors and suppliers and lessors of their EEO obligations under this contract.
b. The contractor will use good faith efforts to ensure subcontractor compliance with their EEO obligations.
Maintenance of the Primary Insurance Policies; Collections Thereunder (a) The Master Servicer shall not take, or permit any Subservicer to take, any action which would result in non-coverage under any applicable Primary Insurance Policy of any loss which, but for the actions of the Master Servicer or Subservicer, would have been covered thereunder. To the extent coverage is available, the Master Servicer shall keep or cause to be kept in full force and effect each such Primary Insurance Policy until the principal balance of the related Mortgage Loan secured by a Mortgaged Property is reduced to 80% or less of the Appraised Value in the case of such a Mortgage Loan having a Loan-to-Value Ratio at origination in excess of 80%, provided that such Primary Insurance Policy was in place as of the Cut-off Date and the Company had knowledge of such Primary Insurance Policy. The Master Servicer shall be entitled to cancel or permit the discontinuation of any Primary Insurance Policy as to any Mortgage Loan, if the Stated Principal Balance of the Mortgage Loan is reduced below an amount equal to 80% of the appraised value of the related Mortgaged Property as determined in any appraisal thereof after the Closing Date, or if the Loan-to-Value Ratio is reduced below 80% as a result of principal payments on the Mortgage Loan after the Closing Date. In the event that the Company gains knowledge that as of the Closing Date, a Mortgage Loan had a Loan-to-Value Ratio at origination in excess of 80% and is not the subject of a Primary Insurance Policy (and was not included in any exception to the representation in Section 2.03(b)(iv)) and that such Mortgage Loan has a current Loan-to-Value Ratio in excess of 80% then the Master Servicer shall use its reasonable efforts to obtain and maintain a Primary Insurance Policy to the extent that such a policy is obtainable at a reasonable price. The Master Servicer shall not cancel or refuse to renew any such Primary Insurance Policy applicable to a Nonsubserviced Mortgage Loan, or consent to any Subservicer canceling or refusing to renew any such Primary Insurance Policy applicable to a Mortgage Loan subserviced by it, that is in effect at the date of the initial issuance of the Certificates and is required to be kept in force hereunder unless the replacement Primary Insurance Policy for such canceled or non-renewed policy is maintained with an insurer whose claims-paying ability is acceptable to each Rating Agency for mortgage pass-through certificates having a rating equal to or better than the lower of the then-current rating or the rating assigned to the Certificates as of the Closing Date by such Rating Agency.
(b) In connection with its activities as administrator and servicer of the Mortgage Loans, the Master Servicer agrees to present or to cause the related Subservicer to present, on behalf of the Master Servicer, the Subservicer, if any, the Trustee and Certificateholders, claims to the related Insurer under any Primary Insurance Policies, in a timely manner in accordance with such policies, and, in this regard, to take or cause to be taken such reasonable action as shall be necessary to permit recovery under any Primary Insurance Policies respecting defaulted Mortgage Loans. Pursuant to Section 3.07, any Insurance Proceeds collected by or remitted to the Master Servicer under any Primary Insurance Policies shall be deposited in the Custodial Account, subject to withdrawal pursuant to Section 3.10.
