SAVINGS/FORCE MAJEURE A Force Majeure occurrence is an event or effect that cannot be reasonably anticipated or controlled and is not due to the negligence or willful misconduct of the affected party. Force Majeure includes, but is not limited to, acts of God, acts of war, acts of public enemies, terrorism, strikes, fires, explosions, actions of the elements, floods, or other similar causes beyond the control of the Contractor or the Commissioner in the performance of the Contract where non- performance, by exercise of reasonable diligence, cannot be prevented. The affected party shall provide the other party with written notice of any Force Majeure occurrence as soon as the delay is known and provide the other party with a written contingency plan to address the Force Majeure occurrence, including, but not limited to, specificity on quantities of materials, tooling, people, and other resources that will need to be redirected to another facility and the process of redirecting them. Furthermore, the affected party shall use its commercially reasonable efforts to resume proper performance within an appropriate period of time. Notwithstanding the foregoing, if the Force Majeure condition continues beyond thirty (30) days, the Parties shall jointly decide on an appropriate course of action that will permit fulfillment of the Parties’ objectives hereunder. The Contractor agrees that in the event of a delay or failure of performance by the Contractor, under the Contract due to a Force Majeure occurrence: a. The Commissioner may purchase from other sources (without recourse to and by the Contractor for the costs and expenses thereof) to replace all or part of the Products which are the subject of the delay, which purchases may be deducted from the Contract quantities without penalty or liability to the State, or b. The Contractor will make commercially reasonable efforts to provide Authorized Users with access to Products first in order to fulfill orders placed before the Force Majeure event occurred. The Commissioner agrees that Authorized Users shall accept allocated performance or deliveries during the occurrence of the Force Majeure event. Neither the Contractor nor the Commissioner shall be liable to the other for any delay in or failure of performance under the Contract due to a Force Majeure occurrence. Any such delay in or failure of performance shall not constitute default or give rise to any liability for damages. The existence of such causes of such delay or failure shall extend the period for performance to such extent as determined by the Contractor and the Commissioner to be necessary to enable complete performance by the Contractor if reasonable diligence is exercised after the cause of delay or failure has been removed. Notwithstanding the above, at the discretion of the Commissioner where the delay or failure will significantly impair the value of the Contract to the State or to Authorized Users, the Commissioner may terminate the Contract or the portion thereof which is subject to delays, and thereby discharge any unexecuted portion of the Contract or the relative part thereof. In addition, the Commissioner reserves the right, in his/her sole discretion, to make an equitable adjustment in the Contract terms and/or pricing should extreme and unforeseen volatility in the marketplace affect pricing or the availability of supply. "Extreme and unforeseen volatility in the marketplace" is defined as market circumstances which meet the following criteria: (i) the volatility is due to causes outside the control of Contractor; (ii) the volatility affects the marketplace or industry, not just the particular Contract source of supply; (iii) the effect on pricing or availability of supply is substantial; and (iv) the volatility so affects Contractor's performance that continued performance of the Contract would result in a substantial loss. Failure of the Contractor to agree to any adjustment shall be a dispute under the Disputes clause; provided however, that nothing in this clause shall excuse the Contractor from performing in accordance with the Contract as changed.
FLORIDA CONVICTED/SUSPENDED/DISCRIMINATORY COMPLAINTS By submission of an offer, the respondent affirms that it is not currently listed in the Florida Department of Management Services Convicted/Suspended/Discriminatory Complaint Vendor List.
Reasonable Accommodation for Applicants / Employees with Disabilities The contractor must be familiar
MOTION FOR FINAL APPROVAL Not later than 16 court days before the calendared Final Approval Hearing, Plaintiff will file in Court, a motion for final approval of the Settlement that includes a request for approval of the PAGA settlement under Labor Code section 2699, subd. (l), a Proposed Final Approval Order and a proposed Judgment (collectively “Motion for Final Approval”). Plaintiff shall provide drafts of these documents to Defense Counsel not later than seven days prior to filing the Motion for Final Approval. Class Counsel and Defense Counsel will expeditiously meet and confer in person or by telephone, and in good faith, to resolve any disagreements concerning the Motion for Final Approval.
Orally Administered Anticancer Medication In accordance with RIGL § 27-20-67, prescription drug coverage for orally administered anticancer medications is provided at a level no less favorable than coverage for intravenously administered or injected cancer medications covered under your medical benefit.
Submitting Loop Makeup Service Inquiries 2.6.2.1 Comcast Phone may obtain LMU information by submitting a mechanized LMU query or a Manual LMUSI. Mechanized LMUs should be submitted through BellSouth's OSS interfaces. After obtaining the Loop information from the mechanized LMU process, if Comcast Phone needs further Loop information in order to determine Loop service capability, Comcast Phone may initiate a separate Manual Service Inquiry for a separate nonrecurring charge as set forth in Exhibit A of this Attachment. 2.6.2.2 Manual LMUSIs shall be submitted according to the guidelines in the LMU CLEC Information Package, incorporated herein by reference, as it may be amended from time to time, which can be found at the following BellSouth website: xxxx://xxxxxxxxxxxxxxx.xxxxxxxxx.xxx/guides/html/unes.html . The service interval for the return of a Manual LMUSI is three (3) business days. Manual LMUSIs are not subject to expedite requests. This service interval is distinct from the interval applied to the subsequent service order.
Retainage for Unacceptable Corrective Action Plan or Plan Failure If the corrective action plan is unacceptable to the Department or Customer, or implementation of the plan fails to remedy the performance deficiencies, the Department or Customer will retain ten percent (10%) of the total invoice amount. The retainage will be withheld until the Contractor resolves the performance deficiencies. If the performance deficiencies are resolved, the Contractor may invoice the Department or Customer for the retained amount. If the Contractor fails to resolve the performance deficiencies, the retained amount will be forfeited to compensate the Department or Customer for the performance deficiencies.
Termination for Force Majeure 15.5.1. The License Agreement may be terminated for Force Majeure Reasons as specified in Article -14.
Normal Commercial Relations Anything contained in this Indenture to the contrary notwithstanding, the Loan Trustee, any Noteholder or any other party to any of the Operative Documents or the Pass Through Documents or any of their affiliates may conduct any banking or other financial transactions, and have banking or other commercial relationships, with the Company, fully to the same extent as if this Indenture were not in effect, including without limitation the making of loans or other extensions of credit to the Company for any purpose whatsoever, whether related to any of the transactions contemplated hereby or otherwise.
Third Party Administrators for Defined Contribution Plans 2.1 The Fund may decide to make available to certain of its customers, a qualified plan program (the “Program”) pursuant to which the customers (“Employers”) may adopt certain plans of deferred compensation (“Plan or Plans”) for the benefit of the individual Plan participant (the “Plan Participant”), such Plan(s) being qualified under Section 401(a) of the Code and administered by TPAs which may be plan administrators as defined in the Employee Retirement Income Security Act of 1974, as amended. 2.2 In accordance with the procedures established in Schedule 2.1 entitled “Third Party Administrator Procedures,” as may be amended by the Transfer Agent and the Fund from time to time (“Schedule 2.1”), the Transfer Agent shall: (a) Treat Shareholder accounts established by the Plans in the name of the Trustees, Plans or TPAs, as the case may be, as omnibus accounts; (b) Maintain omnibus accounts on its records in the name of the TPA or its designee as the Trustee for the benefit of the Plan; and (c) Perform all Services under Section 1 as transfer agent of the Funds and not as a record-keeper for the Plans. 2.3 Transactions identified under Sections 1 and 2 of this Agreement shall be deemed exception services (“Exception Services”) when such transactions: (a) Require the Transfer Agent to use methods and procedures other than those usually employed by the Transfer Agent to perform transfer agency and recordkeeping services; (b) Involve the provision of information to the Transfer Agent after the commencement of the nightly processing cycle of the TA2000 System; or (c) Require more manual intervention by the Transfer Agent, either in the entry of data or in the modification or amendment of reports generated by the TA2000 System, than is normally required.