Landlord's Cost Sample Clauses

Landlord's Cost. The charges of any architect or engineer of Landlord employed to pass upon any plans and specifications and to supervise and approve any construction or for any services rendered by the architect or engineer to Landlord as contemplated by any of the provision of this Lease, will be paid to tenant as a cost of the repair or rebuilding. The fees of such architect or engineer will be those customarily paid for comparable services.
Sample 1
AutoNDA by SimpleDocs
Landlord's Cost. Tenant shall not be responsible for certain income taxes expressly excluded from Tenant’s responsibility in Section 5.2, the cost of construction of new building areas, the cost of initial improvements to premises leased to tenants of the Shopping Center other than Tenant, leasing commissions, ground rent and debt service payable under any Mortgage (as hereinafter defined).
Sample 1
Landlord's Cost. Landlord shall be responsible for all costs, expenses and delays associated with Landlord’s Work including change order requests to the extent that they are (i) initiated by Landlord, (ii) mandated by applicable Governmental Authorities, (iii) required to bring the Conceptual Engineering Package and/or the Site Work Plans into conformance with one another, with applicable governmental requirements, the Utility Work and/or the Site Work, or (iv) required to correct deficiencies or inaccuracies within such plans.
Sample 1
Landlord's Cost. Any balance of the award remaining after the foregoing applications will be allocated to the Landlord.
Sample 1
Landlord's Cost. Except as otherwise specifically provided in Article 3, Landlord will be liable and obligated to pay for all costs of preparation of the Process Facility Plans and all costs related to the design, engineering, procurement, installation, construction, interconnection, testing and Installation Qualification of the Facility, including, but not limited to, all labor and materials. All such costs will be included in the Project Cost as defined in Section 5 of the Lease; provided, however, that certain Qualified Expenses (as defined in the Escrow Agreement) relating to the acquisition of the Land, and the design, engineering and construction of the Facility, will be paid out of the Escrow Funds (as defined in the Escrow Agreement). Landlord will, from and after the full execution of this Lease and until the delivery of landlord's final written certification pursuant to Section 3.3 of the Lease, deliver to Tenant on a monthly basis a written certification of the Project Cost to date, specified by line item, consistent with the terms and requirements of the Lease and this Addendum. Additionally, from and after the full execution of the Lease, Landlord will provide to Tenant and Tenant's Consultant, during normal business hours, full and complete access to all books, records and accounts of Landlord to verify the amount of the Project Cost.
Sample 1
Landlord's Cost. Except as otherwise specifically provided in this Addendum, Landlord will be liable and obligated to pay for all costs of preparation of the Base Building Plans and all costs of developing and constructing the Base Building, including, but not limited to, all permit costs, impact fees, architectural and engineering fees, and costs for labor and materials.
Sample 1
Landlord's Cost. Landlord shall construct the Premises in accordance with the Final Plans at its sole cost and expense. Provided there have been no increases in the cost to complete the Premises due to a Tenant Delay or Force Majeure Delay then Landlord shall complete the construction with cost not to exceed $___________ (the “Work Cost Estimate”). In the event the costs for completion of the Premises exceed the Work Cost Estimate, provided there have been no increases in the cost to complete the Premises due to a Tenant Delay or Force Majeure Delay, Landlord shall be responsible for such excess.
Sample 1
AutoNDA by SimpleDocs
Landlord's Cost. Except as otherwise specifically provided in Article III or in Section 5.2, Landlord will be liable and obligated to pay for all costs of preparation of the Base Building Plans, the Leasehold Improvement Plans, and all costs of developing and constructing the Base Building, including, but not limited to, all labor and materials. In addition, to the extent provided in Section 5.2 and except as otherwise specifically provided in Article III, Landlord will be obligated to fund the cost of developing and constructing the Leasehold Improvements, and for all costs of developing and constructing the Leasehold Improvements in excess of the established Leasehold Improvement Cost (unless such increase is a direct result of Tenant Delay or Tenant's Changes to the Leasehold Improvement Plans or the Leasehold Improvements Work as provided in Article III).
Sample 1

Related to Landlord's Cost

  • Landlord’s Costs Tenant shall, within thirty (30) days after receipt of an invoice from Landlord, pay the reasonable costs, expenses, and fees of any architect or engineer employed by Landlord to review any plans and specifications and to supervise and approve any construction, or for any services rendered by such architect or engineer to Landlord as contemplated by any of the provisions of this Agreement, or for any services performed by Landlord's attorneys in connection therewith; provided, however, that Landlord will consult with Tenant and notify Tenant of the estimated amount of such expenses.

  • Landlord’s Expenses In the event Tenant shall assign this Lease or sublet the Premises or request the consent of Landlord to any Transfer, then Tenant shall pay Landlord's reasonable costs and expenses incurred in connection therewith, including, but not limited to, attorneys', architects', accountants', engineers' or other consultants' fees.

  • Lessee's Improvements Since Lessor is the Insuring Party, Lessor shall not be required to insure Lessee-Owned Alterations and Utility Installations unless the item in question has become the property of Lessor under the terms of this Lease.

  • Tenant’s Costs Within 60 days after the Commencement Date, and within 60 days after the beginning of each calendar year, Landlord shall give Tenant a written estimate, for such calendar year, of Tenant’s share of the cost of utilities, if not separately metered, taxes and insurance provided by Landlord (“Tenant Costs”). Tenant shall pay such estimated amount to Landlord in equal monthly installments, in advance. Within 90 days after the end of each calendar year, Landlord shall furnish to Tenant a statement showing in reasonable detail the costs incurred by Landlord for the operation and maintenance of the Premises during such year (the “Annual Statement”), and Tenant shall pay to Landlord Tenant’s proportionate share of the cost incurred in excess of the payments made by Tenant within 10 days of receipt of such statement. In the event that the payments made by Tenant for the operation and maintenance of the Premises exceed Tenant’s share of the cost of same, such amount shall be credited by Landlord to the Rent or other charges next due and owing, provided that, if the Lease term has expired, Landlord shall accompany said statement with the amount due Tenant. Tenant shall have the right, by giving written notice thereof to Landlord within sixty (60) days after Tenant’s receipt of each Annual Statement, to contest all or any item comprising Tenant Costs and in connection therewith audit Landlord’s books and records relating to Tenant Cost covered by the Annual Statement. Landlord shall promptly provide Tenant with copies of all bills and records supporting the Tenant Costs or any particular item of Tenant Costs specified by Tenant in writing. If Tenant fails to deliver a notice of audit/contest to Landlord within the aforesaid sixty (60) day period, Tenant shall be deemed to have accepted the Annual Statement for the applicable calendar year.

  • Tenant Work Before commencing any repair or Alteration (“Tenant Work”), Tenant shall deliver to Landlord, and obtain Landlord’s approval of, (a) names of contractors, subcontractors, mechanics, laborers and materialmen; (b) evidence of contractors’ and subcontractors’ insurance; and (c) any required governmental permits. Tenant shall perform all Tenant Work (i) in a good and workmanlike manner using materials of a quality reasonably approved by Landlord; (ii) in compliance with any approved plans and specifications, all Laws, the National Electric Code, and Landlord’s construction rules and regulations; and (iii) in a manner that does not impair the Base Building. If, as a result of any Tenant Work, Landlord becomes required under Law to perform any inspection, give any notice, or cause such Tenant Work to be performed in any particular manner, Tenant shall comply with such requirement and promptly provide Landlord with reasonable documentation of such compliance. Landlord’s approval of Tenant’s plans and specifications shall not relieve Tenant from any obligation under this Section 7.3. In performing any Tenant Work, Tenant shall not use contractors, services, labor, materials or equipment that, in Landlord’s reasonable judgment, would disturb labor harmony with any workforce or trades engaged in performing other work or services at the Project.

  • Landlord’s Contribution Landlord shall contribute rent abatements up to the total amount of ONE HUNDRED FIFTY THOUSAND DOLLARS ($150,000.00) (“Landlord’s Contribution”) on account of the cost of refurbishing the Leased Premises including design and engineering costs. Landlord’s Contribution shall be available to Tenant only as follows: (i) Tenant shall submit to Landlord a written request to utilize a portion of Landlord’s Contribution as an abatement of one or more monthly installments of Base Rent (as hereinafter defined) (each a “Contribution Request”); (ii) each Contribution Request shall include evidence reasonably satisfactory to Landlord that Tenant has actually paid to contractors and other relevant professionals an amount at least equal to the amount sought in the Contribution Request in connection with construction, design and or other service and materials directly related to and necessary in connection with the Expansion Project (“Refit Expenses”); (iii) unless a Contribution Request is disputed by Landlord within ten (10) days from receipt by Landlord, Tenant shall be entitled to abatement of Base Rent monthly installment(s) first payable not less than thirty (30) days from submission of such Contribution Request to Landlord; (iv) in addition to the foregoing: (A) Tenant shall be limited to no more than three (3) contribution requests per year; (B) each Contribution Request shall be in an amount not less than the lesser of the remaining unused portion of Landlord’s Contribution and the Base Rent payable for one (1) month and shall specify how Tenant intends to apply the Base Rent abatements to upcoming monthly installment(s) of Base Rent; and (C) monthly abatements of Base Rent shall be applied to whole months and Tenant shall have no right to a partial abatement of monthly Base Rent other than with respect to the last Contribution Request.

  • Landlord’s Property All Alterations, improvements, fixtures, equipment and/or appurtenances which may be installed or placed in or about the Premises, from time to time, shall be at the sole cost of Tenant and shall be and become the property of Landlord; provided, however, Landlord may, by written notice to Tenant prior to the end of the Lease Term, or given following any earlier termination of this Lease, require Tenant, at Tenant’s expense, to remove any Alterations or improvements and to repair any damage to the Premises and Building caused by such removal and return the affected portion of the Premises to their condition existing prior to the installation of such Alterations or improvements or, at Landlord’s election, to a building standard tenant improved condition as determined by Landlord; provided; however, that notwithstanding the foregoing, upon request by Tenant at the time of Tenant’s request for Landlord’s consent to any Alteration or improvement, Landlord shall notify Tenant whether the applicable Alteration or improvement will be required to be removed pursuant to the terms of this Section 8.5. If Tenant fails to complete such removal and/or to repair any damage caused by the removal of any Alterations or improvements in the Premises and return the affected portion of the Premises to their condition existing prior to the installation of such Alterations or improvements or, if elected by Landlord, to a building standard tenant improved condition as determined by Landlord, prior to the expiration or earlier termination of this Lease, then Rent shall continue to accrue under this Lease in accordance with Article 16, below, after the end of the Lease Term until such work shall be completed, and Landlord shall have the right, but not the obligation, to perform such work and to charge the cost thereof to Tenant. Tenant hereby protects, defends, indemnifies and holds Landlord harmless from any liability, cost, obligation, expense or claim of lien, including but not limited to, court costs and reasonable attorneys’ fees, in any manner relating to the installation, placement, removal or financing of any such Alterations, improvements, fixtures and/or equipment in, on or about the Premises, which obligations of Tenant shall survive the expiration or earlier termination of this Lease.

  • Landlord’s Fees Whenever Tenant requests Landlord to take any action not required of it hereunder or give any consent required or permitted under this Lease, Tenant will reimburse Landlord for Landlord’s reasonable, out-of-pocket costs payable to third parties and incurred by Landlord in reviewing the proposed action or consent, including reasonable attorneys’, engineers’ or architects’ fees, within thirty (30) days after Landlord’s delivery to Tenant of a statement of such costs. Tenant will be obligated to make such reimbursement without regard to whether Landlord consents to any such proposed action.

  • Landlord Improvements (a) On the Commencement Date, Landlord will deliver the Leased Premises to Tenant in a broom clean condition, and, along with the lighting, electrical (excluding the UPS system and the diesel generator), mechanical and plumbing fixtures, plumbing systems, dock doors and HVAC servicing the Leased Premises, hot water, doors and plate-glass, will be delivered to Tenant in good condition and repair, as defined in Section 5.05 above. (b) After receipt of the Letter of Credit and any required building permit, Landlord will commence and diligently pursue to completion, the construction of the improvements to the Leased Premises (the “Landlord Improvements”), in accordance with plans and specifications as shown in Exhibit B, subject to approval by local regulatory authorities (the “Plans”), which Plans are made a part of this Lease by reference. Any changes or modifications to the Plans must be made and accepted by written change order or agreement signed by Landlord and Tenant and will constitute an amendment to this Lease. Any Landlord Improvements made by Landlord are the property of Landlord and must be surrendered to Landlord upon the termination of this Lease without credit to Tenant. Upon completion of any Landlord Improvements and issuance of a final certificate of occupancy (to be applied for by Landlord’s general contractor) and certification from Landlord’s general contractor certifying to Tenant that all Landlord Improvements have been completed in accordance with the Plans (the “General Contractor’s Certificate”), thereafter Landlord shall provide and Tenant shall acknowledge receipt and acceptance of “as-built plans” of all work done in accordance with this Section 6.01. (c) Landlord shall furnish an allowance of up to $172,800.00 (One hundred seventy-two thousand, eight hundred dollars) (“Landlord Improvement Allowance”) to be credited against the cost of the construction of the Landlord Improvements. If the actual cost of construction of the Landlord Improvements is less than the Landlord Improvement Allowance (“Allowance Overage”), Tenant shall have no right or claim to such difference; provided however, that if there is an Allowance Overage, Landlord, upon submission of supporting documentation by Tenant, will reimburse Tenant for any third party costs of low voltage wiring and laboratory benches for the Leased Premises, but such reimbursement shall not exceed the lesser of the Allowance Overage or 69,120.00 (Sixty-nine thousand, one hundred twenty & xx/100 dollars). If the actual cost of construction of the Landlord Improvements exceeds the Landlord Improvement Allowance, Tenant shall pay such excess cost to Landlord within ten (10) business days after receipt of supporting documentation and the General Contractor’s Certificate,. (d) Notwithstanding anything contained in Section 6.01 (c) above, within 30 days after the issuance of the General Contractor’s Certificate, Landlord will determine the sum of (i) the actual cost of the Landlord Improvements, plus (ii) if any, the actual costs submitted by Tenant towards the Contingent Allowance, and the product of the calculation shall be rounded to the next $1,000.00 (One Thousand Dollars). If the resultant amount is less than the Landlord Improvement Allowance, Landlord shall reduce the monthly Base Rent by $20.25 (“Base Rent Reduction Factor”) for each whole $1,000.00 (One Thousand Dollars) of such amount effective January 1, 2012. If it is determined that the monthly Base Rent is to be reduced and if Tenant has already paid Base Rent in a pre-reduction amount, Landlord shall give Tenant credit for any such excess payment, and reduction in monthly Base Rent shall be memorialized in an amendment to this Lease. In the event that the monthly Base Rent is reduced in accordance with this Section 6.01(d), there shall be no reduction in the Security Deposit Amount or in the requirements set forth for the Letter of Credit. The following example illustrates the intentions of the parties hereto as to computation of any reduction of the monthly Base Rent: Assumptions: 1. Actual cost of the Landlord Improvements: $100,000.00 2. Actual cost of qualifying costs for Contingent Allowance: $50,500.00 Total cost of Landlord Improvements and Contingent Allowance Costs: ($100,000.00 + $50,500.00) = $150,500.00 Determination of reduction in monthly Base Rent: Total Landlord Improvement Allowance $ 172,800.00 Less total cost of Landlord Improvements and contingent costs 150,500.00 $ 22300.00 Rounded to next $1,000.00 (One Thousand Dollars) $ 23,000.00 Divided by $1,000.00 (One Thousand Dollars) 1,000.00 Base Rent Reduction Factor 20.25 Reduction in monthly Base Rent $ 465.75 (e) In addition to the Landlord Improvements, Landlord, at Landlord’s sole cost and expense, shall have the following additional work performed on the Leased Premises prior to delivery of possession to Tenant, such work to be coordinated with the construction of the Landlord Improvements: (i) Replace all stained, damaged or missing ceiling tiles, (ii) Paint all walls in the Leased Premises, the color to be designated by Tenant, (iii) Replace all vinyl floor tiles in the open laboratory area as shown in Exhibit C, (iv) Shampoo all carpets in the office areas and hallways and (v) Any existing water supply or drainage pipes in the open lab area that are not initially utilized by Tenant shall be capped and made reasonably flush with the floor, but such capping shall allow for those pipes to be tapped by Tenant for future use. (vi) Re-caulk all perimeter flashing; install new pads under all gas line blocking; repair any loose or open curb or wall flashing; repack all pitch pans; repair any open joints on gravel guard; repair any loose scupper flashing; clean, prime and install EPDM peel and stick tape to all roof side tilt wall joints; clean all debris from around drains and entire roof; install Xxxxxx 97 asbestos free aluminum coating to entire roof surface (vii) Repair any existing alligator or pothole areas.

  • Tenant’s Alterations (a) Except as hereafter provided, Tenant shall make no alterations, additions or improvements (“Tenant Alterations”) to the Leased Space without the consent of Landlord, which consent shall not be unreasonably withheld, delayed or conditioned. At the time of Landlord’s consent, Landlord shall designate whether Tenant shall be required to remove the proposed Tenant Alteration upon termination of this Lease, and the absence of such designation in Landlord’s written consent shall be deemed Landlord’s agreement that Tenant shall not be obligated to remove Tenant Alterations upon the termination of this Lease. Landlord also may impose such reasonable conditions as part of its consent as Landlord deems appropriate, taking into consideration the nature of the proposed Tenant Alteration, including, without limitation, requiring Tenant to furnish Landlord with security for the payment of all costs to be incurred in connection with such work, insurance, and copies of the plans, specifications and permits necessary for such work. Nothing herein, however, shall be construed to obligate Tenant to construct any Tenant Alteration for which Landlord has given its consent. (b) Landlord’s consent shall not be required for Tenant Alterations which (i) do not adversely impact the structural integrity of the Building or the systems serving the Building or their operation, (ii) are not visible from the Building exterior and (iii) qualify under the following: (A) The Tenant Alteration is to be made to portions of the Leased Premises other than the laboratory areas and the cost thereof is $10,000 or less with respect to any Tenant Alteration project (or $20,000 or less in the aggregate with respect to Tenant Alteration projects undertaken over any twelve (12) consecutive month period); or (B) The Tenant Alteration is to be made to the laboratory areas of the Leased Premises and the cost thereof is $50,000 or less with respect to any Tenant Alteration project (or $100,000 or less in the aggregate with respect to Tenant Alteration projects undertaken over any twelve (12) consecutive month period). Tenant Alterations described in this subsection (b) for which Landlord’s consent is not required hereinafter are called “Permitted Tenant Alterations.” Notwithstanding the foregoing, painting or carpeting of the interior of the Leased Space and like cosmetic improvements shall not be deemed Tenant Alterations regardless of the cost thereof. Tenant shall not be obligated to remove Permitted Tenant Alterations upon the termination of this Lease unless an Event of Default has occurred which is then continuing and Landlord so requires such removal. (c) All Tenant Alterations shall be done at Tenant’s expense by contractors approved by Landlord, which approval shall not be unreasonably withheld, delayed or conditioned and shall be deemed given unless Landlord notifies Tenant of its objections within ten (10) business days after delivery of Tenant’s request for approval. With respect to Tenant Alterations other than the Permitted Tenant Alterations, no work shall be performed until the plans therefore have been approved by Landlord, which approval shall not be unreasonably withheld, delayed or conditioned and shall be deemed approved unless Landlord notifies Tenant of objections to the proposed plans within ten (10) business days after delivery to Landlord of a complete set of the plans therefor. In connection with the review of plans submitted by Tenant, Landlord shall be reimbursed by Tenant for Landlord’s cost in reviewing such plans at the rate of $125.00 per hour; subject to reasonable increase to reflect the then current hourly charge imposed for such review by Landlord for its tenants in the Center generally, and prior to undertaking any such review, Landlord shall provide a statement of the maximum review hours to be dedicated to such review. With respect to Permitted Tenant Alterations, Tenant shall provide Landlord with a copy of Tenant’s application for a building permit therefor, if applicable (together with all attachments thereto), and no review fee shall be charged to Tenant by Landlord in connection therewith nor shall Landlord’s approval of such application be required. Tenant shall provide copies of as-built plans and specifications for all Tenant Alterations to Landlord within a reasonable time of completion of the Tenant Alteration. All Tenant Alterations shall be done in a first class, workmanlike manner and shall comply with all insurance requirements then made available to Tenant and all applicable laws, ordinances, rules and regulations of governmental authorities having jurisdiction thereover, and, where applicable, with all reasonable requirements of Landlord imposed as a condition of such consent. (d) If, as a condition of Landlord’s consent, removal of a Tenant Alteration is required at termination of this Lease, Tenant shall promptly remove such Tenant Alterations and repair any damage occasioned by such removal. In default thereof, Landlord may effect said removal and repairs at Tenants expense. With respect to any Tenant Alterations which Tenant is not obligated to remove hereunder (including without limitation Permitted Tenant Alterations), such Tenant Alterations, if not removed by Tenant upon the termination of this Lease, shall be deemed abandoned by Tenant, and deemed a part of Landlord’s property, notwithstanding any provision of Section 16 to the contrary.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!