Maintenance Services Subject to Client’s timely payment of the applicable maintenance fees, Accenture will make available the following maintenance services (“Maintenance Services”):
MAINTENANCE SERVICE Free maintenance services including spares shall be provided by the vendor during the period of warranty. User, at its discretion may ask the vendor to provide maintenance services after warranty period, i.e. Annual maintenance and repairs of the system at the rates indicated by bidder in its proposal and on being asked so, the vendor shall provide the same. The cost of annual maintenance and repairs cost (after warranty period), which will include cost of spares replaced, shall be paid in equal quarterly installments at the end of each quarter.
Service Levels All service level requirements will be set forth in Exhibit A (“XXXX.xxx Referral Service Level Requirements”). Recipient Xxxxxx agrees to adhere, and encourage Recipient Agent’s adherence, with the version of the XXXX.xxx Referral Service Level Requirements in effect at the time XXXX.xxx identifies the Referral to Recipient Broker/Agent.
Service Level In the event that League InfoSight discovers or is notified by you of the existence of Non-Scheduled Downtime, we will use commercially reasonable efforts to determine the source of the problem and attempt to resolve it as quickly as possible.
Support and Maintenance Services Information about Teradici’s support and maintenance for the Licensed Product may be found at xxxxx://xxxx.xxxxxxxx.xxx.
Maintenance Scheduling The NTO shall schedule maintenance of its facilities designated as NTO Transmission Facilities Under ISO Operational Control and schedule any outages (other than forced transmission outages) of said transmission system facilities in accordance with outage schedules approved by the ISO. The NTO shall comply with maintenance schedules coordinated by the ISO, pursuant to this Agreement, for NTO Transmission Facilities Under ISO Operational Control. The NTO shall be responsible for providing notification of maintenance schedules to the ISO for NTO Transmission Facilities Requiring ISO Notification. The NTO shall provide notification of maintenance schedules to affected Transmission Owners for NTO Transmission Facilities Requiring ISO Notification and Local Area Transmission Facilities pursuant to Section 3.5.3 of the ISO Services Tariff.
Maintenance Support State Street shall use commercially reasonable efforts to correct system functions that do not work according to the System Product Description as set forth on Attachment A in priority order in the next scheduled delivery release or otherwise as soon as is practicable.
Maintenance and Support Services If this Agreement is for IT goods or services, this section applies: Unless otherwise specified in this Agreement: The Contractor shall promptly provide the Court with all Upgrades, including without limitation: (i) all Upgrades generally made available by Contractor to its other customers; (ii) Upgrades as necessary so that the Work complies with the Specifications and Applicable Law (including changes in Applicable Law); (iii) Upgrades as necessary so that the Work operates under new versions or releases of the Court’s operating system or database platform; and (iv) all on-site services necessary for installation of Upgrades. Without limiting any other obligation of Contractor under this Agreement, Contractor represents and warrants that it will maintain services, equipment, software or any other part of the Work so that they operate in accordance with their Specifications and Documentation; and The Contractor shall respond to the Court within four (4) hours after the Court reports a Technical Support Incident (such hours all occurring during Standard M&S Hours) to Contractor. DELIVERY, ACCEPTANCE, AND PAYMENT Delivery. Contractor shall deliver to the Court the Deliverables in accordance with this Agreement, including the Statement of Work. Unless otherwise specified by this Agreement, Contractor will deliver all goods purchased by the Court “Free on Board Destination Freight Prepaid” to the Court at the address and location specified by the Court. Title to all goods purchased by the Court vests in the Court upon payment of the applicable purchase price. Contractor will bear the risk of loss for any Work being delivered until received by the Court at the proper location. All shipments by Contractor or its Subcontractors must include packing sheets identifying: this Agreement number, the Court’s purchase order number, item number, quantity and unit of measure, part number and description of the goods shipped, and appropriate evidence of inspection, if required. Goods for different Agreements shall be listed on separate packing sheets.
Service Level Agreement 6.1 NCR Voyix will use commercially reasonable efforts to make the Service available to you at or above the Availability Rate set forth at xxxxx://xxx.xxx.xxx/support/aloha-sla. If NCR Voyix does not meet the Availability Rate, you are entitled to request a service-level credit subject to the terms of this Agreement. This credit is calculated as a percentage of the monthly recurring bill (or monthly pro rata share of billing, if billing does not occur monthly) for the Service for the month in which the Availability Rate was not met. The Availability Rate is determined by: (a) dividing the total number of valid outage minutes in a calendar month by the total number of minutes in that month; (b) subtracting that quotient from 1.00; (c) multiplying that difference by 100; and (d) rounding that result to two decimal places in accordance with standard rounding conventions. The number of outage minutes per day for a given service is determined by the lesser of the number of outage minutes.
6.2 Unavailability due to other conditions or caused by factors outside of NCR Voyix’s reasonable control will not be included in the calculation of the Availability Rate. Further, the following are expressly excluded from the calculation of the Availability Rate: (a) service unavailability affecting services or application program interfaces that are not used by you; (b) cases where fail-over to another data center is available but not utilized; (c) transient time-outs, required re-tries, or slower-than-normal response caused by factors outside of NCR Voyix’s reasonable control; (d) Scheduled Downtime, including maintenance and upgrades; (e) force majeure; (f) transmission or communications outages outside the NCR Voyix- controlled environment; (g) store-level down-time caused by factors outside of NCR Voyix’s reasonable control; (h) outages attributable to services, hardware, or software not provided by NCR Voyix, including, but not limited to, issues resulting from inadequate bandwidth or related to third-party software or services;
(i) use of the Service in a manner inconsistent with the documentation for the application program interface or the NCR Voyix Product; (j) your Point of Sale (“POS”) failure or the failure to properly maintain the POS environment, including updating the POS firmware or version of the software running on the POS as recommended by either NCR Voyix, a third-party POS reseller or servicer; and (k) issues related to third party domain name system (“DNS”) errors or failures.
6.3 To obtain a service-level credit, you must submit a claim by contacting NCR Voyix through the website at xxxxx://xxx.xxx.xxx/support/aloha-sla Your failure to provide the claim and other information will disqualify you from receiving a credit. NCR Voyix must receive claims within 60 days from the last day of the impacted month. After that date, claims are considered waived and will be refused. You must be in compliance with the Agreement in order to be eligible for a service-level credit. You may not unilaterally offset for any performance or availability issues any amount owed to NCR Voyix. If multiple Services experience an outage in a given month, the total credit for that month will be the highest credit allowed for any single Service which failed; there is no stacking of credits.
6.4 The remedies set forth in the Section are your sole and exclusive remedies for performance or availability issues affecting the Services, including any failure by NCR Voyix to achieve the Availability Rate.
Maintenance Outages If Seller reasonably determines that it is necessary to schedule a Maintenance Outage, Seller shall notify Buyer of the proposed Maintenance Outage at least five (5) days before the outage begins (or such shorter period to which Buyer may reasonably consent in light of then existing conditions). Upon such notice, the Parties shall plan the Maintenance Outage to mutually accommodate the reasonable requirements of Seller and the service obligations of Buyer; provided, however, that, unless Buyer otherwise consents, such consent not to be unreasonably withheld, no Maintenance Outage may be scheduled between the hour ending 0700 through the hour ending 2200, Monday through Saturday, during the time period commencing on May 15 and concluding on September 15. Notice of a proposed Maintenance Outage shall include the expected start date and time of the outage, the amount of Capacity of the Facility that will not be available, and the expected completion date and time of the outage. Seller shall give Buyer notice of the Maintenance Outage as soon as Seller determines that the Maintenance Outage is necessary. Buyer shall promptly respond to such notice and may request reasonable modifications in the schedule for the outage. Seller shall use all reasonable efforts to comply with any request to modify the schedule for a Maintenance Outage. Seller shall notify Buyer of any subsequent changes in Capacity available to Buyer or any changes in the Maintenance Outage completion date and time. As soon as practicable, any notifications given orally shall be confirmed in writing. Seller shall take all reasonable measures and exercise its best efforts in accordance with Prudent Electrical Practices to minimize the frequency and duration of Maintenance Outages.
