Project Documents In addition to any other pertinent and necessary Project documents, the following documents shall be used in the development of the Project:
A. TxDOT 2011 Texas Manual of Uniform Traffic Control Devices for Streets and Highways, including latest revisions
B. Texas Department of Transportation's Standard Specifications for Construction of Highways, Streets, and Bridges, 2014 (English units)
Project Documentation All documentation provided to the City other than Project drawings shall be furnished on a Microsoft compatible compact disc.
Material Project Documents (a) The Company shall at all times (i) perform and observe all of the covenants under the Material Project Documents to which it is a party and take reasonable actions to enforce all of its rights thereunder, other than to the extent the same could not reasonably be expected to have a Material Adverse Effect, (ii) subject to the provisions of clause (b) of this Section 9.8, maintain the System Leases (other than Leases constituting System Leases only pursuant to clause (5) of the definition thereof) in full force and effect, and (iii) maintain the Leases (other than the System Leases referred to in the foregoing clause (ii) of this Section 9.8(a)) to which it or any of its Subsidiaries is a party in full force and effect, except to the extent the same could not reasonably be expected to have a Material Adverse Effect.
(b) If the term of a Lease with the Company or one of its Subsidiaries expires and the Qualified Lessee under such Lease has either ceased operating the related assets or has ceased paying rent as required under the applicable Lease, the Company shall, or shall cause a Subsidiary, as applicable, to enter into a supplement or a new Lease with respect to the related leasehold assets with a Qualified Lessee that provides for rent that, when combined with all other expected revenue, will, in the reasonable judgment of the Company, as of the commencement date of such supplement or new Lease, generate sufficient revenue to satisfy the requirements of Section 9.9 and will not otherwise result in a materially worse position for the Company as compared to the terms of the applicable expired Lease. Each such new Lease shall have a term of at least five years. Notwithstanding the foregoing, if (i) such expired Lease relates to transmission and/or distribution assets that are not generating significant revenue, (ii) the failure to renew such Lease would not constitute a Material Adverse Effect and (iii) the Company reasonably believes it will generate sufficient revenue and hold sufficient assets (without giving effect to the leasehold assets with respect to such Lease) to satisfy the requirements of Section 9.9, then this Section 9.8(b) will not require a supplement or new lease with respect to such leasehold assets.
Construction Document Phase 1.4.1 Based on the approved Design Development Documents, Guaranteed Maximum Price, coordinated models and any further adjustments in the scope or quality of the Project or in the Amount Available for the Construction Contract authorized by the Owner, the Architect/Engineer shall prepare, for approval by the Owner and review by the Construction Manager, Construction Documents consisting of Drawings, Schedules and Specifications derived from the model(s) in accordance with Owner’s written requirements setting forth in detail the requirements for construction of the Project, including, without limitation, the BIM Execution Plan and “Facility Design Guidelines”. The Plans, Drawings and Specifications for the entire Project shall be so prepared that same will call for the construction of the building and related facilities, together with its built-in permanent fixtures and equipment which will cost not more than the Guaranteed Maximum Price accepted by Owner, or the Amount Available for the Construction Contract established by Owner if no Guaranteed Maximum Price proposal has been accepted by Owner. The Architect/Engineer will be responsible for managing the design to stay within such Guaranteed Maximum Price proposal or Amount Available for the Construction Contract. The Architect/Engineer shall review the Construction Documents as they are being prepared at intervals appropriate to the progress of the Project with the Owner and Construction Manager at the Project site or other location specified by Owner in the State of Texas. The Architect/Engineer shall utilize the model(s) to support the review process during Construction Documents. The Architect/Engineer shall provide the Construction Manager with a compact disc containing documents and data files derived from the model to assist the Construction Manager in fulfilling its responsibilities to the Owner.
1.4.2 As a part of Construction Documents Phase, Architect/Engineer shall accomplish model coordination, aggregation and “clash detection” to remove conflicts in design between systems, structures and components. Architect/Engineer shall demonstrate and provide written assurance to Owner that all conflicts/collisions between models have been resolved.
1.4.3 The Architect/Engineer shall consult with the Owner and Construction Manager on matters such as construction phasing and scheduling, bid or proposal alternates, liquidated damages, the construction contract time period, and other construction issues appropriate for the Project. The Architect/Engineer shall assist the Owner and Construction Manager in the preparation of the necessary bidding information, bidding forms, RFP information, and RFP forms, and the Conditions of the Contract.
1.4.4 The Architect/Engineer shall assist the Owner in connection with the Owner’s responsibility and procedures for obtaining approval of all building and accessibility authorities having jurisdiction over the Project.
1.4.5 The Architect/Engineer shall provide coordination and inclusion of sequence of operations for all operable systems in the facility as defined by Owner during Design Development.
1.4.6 The Architect/Engineer shall review the Estimated Construction Cost prepared by the Construction Manager, and shall provide written comments.
1.4.7 The Architect/Engineer shall participate in a final review of the Construction Documents and model(s) with the Owner and Construction Manager at the Project location or other location specified by Owner in the State of Texas. Prior to the Owner’s approval of the Construction Documents, the Architect/Engineer shall incorporate such changes as are necessary to satisfy the Owner’s review comments.
1.4.8 Before proceeding into the Bidding and Proposal Phase, the Architect/Engineer shall obtain Owner’s written acceptance of the Construction Documents and approval of the Final Amount Available for the Construction Contract as approved by the Board of Regents.
Loan Document Status Each related Mortgage Note, Mortgage, Assignment of Leases (if a separate instrument), guaranty and other agreement executed by or on behalf of the related Mortgagor, guarantor or other obligor in connection with such Mortgage Loan is the legal, valid and binding obligation of the related Mortgagor, guarantor or other obligor (subject to any non-recourse provisions contained in any of the foregoing agreements and any applicable state anti-deficiency or market value limit deficiency legislation), as applicable, and is enforceable in accordance with its terms, except as such enforcement may be limited by (i) bankruptcy, insolvency, fraudulent transfer, reorganization, moratorium or other similar laws affecting the enforcement of creditors’ rights generally and (ii) general principles of equity (regardless of whether such enforcement is considered in a proceeding in equity or at law) and except that certain provisions in such Mortgage Loan documents (including, without limitation, provisions requiring the payment of default interest, late fees or Prepayment Premium/Yield Maintenance Charge) may be further limited or rendered unenforceable by applicable law, but (subject to the limitations set forth above) such limitations or unenforceability will not render such Mortgage Loan documents invalid as a whole or materially interfere with the Mortgagee’s realization of the principal benefits and/or security provided thereby (clauses (i) and (ii) collectively, the “Standard Qualifications”). Except as set forth in the immediately preceding sentence, there is no valid offset, defense, counterclaim or right of rescission available to the related Mortgagor with respect to any of the related Mortgage Notes, Mortgages or other Mortgage Loan documents, including, without limitation, any such valid offset, defense, counterclaim or right based on intentional fraud by Mortgage Loan Seller in connection with the origination of the Mortgage Loan, that would deny the Mortgagee the principal benefits intended to be provided by the Mortgage Note, Mortgage or other Mortgage Loan documents.
Mortgage Loan Document Status Each related Mortgage Note, Mortgage, Assignment of Leases (if a separate instrument), guaranty and other agreement executed by or on behalf of the related Mortgagor, guarantor or other obligor in connection with such Mortgage Loan is the legal, valid and binding obligation of the related Mortgagor, guarantor or other obligor (subject to any non-recourse provisions contained in any of the foregoing agreements and any applicable state anti-deficiency or market value limit deficiency legislation), as applicable, and is enforceable in accordance with its terms, except (i) as such enforcement may be limited by (a) bankruptcy, insolvency, fraudulent transfer, reorganization, moratorium or other similar laws affecting the enforcement of creditors’ rights generally and (b) general principles of equity (regardless of whether such enforcement is considered in a proceeding in equity or at law) and (ii) that certain provisions in such Mortgage Loan documents (including, without limitation, provisions requiring the payment of default interest, late fees or prepayment/yield maintenance fees, charges and/or premiums) are, or may be, further limited or rendered unenforceable by or under applicable law, but (subject to the limitations set forth in clause (i) above) such limitations or unenforceability will not render such Mortgage Loan documents invalid as a whole or materially interfere with the Mortgagee’s realization of the principal benefits and/or security provided thereby (clauses (i) and (ii) collectively, the “Standard Qualifications”). Except as set forth in the immediately preceding sentences, there is no valid offset, defense, counterclaim or right of rescission available to the related Mortgagor with respect to any of the related Mortgage Notes, Mortgages or other Mortgage Loan documents, including, without limitation, any such valid offset, defense, counterclaim or right based on intentional fraud by Seller in connection with the origination of the Mortgage Loan, that would deny the Mortgagee the principal benefits intended to be provided by the Mortgage Note, Mortgage or other Mortgage Loan documents.
Project Contracts Prior to the delivery of this Lease, the Company may have entered into a contract or contracts with respect to the acquisition and/or construction of the Improvements. Those contracts, and any such contracts entered into by the Company after delivery of this Lease are hereinafter referred to as the “Project Contracts.” Prior to the delivery hereof, certain work has been or may have been performed on the Improvements pursuant to said Project Contracts or otherwise. Subject to the Lender’s rights in the Project Contracts, the Company hereby conveys, transfers and assigns to the Issuer all of the Company’s rights in, but not its obligations under the Project Contracts and the Issuer hereby designates the Company as Issuer’s agent for the purpose of executing and performing the Project Contracts. After the execution hereof, the Company shall cause the Project Contracts to be fully performed by the contractor(s), subcontractor(s) and supplier(s) thereunder in accordance with the terms thereof, and the Company covenants to cause the Improvements to be acquired, constructed and/or completed in accordance with the Project Contracts. Any and all amounts received by the Issuer, the Trustee or the Company from any of the contractors or other suppliers by way of breach of contract, refunds or adjustments shall become a part of and be deposited in the Project Fund.
Plan Document Acknowledgment By accepting the RSUs, you acknowledge that you have received a copy of the Plan, reviewed the Plan, the Agreement and this Addendum A in their entirety and fully understand and accept all provisions of the Plan, the Agreement and this Addendum A. In addition, you further acknowledge that you have read and specifically and expressly approve without limitation the following clauses in the Agreement: Section 4 (Responsibility for Taxes); Section 7 (Acknowledgement of Nature of Plan and RSUs); Section 8 (No Advice Regarding Grant); Section 9 (Right to Continued Employment); Section 11 (Deemed Acceptance); Section 13 (Severability and Validity); Section 14 (Governing Law, Jurisdiction and Venue); Section 16 (Electronic Delivery and Acceptance); Section 17 (Xxxxxxx Xxxxxxx/Market Abuse Laws); Section 18 (Language); Section 19 (Compliance with Laws and Regulations); Section 20 (Entire Agreement and No Oral Modification or Waiver); Section 21 (Addendum A); Section 22 (Foreign Asset/Account Reporting Requirements and Exchange Controls); and Section 23 (Imposition of Other Requirements).
Product Documentation You should review the policy documents carefully to ensure they accurately reflect the cover, conditions, limits and other terms that you require. Particular attention should be paid to policy conditions and warranties as failure to comply with these could invalidate your policy. Claims can arise, under certain types of insurance contract, long after the expiry of the policy. It is therefore important that you retain and keep safely all documents associated with your policy.
MSAA Indicator Technical Specification Document This Agreement shall be interpreted with reference to the MSAA Indicator Technical Specifications document.
