We use cookies on our site to analyze traffic, enhance your experience, and provide you with tailored content.

For more information visit our privacy policy.

START OF WORK Sample Clauses

START OF WORK. 2.1 The contractor is not authorized to go onto the property on which the work is to be done, nor move materials, equipment or workers onto that property, nor to start on-site work until the contract with the county is signed, the county sends the contractor written notice to proceed with the work and the contractor has filed the public works bonds required in the invitation to bid. 2.2 The contractor shall coordinate with the county's designated representative in accordance with the project specifications.
AutoNDA by SimpleDocs
START OF WORK. We are prepared to start work with the understanding that a signed copy of this Agreement will be forthcoming.
START OF WORK a) The Vendor shall commence work by the start date indicated in the bid documents. b) The time of starting may be postponed by written agreement between the City and the Vendor because of expected delays, or because of other contingencies clearly beyond the control or responsibility of the Vendor. c) The City may delay the beginning of all or any part of the work if materials or equipment to be furnished by the Owner are not delivered. The Vendor shall have no claim for damages on account of such delay, but shall be entitled to as much additional time in which to perform and complete this Contract on their part as the City shall certify in writing to be equitable.
START OF WORK a) The Contractor shall commence work, at such points as the City may approve, within 45 days after the date of the Notice to Proceed by the City, or, if no such notice is issued, within 60 days after the execution of this Contract by the City. b) The time of starting may be postponed by written agreement between the City and the Contractor because of expected delays in receipt of materials and equipment, or if the season is unsuitable for commencement of the work, or because of other contingencies clearly beyond the control or responsibility of the Contractor. c) The City may delay the beginning of all or any part of the work if the necessary lands or rights-of-way for such work have not been obtained, or if materials or equipment to be furnished by the Owner are not delivered. The Contractor shall have no claim for damages on account of such delay, but shall be entitled to as much additional time in which to perform and complete this Contract on their part as the City shall certify in writing to be equitable.
START OF WORKNo Work may begin until the applicable First Source Hiring Agreement and ECA has been duly executed and delivered by the parties to such agreements.
START OF WORKNo Contract shall become effective until the Contract has been approved by the required City Departments, signed by the City of Detroit Chief Procurement Officer, and approved by resolution of the Detroit City Council. Prior to the completion of this approval process, the Supplier will have no authority to begin work on this Contract. The Chief Procurement Officer shall not authorize any payments to the Supplier prior to such approvals, nor shall the City incur any liability to reimburse the Supplier regarding any expenditure for the purchase of materials or the payment of services.
START OF WORK. (a) The Owner will not commence construction of the Works until all City agreements and permits are executed and issued, and the Owner has complied with all pre-construction requirements in this Agreement. (b) Without limiting the foregoing, a Road Right of Way Use Permit pursuant to the City’s Traffic and Highways Bylaw (as amended or replaced from time to time) is required prior to the commencement of any works or activities on any City roadway.
AutoNDA by SimpleDocs
START OF WORK. The date work commences on-site shall be considered the actual start date of the agreement. The completion date shall be established by adding the number of days specified for the performance.
START OF WORK. As to any Existing Work Borrower will cause such construction to cease and terminate all existing contracts for construction of the Work. Borrower will not recommence construction or permit any Contractor, including General Contractor, to recommence any Work until Lender and the Disbursing Agent have been provided: (a) A Sworn Cost Statement sworn to by the Contractor of the Project itemizing all Direct Costs to be incurred in constructing the Project, the name of each and every known contractor, sub-contractor, workmen and materialman, his address and an estimate of the dollar value of the work, labor and materials to be done or supplied and a general statement of the nature of the work to be done or materials to be supplied by each contractor and if not yet bid, the amount of the subcontract to be bid (to be updated as subcontracts are bid). (b) A Final Affidavit from the Borrower with respect to any existing work done on the Premises identifying (i) by name each and every contractor, sub-contractor, workmen and materialman the Contractor has contracted with, (ii) his address, (iii) the dollar value of the work, labor and materials done or supplied, (iv) a general statement of the nature of the work done or materials supplied, and (v) that all lienors under contract have been paid in full. (c) A Final Affidavit by any contractor engaged by the Borrower with respect to any work done under a prior Notice of Commencement identifying by name each and every contractor, sub-contractor, workmen and materialman, his address, the dollar value of the work, labor and materials done or supplied, including the list described in Section 713.165 Florida Statutes, and a general statement of the nature of the work to be done or materials to be supplied with respect to any existing Work under contract. (d) Final Waiver and Release of Lien from each person or entity who has performed work and/or provided materials or supplies to the Project acknowledging that the Existing Notices of Commencement are void. (e) Termination of all existing contracts for any Work done on the Project. (f) Removal of all posted Existing Notices of Commencement. (g) Affidavit of the Owner in accordance with Florida Statutes 713.07 in reasonable form reciting the facts that establish of record the date that construction ceased and that all parties who have provided work and/or furnished material to the Project have been paid in full. (h) A Notice of Termination of any Existing Notice of Commenceme...
START OF WORK. Construction of the site grading shall be commenced within thirty (30) days of the date of this Agreement. A Notice to Proceed will be delivered to Design Builder not later than the time and in the manner required by the Design Build Agreement but not later than thirty (30) days after (i) issuance of a final judgment on the Appeal or (b) expiration of any Appeal Rights. Borrower shall diligently pursue construction of the Project to completion, and supply such moneys and perform such duties as may be necessary to complete the construction of the Project pursuant to the Contract Documents and in full compliance with all terms and conditions of this Agreement all of which shall be accomplished on or before the Substantial Completion Date (subject to extensions to the First Extended Date and the Second Extended Date if the Appeal is filed and the respective First Extension Fee and Second Extension Fee are paid) and without Liens, claims or assessments (actual or contingent) asserted against the Premises for any material, labor or other items furnished in connection therewith, and all in full compliance with all Governmental Requirements, evidence of satisfactory compliance with all of which Borrower will provide to Lender upon request therefor by Lender. Borrower agrees to hold harmless and indemnify the Lender from any claimed or threatened Lien against the Premises.
Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!