Construction Phase Services (CPS Sample Clauses

Construction Phase Services (CPS. The Engineer shall remove a portion of CPS effort from prime provider and distribute effort among Team members in this supplement. DocuSign Envelope ID: ED7DF0BF-CED8-459B-BD20-D429F09B7CE5 Contract No. 15-6SDP5001 Supplemental Agreement No. 3 Attachment E-3 Fee Schedule PS Contract No. 5026 Hwy: US 281 ‐ From LP 1604 to Stone Oak Prkwy CSJ: 0253‐04‐146 County: Bexar Prime: HNTB PROJECT SUMMARY BASIC SERVICES Task Descriptions HNTB SA03 Xxxx SA03 Xxxxxxx SA03 Xxxxxxx SA03 K Xxxxxx SA03 HVJ SA03 LTRA SA03 PCI SA03 XXXX XX00 XXX XX00 XXX XX00 XX00 Hours FUNCTION CODE 102 – FEASIBILITY STUDIES 123 0 123 FUNCTION CODE 120 – SOCIAL /ECONOMIC /ENV 0 0 (82) (82) FUNCTION CODE 130 – RIGHT‐OF‐WAY DATA 860 0 60 920 FUNCTION CODE 160 ‐ ROADWAY DESIGN 1,770 0 80 319 2,169 FUNCTION CODE 300 – DESIGN VERIFICATION, CHANGES AND ALTERATIONS (786) (182) 60 88 732 88 0 LABOR TOTALS 3,052 0 (000) 00 000 0 00 88 0 772 88 4,267 XXX UNIT COST ITEMS UNIT COST ITEMS OTHER DIRECT EXPENSES PROJECT TOTAL BASIS SERVICES Task Descriptions HNTB SA03 Xxxx SA03 Xxxxxxx SA03 Xxxxxxx SA03 K Xxxxxx SA03 HVJ SA03 LTRA SA03 PCI SA03 RODS SA03 SEA SA03 SSA XX00 XX00 Cost FUNCTION CODE 102 – FEASIBILITY STUDIES $ 26,044.92 $ ‐ $ 26,044.92 FUNCTION CODE 120 – SOCIAL /ECONOMIC /ENV $ ‐ $ ‐ $ (13,860.00) $ (13,860.00) FUNCTION CODE 130 – RIGHT‐OF‐WAY DATA $ 151,108.32 $ ‐ $ 9,031.80 $ 24,742.08 $ 184,882.20 FUNCTION CODE 145 – MANAGING CONTRACT $ 195,029.64 $ ‐ $ 1,545.84 $ ‐ $ 8,056.00 $ 204,631.48 FUNCTION CODE 160 ‐ ROADWAY DESIGN $ 257,211.34 $ ‐ $ 10,305.60 $ 32,986.15 $ 300,503.09 FUNCTION CODE 300 – DESIGN VERIFICATION, CHANGES AND ALTERATIONS $ (130,316.39) $ ‐ $ (28,390.00) $ ‐ $ 13,216.08 $ 14,460.08 $ 115,304.64 $ 15,649.44 $ (76.15) LABOR TOTALS $ 499,077.83 $ ‐ $ (42,250.00) $ 11,851.44 $ 46,202.23 $ ‐ $ 9,031.80 $ 39,202.16 $ 123,360.64 $ 15,649.44 $ 702,125.54 XXX UNIT COST ITEMS $ ‐ $ ‐ $ ‐ $ ‐ $ 57,350.00 $ ‐ $ 57,350.00 UNIT COST ITEMS $ ‐ $ ‐ $ ‐ $ ‐ $ (305,348.00) $ ‐ $ ‐ $ ‐ $ (305,348.00) OTHER DIRECT EXPENSES $ 24,424.50 $ ‐ $ ‐ $ 152.00 $ 5,336.72 $ 3,060.00 $ 561.80 $ 45.00 $ 33,580.02 PROJECT TOTAL $ 523,502.33 $ ‐ $ (42,250.00) $ 11,851.44 $ 46,354.23 $ (305,348.00) $ 71,718.52 $ 42,262.16 $ 123,922.44 $ 15,694.44 $ 487,707.56 DocuSign Envelope ID: ED7DF0BF-CED8-459B-BD20-D429F09B7CE5 Contract No. 15-6SDP5001 Supplemental Agreement No. 3 Attachment E-3 Fee Schedule PS Contract No. 5026 Hwy: US 281 ‐ From LP 1604 to Stone Oak Prkwy CSJ: 0253‐04‐146 County: Bexar Prime: HNT...
Sample 1
AutoNDA by SimpleDocs

Related to Construction Phase Services (CPS

  • Construction Phase Services 3.1.1 – Basic Construction Services

  • PRE-CONSTRUCTION PHASE SERVICES The Pre-Construction Phase shall be deemed to commence upon the date specified in a written Notice to Proceed with Pre-Construction Phase Services issued by Owner and shall continue through completion of the Construction Documents and procurement of all major Subcontractor agreements. Contractor is not entitled to reimbursement for any costs incurred for Pre-Construction Phase Services performed before issuance of the written Notice to Proceed. Pre-Construction Phase Services may overlap Construction Phase Services. Contractor shall perform the following Pre-Construction Phase Services:

  • Construction Phase Fee Contractor’s Construction Phase Fee is the maximum amount payable to Contractor for any cost or profit expectation incurred in the performance of the Work that is not specifically identified as being eligible for reimbursement by Owner elsewhere in this Agreement. References in the UGSC to Contractor’s “overhead” and “profit” mean Contractor’s Construction Phase Fee. The Construction Phase Fee includes, but is not limited to, the following items: 9.1 All profit, profit expectations and costs associated with profit sharing plans such as personnel bonuses, incentives, and rewards; company stock options; or any other like expenses of Contractor.

  • Construction Phase Part 1 –

  • Pre-Commencement Phase Services The services required to be provided by the Contractor for the Pre- Commencement Phase of the Project in accordance with the Contract Documents.

  • Construction Administration Phase Delete the following paragraph if Submittal Exchange isn’t going to be used: 2.

  • Construction Services 4,500 thousand SDR for Japan Post in Group A 15,000 thousand SDR for all other entities in Group A 4,500 thousand SDR for entities in Group B Architectural, engineering and other technical services covered by this Agreement: 450 thousand SDR

  • Construction Management Fee The Construction Management Fee for the Project shall be either a ☒Lump Sum or ☐Not-To-Exceed Fee of Thirty-Six Thousand, Eight Hundred Forty-Six Dollars and Twenty-Six Cents ($36,846.26). NOTE: Allowances will be on a Not-To-Exceed basis. All unused funds will be returned to the School District at the time of construction closeout. Fee will be paid only on cost of work for these items. Exhibit C- Project Assignment Page 2 of 4

  • Information Systems Acquisition Development and Maintenance a. Client Data – Client Data will only be used by State Street for the purposes specified in this Agreement.

  • Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!