THE WORK The term "
Tenant Improvements Subject to this Section 4, Tenant shall accept the Suite 110 Premises in its “as is” condition (subject to Landlord's continuing repair and maintenance obligations, as outlined in Section 10 of the Lease (as may be amended)), and Landlord shall have no obligation to make any alterations or improvements thereto whatsoever (provided that Landlord shall deliver same in good and tenantable condition, broom clean, with all systems serving same in good working order). Any alterations that Tenant desires to make in the Suite 110 Premises shall be subject to all the terms and conditions set forth in Section 11 of the Lease. Notwithstanding anything in the Lease to the contrary, Landlord hereby agrees to grant Tenant an allowance in the amount of $10,000 to be applied toward the cost (including architectural and engineering fees) of alterations performed by Tenant in the Suite 110 Premises (the “Granted Allowance”) in conjunction with Tenant’s initial occupancy of Suite 110 Premises. Provided no Event of Default then exists under the Lease, the Granted Allowance (or portions thereof) shall be disbursed to Tenant within thirty (30) days following Tenant's submission to Landlord of paid invoices for work related to alterations performed by Tenant in the Suite 110 Premises, accompanied by waivers of liens executed by all contractors employed by Tenant for the performance of such work. If the cost of Tenant's alterations in the Suite 110 Premises exceeds the amount of the Granted Allowance, the excess shall be paid by Tenant after the Granted Allowance is fully exhausted. Any portion of the Granted Allowance that has not been applied (or contracted to be applied) in the manner set forth above by the date which is twelve (12) months following the Eighth Amendment Commencement Date shall revert to Landlord, and Tenant shall have no further rights with respect thereto.
Tenant Work Before commencing any repair or Alteration (“Tenant Work”), Tenant shall deliver to Landlord, and obtain Landlord’s approval of, (a) names of contractors, subcontractors, mechanics, laborers and materialmen; (b) evidence of contractors’ and subcontractors’ insurance; and (c) any required governmental permits. Tenant shall perform all Tenant Work (i) in a good and workmanlike manner using materials of a quality reasonably approved by Landlord; (ii) in compliance with any approved plans and specifications, all Laws, the National Electric Code, and Landlord’s construction rules and regulations; and (iii) in a manner that does not impair the Base Building. If, as a result of any Tenant Work, Landlord becomes required under Law to perform any inspection, give any notice, or cause such Tenant Work to be performed in any particular manner, Tenant shall comply with such requirement and promptly provide Landlord with reasonable documentation of such compliance. Landlord’s approval of Tenant’s plans and specifications shall not relieve Tenant from any obligation under this Section 7.3. In performing any Tenant Work, Tenant shall not use contractors, services, labor, materials or equipment that, in Landlord’s reasonable judgment, would disturb labor harmony with any workforce or trades engaged in performing other work or services at the Project.
Excavation If any excavation shall be made upon land adjacent to or under the Building, or shall be authorized to be made, Tenant shall afford to the person causing or authorized to cause such excavation license to enter the Premises for the purpose of performing such work as said person shall deem reasonably necessary to preserve and protect the Building from injury or damage and to support the same by proper foundations, without any claim for damages or liability against Landlord (except in the case of Landlord Parties’ willful misconduct or gross negligence) and without reducing or otherwise affecting Tenant’s obligations under this Lease. Any such work must be conducted in a manner that minimizes disruption and inconvenience to Tenant.
Roof Any Tenant-installed equipment must be removed with all roof penetrations properly repaired by a licensed roofing contractor approved by Landlord. Leaks arising from any Tenant-installed equipment or roof penetrations must be fixed in accordance with Landlord’s maintenance and repair recommendations.
Base Building Work Landlord shall construct the Base Building Work as further set forth on Exhibit 10.03, attached.
Construction of the Tenant Improvements Landlord shall construct the Tenant Improvements in accordance with this exhibit and the construction contract to be executed by Landlord and its contractor(s). The construction contract for constructing the Tenant Improvements and the contractor(s) to perform the work shall be approved and/or selected, as the case may be, by Landlord at its sole and absolute discretion without the consent of Tenant.
Tenant Improvement Plans Any work proposed by Tenant at the Premises or Building (the “Tenant Improvements”) shall be subject to Landlord’s reasonable prior approval and shall be subject to the other terms and conditions of this Exhibit, which approval shall not be unreasonably withheld or delayed except for good cause shown. All architectural, engineering and other design fees shall be paid by Tenant, provided that, of the total Tenant Improvement Allowance, up to Five and No/100 Dollars (S5.00) per rentable square foot of the Premises of such fees may be subject to reimbursement under the Tenant Improvement Allowance. Tenant shall use its architect, engineers and other design professionals, all of whom shall comply with any applicable licensing or governmental requirements of the City of Santa Xxxxx and the State of California. Tenant shall cause its architect, who shall be subject to Landlord’s prior approval (“Tenant’s Architect”), which approval shall not be unreasonably withheld or delayed except for good cause shown, to prepare a draft space plan (the “Space Plan”) for the Tenant Improvements and shall submit the proposed Space Plan to Landlord for the latter’s approval (not to be unreasonably withheld or delayed) within twenty-one (21) days following mutual execution of the Lease. (If available upon mutual execution of this Lease, a mutually-approved preliminary space plan for the Tenant Improvements has been attached hereto as Exhibit C-1.) Landlord shall deliver to Tenant any written objections, questions or comments of Landlord with regard to the Space Plan, and Tenant shall cause the Space Plan to be revised to address such written comments and shall resubmit said Space Plan to Landlord for approval within five (5) business days thereafter. Such process shall continue until Landlord has approved the Space Plan. Tenant’s Architect shall then prepare working drawings and specifications for the Tenant Improvements, including architectural, structural, plumbing, mechanical, electrical, and fire protection drawings as required, suitable for permit application (the “Working Drawings”) and shall submit the proposed Working Drawings to Landlord for the latter’s approval within sixty (60) days following Landlord’s approval of the final Space Plan. The Space Plan and Working Drawings shall be subject to Landlord’s approval, which Landlord agrees shall not be unreasonably withheld or delayed. Landlord shall not be deemed to have acted unreasonably if it withholds its approval thereof because, in Landlord’s reasonable opinion as supported by statement or reports from licensed engineers, the work, as described in any such item: (i) will adversely affect Building systems, the structure of the Building or the safety of the Building and/or their occupants; (ii) will materially impair Landlord’s ability to furnish services to Tenant or other tenants at the Project; (iii) would materially increase the cost of operating the Building; (iv) would violate any governmental laws, rules or ordinances (or interpretations thereof); (v) contains or uses hazardous or toxic materials or substances not permitted under Applicable Laws; (vi) would affect the external appearance of the Building; (vii) would materially and adversely affect another tenant’s premises at the Project: or (viii) is prohibited by any mortgage, trust deed or other instrument encumbering the Building or Project. Landlord shall deliver to Tenant any written objections, questions or comments of Landlord with regard to the Working Drawings, and Tenant shall cause the Working Drawings to be revised to address such written comments and shall resubmit said Working Drawings to Landlord for approval within ten (10) business days thereafter. Such process shall continue until Landlord has approved the Working Drawings. Landlord’s approval of the Space Plan and/or the Working Drawings shall not be deemed any representation or warranty that the same comply with applicable codes.
Common Areas Tenant shall have the non-exclusive right to use in common with other tenants in the Project, and subject to the Rules and Regulations referred to in Article 5 of this Lease, those portions of the Project which are provided, from time to time, for use in common by Landlord, Tenant and any other tenants of the Project (such areas, together with such other portions of the Project designated by Landlord, in its discretion, including certain areas designated for the exclusive use of certain tenants, or to be shared by Landlord and certain tenants, are collectively referred to herein as the “Common Areas”). The Common Areas shall consist of the “Project Common Areas” and the “Building Common Areas.” The term “Project Common Areas,” as used in this Lease, shall mean the portion of the Project designated as such by Landlord or areas within the Project that the occupants of the Building are permitted to utilize pursuant to a recorded declaration and which areas shall be maintained in accordance with the declaration. The term “Building Common Areas,” as used in this Lease, shall mean the portions of the Common Areas located within the Building reasonably designated as such by Landlord. The manner in which the Common Areas are maintained and operated shall be at the reasonable discretion of Landlord and the use thereof shall be subject to the Rules and Regulations as Landlord may make from time to time. Landlord reserves the right to close temporarily, make alterations or additions to, or change the location of elements of the Project and the Common Areas, provided that, in connection therewith, Landlord shall perform such closures, alterations, additions or changes in a commercially reasonable manner and, in connection therewith, shall use commercially reasonable efforts to minimize any material interference with Tenant’s use of and access to the Premises.
Tenant’s Work During the Term Tenant may not perform any work, alterations, installations, additions, improvements, structural repairs or restorations to the Property (“Tenant’s Work”) without the prior written consent of Landlord which (i) in the case of alterations, additions, installations or improvements of a structural nature or involving the Building systems, may be granted or withheld by Landlord in its sole and absolute discretion and (ii) in the case of alterations or improvements of a non-structural nature or not involving Building systems, shall not be unreasonably withheld or delayed. In connection with such consent, Tenant shall submit to Landlord such detailed plans, specifications, drawings and other materials reasonably requested by Landlord. Tenant may make such non-structural alterations and perform work of a decorative nature without Xxxxxxxx’s prior written consent. At Tenant’s sole cost, Xxxxxxxx agrees to cooperate with Xxxxxx (including signing applications) in obtaining any necessary permits for any Tenant’s Work that Xxxxxx is permitted to make hereunder. In all cases the Tenant’s Work shall be performed at Tenant’s sole cost and expense and by contractors selected by Xxxxxx. Tenant agrees that the Tenant’s plans and specifications shall be in compliance with applicable laws, rules and regulations, that Tenant shall not commence construction until it obtains (if required) a building permit for Tenant’s Work, and that such Tenant’s Work shall be performed in accordance with the building permit, in compliance with applicable law and in accordance with the Tenant’s plans and specifications. As a condition of approving such Tenant's Work the Landlord may require the Tenant to maintain such additional insurance coverages (in addition to those required in Article 8 hereof) as the Landlord may reasonably require.