We use cookies on our site to analyze traffic, enhance your experience, and provide you with tailored content.

For more information visit our privacy policy.

CRITICAL ITEMS Sample Clauses

CRITICAL ITEMS. 18.1. Critical items are designated in a Specification. Any delivery of critical items must be accompanied by a Certificate of Compliance signed by an authorised representative of your Quality Assurance Department, attesting that the requirements of the Specification have been met. 18.2. Critical items must be manufactured to the approved construction and procedures. No change will be made to construction or production methods without prior written approval from us. 18.3. Critical items must always be accompanied by a manufacturer's batch number which is traceable. You must maintain records to allow traceability back to the initial lot identification of all raw constituents used in the manufacture of items supplied against the Specification.
CRITICAL ITEMS. All Contractor supplied hardware associated with the Server, Contractor supplied interfaces, and Capture Stations that are required to the County to perform its day to day duties associated with the capture and storage of "mug" photo images shall be considered as Critical Items. The only hardware exception to this paragraph will be the printers.
CRITICAL ITEMS. All IWS hardware associated with the Server, IWS supplied interfaces, and Capture Stations that prohibit the COUNTY from performing their day to day duties associated with the capture and storage of mug photo images shall be considered as CRITICAL ITEMS. The only hardware exception to this paragraph will be the printers.
CRITICAL ITEMS. 10.1. In addition to the Scope of Work and Attachments, the items listed in this section are critical to the success of the project. These items will be used in evaluating and scoring the proposal. Vendor proposal should address items in this section in enough detail to provide evaluators an accurate understanding of vendor capabilities. Proposals that fail to sufficiently respond to these items may be considered non-responsive.
CRITICAL ITEMS. All Seller hardware associated with the Server, Seller supplied interfaces, and Capture Stations that prohibit the Buyer from performing their day to day duties associated with the capture and storage of mug photo images or as defined as System Downtime under paragraph D.6.1 shall be considered as CRITICAL ITEMS. The only hardware exception to this paragraph will be the printers.

Related to CRITICAL ITEMS

  • Critical Illness Three (3) days per year, with pay, shall be granted in the case of a critical illness or accident to a member of the employee's immediate family as defined in Section 9.4.2. A statement by the physician verifying the need for the employee to be present with the immediate family member shall be attached to the absence form.

  • SHOP DRAWINGS, PRODUCT DATA AND SAMPLES 4.12.1 Shop Drawings are drawings, diagrams, schedules and other, data specially prepared for the Work by the Contractor or any Subcontractor, manufacturer, supplier or distributor to illustrate some portion of the Work. 4.12.2 Product Data are illustrations, standard schedules, performance charts, instructions, brochures, diagrams and other information furnished by the Contractor to illustrate a material, product or system for some portion of the Work. 4.12.3 Samples are physical examples which illustrate materials, equipment or workmanship and establish standards by which the Work will be judged. 4.12.4 The Contractor shall review, approve and submit, with reasonable promptness and in such sequence as to cause no delay in the Work or in the work of the State or any separate contractor, all Shop Drawings, Product Data and Samples required by the Contract Documents. 4.12.5 By approving and submitting Shop Drawings, Product Data and Samples, the Contractor represents that he / she has determined and verified all materials, field measurements, and field construction criteria related thereto, or will do so, and that he / she has checked and coordinated the information contained within such submittals with the requirements of the Work and of the Contract Documents. 4.12.6 The Contractor shall not be relieved of responsibility for any deviation from the requirements of the Contract Documents by the Architect's approval of Shop Drawings, Product Data or Samples under Subparagraph 2.2.7 of these General Conditions unless the Contractor has specifically informed the Architect and the State in writing of such deviation at the time of sub- mission and the Architect and the State has given written approval to the specific deviation. The Contractor shall not be relieved from responsibility for errors or omissions in the Shop Drawings, Product Data or Samples by the Architect's approval thereof. 4.12.7 The Contractor shall direct specific attention, in writing or on resubmitted Shop Drawings, Product Data or Samples, to revisions other than those requested by the Architect on previous submittals. 4.12.8 No portion of the Work requiring submission of a Shop Drawing, Product Data or Sample shall be commenced until the submittal has been approved by the Architect as provided in Subparagraph 2.2.7 of these General Conditions. All such portions of the Work shall be in accordance with approved submittals.

  • Review Systems; Personnel It will maintain business process management and/or other systems necessary to ensure that it can perform each Test and, on execution of this Agreement, will load each Test into these systems. The Asset Representations Reviewer will ensure that these systems allow for each Review Receivable and the related Review Materials to be individually tracked and stored as contemplated by this Agreement. The Asset Representations Reviewer will maintain adequate staff that is properly trained to conduct Reviews as required by this Agreement.

  • Contract Database Metadata Elements Title: Xxxxxxx-Xxx Xxxxx Central School District and Xxxxxxx-Xxx Xxxxx Teachers Association (2007)

  • Critical Accounting Policies The section entitled “Management’s Discussion and Analysis of Financial Condition and Results of Operations” in the Time of Sale Prospectus and the Prospectus accurately and fairly describes (i) the accounting policies that the Company believes are the most important in the portrayal of the Company’s financial condition and results of operations and that require management’s most difficult subjective or complex judgment; (ii) the material judgments and uncertainties affecting the application of critical accounting policies and estimates; (iii) the likelihood that materially different amounts would be reported under different conditions or using different assumptions and an explanation thereof; (iv) all material trends, demands, commitments and events known to the Company, and uncertainties, and the potential effects thereof, that the Company believes would materially affect its liquidity and are reasonably likely to occur; and (v) all off-balance sheet commitments and arrangements of the Company and its Controlled Entities, if any. The Company’s directors and management have reviewed and agreed with the selection, application and disclosure of the Company’s critical accounting policies as described in the Registration Statement, the Time of Sale Prospectus and the Prospectus and have consulted with its independent accountants with regards to such disclosure.

  • Technical Objections to Grievances It is the intent of both Parties of this Agreement that no grievance shall be defeated merely because of a technical error, other than time limitations in processing the grievance through the grievance procedure. To this end, an arbitration board shall have the power to allow all necessary amendments to the grievance and the power to waive formal procedural irregularities in the processing of a grievance, in order to determine the real matter in dispute and to render a decision according to equitable principles and the justice of the case.

  • Service Content SORACOM Air Global Service contains the following services. Subscription (plan) Content plan01s It is suitable for IoT/M2M equipment. plan01s - Low Data Volume It is suitable for IoT/M2M equipment. Especially, it is suitable for small data usage. plan01 plan01 can be purchased in the USA and Japan. It is characterized by a wide coverage area. plan01 - Low Data Volume plan01 - Low Data Volume can be purchased in the USA and Japan. It is suitable for small data usage. plan02 plan02 can be purchased in Europe. Data communication charges are kept low in Europe and it is suitable for use in Europe. Subscription (Speed Class) Content s1 class Data Transmission Service that adjusts the outgoing and incoming transmission speed between the terminal and SORACOM so that the transmission is symmetrical

  • Shop Drawings and Samples After checking and verifying all field measurements, the CM will submit to the AE and Owner for approval, in accordance with the acceptable schedule of Shop Drawing submission, five copies of all Shop Drawings, which shall have been checked by and stamped with the approval of the CM and identified as the AE may require. The data shown on the Shop Drawings will be complete with respect to dimensions, design criteria, materials of construction and the like to enable the AE to review the information as required. The CM will also submit to the AE for approval with such promptness as to cause no delay in the Work, all samples required by the Contract Documents. All samples will have been checked by and stamped with the approval of the CM, identified clearly as to material, manufacturer, any pertinent numbers and the use for which intended. (a) At the time of each submission, the CM will in writing call the AE's attention to any deviations that the Shop Drawing or sample may have from the requirements of the Contract Documents and, in addition, shall cause a specific notation to be made on each shop drawing submitted for review and approval of each such variation. The AE will review and approve with reasonable promptness Shop Drawings and Samples, but its review and approval shall be only for conformance with the design concept of the PROJECT and for compliance with the information given in the Contract Documents. The approval of a separate item as such will not indicate approval of the assembly in which the item functions. The CM will make any corrections required by the AE and will return the required number of corrected copies of Shop Drawings and resubmit new samples until approved. All cost incurred for the resubmitted shop drawing shall be the CM responsibility. The CM's stamp of approval on any Shop Drawing or sample shall constitute a representation to the AE that the CM has either determined and verified all quantities, dimensions, field construction criteria, materials, catalog numbers and similar data or he assumes full responsibility for doing so, and that he has reviewed or coordinated each Shop Drawing or sample with the requirements of the Work and the Contract Document. No work requiring a Shop Drawing or sample submissions shall be commenced until the submission has been approved by the AE. Any related work performed prior to review and approval by the Owner of the pertinent submission will be sole expense and responsibility of the CM. A copy of each approved Shop Drawing and each approved sample shall be kept in good order by the CM at the site and shall be available to the AE. The AE approval of Shop Drawings or samples shall not relieve the CM from his responsibility for any deviations from the requirements of the Contract Documents, unless the CM has in writing called the AE's attention to such deviation at the time of submission and the Owner and the AE have given written approval to the specific deviation; or shall any approval by the AE relieve the CM from responsibility for errors or omissions in the Shop Drawings.

  • Changes in Equipment, Systems, Etc USBFS reserves the right to make changes from time to time, as it deems advisable, relating to its systems, programs, rules, operating schedules and equipment, so long as such changes do not adversely affect the services provided to the Trust under this Agreement.

  • Review Systems The Asset Representations Reviewer will maintain and utilize an electronic case management system to manage the Tests and provide systematic control over each step in the Review process and ensure consistency and repeatability among the Tests.