Inclement Weather 24.1 This Inclement Weather clause sets out the full rights, obligations and entitlements of the parties and establishes the conditions under which payment for periods of inclement weather shall be made.
24.2 This Inclement Weather clause is to be read and observed in lieu of the provisions of the award and VBIA.
24.3 Definition – inclement weather Inclement weather shall mean the existence of rain or abnormal climatic conditions (whether they be those of hail, snow, cold, high wind, severe dust storm, extreme high temperature or the like or any combination thereof) by virtue of which it is either not reasonable or not safe for employees exposed thereto to continue working whilst the same prevail.
Weather User understands and agrees that during the term of this agreement, User will strictly adhere to the Weather Protocols set forth in the Grand Park Emergency Management Plan. The Grand Park Emergency Management Plan is made available on the Grand Park website or by request a copy may be provided by the Commission. In the event of inclement weather, the Commission will retain final determination as to the ability of the facility to support the Event.
a. If the facility is unable to support the event due to an "Act of God" the Commission will not provide a refund or credit to the User. User may obtain event insurance through a vendor of their choosing to cover the "Act of God" scenario.
b. If the facility is deemed unable to support the event by the Commission, the Commission will work with the User to reschedule such activity as was affected by the facility closure. In such case that the activity may not be rescheduled, Commission will credit the User for such activity as was affected by the closure and allow the credit to be utilized toward a future event.
c. If the facility is deemed unable to support the event by the User, the Commission will work with the User to reschedule such activity as was affected within the general time constraints of the User's Event. In such case that the activity may not be rescheduled, Commission will not credit the User.
Emergencies 10.3.1 In any emergency affecting the safety of persons or property, the Contractor shall act to prevent threatened damage, injury or loss. Any additional compensation or extension of time claimed by the Contractor on account of emergency work shall be determined as provided in Article 12 for Changes in the Work.
Wet Weather In the event of wet weather, work in the open will continue until the particular work in hand can no longer be done safely and efficiently. Whilst it is raining, employees will be required to: Continue to work under cover or relocate to alternative work under cover, on site. Obtain materials and services for employees working under cover where there is only minimal exposure to inclement weather. When required, perform emergency and safety work. In addition, work on unexpected breakdowns, which can be corrected in limited time duration. Should a portion of the project be affected by wet weather, all other employees not so affected shall continue working in accordance with award conditions, regardless that some employees may be entitled to cease work due to wet weather. If a halt to productive work occurs due to inclement weather, the parties agree that employees may be relocated to other unaffected sites. Where the above steps are not possible, affected employees may be required to attend tool box meetings, work planning sessions or skills development activities, all of which will count as productive time for payment purposes.
Completion of Concrete Pours and Emergency Work (a) Except as provided in this sub-clause an Employee shall nor work or be required to work in the rain.
(b) Employees shall not be required to start a concrete pour in Inclement Weather.
(c) Where a concrete pour has been commenced prior to the commencement of a period of Inclement Weather Employees may be required to complete such concrete pour to a practical stage and for such work shall be paid at the rate of double time calculated to the next hour, and in the case of wet weather shall be provided with adequate wet weather gear.
(d) If an Employee’s clothes become wet as a result of working in the rain during a concrete pour the Employee shall, unless the Employee has a change of dry working clothes available, be allowed to go home without loss of pay.
(e) The provisions of clauses 32.7(c) and 32.7(d) hereof shall also apply in the case of emergency work where the Employees concerned and their delegates agree that the work is of an emergency nature and can start and/or proceed.
Evacuation (1) If the Combatant Commander orders a mandatory evacuation of some or all personnel, the Government will provide assistance, to the extent available, to United States and third country national contractor personnel.
(2) In the event of a non-mandatory evacuation order, unless authorized in writing by the Contracting Officer, the Contractor shall maintain personnel on location sufficient to meet obligations under this contract.
Adverse Weather Shall be only weather that satisfies all of the following conditions: (1) unusually severe precipitation, sleet, snow, hail, or extreme temperature or air conditions in excess of the norm for the location and time of year it occurred based on the closest weather station data averaged over the past five years, (2) that is unanticipated and would cause unsafe work conditions and/or is unsuitable for scheduled work that should not be performed during inclement weather (i.e., exterior finishes), and (3) at the Project.
Interruptions There shall be no abatement of rent and Lessor shall not be liable in any respect whatsoever for the inadequacy, stoppage, interruption or discontinuance of any utility or service due to riot, strike, labor dispute, breakdown, accident, repair or other cause beyond Lessor's reasonable control or in cooperation with governmental request or directions.
Service Interruptions The Company may need to interrupt Your access to the Website to perform maintenance or emergency services on a scheduled or unscheduled basis. You agree that Your access to the Website may be affected by unanticipated or unscheduled downtime, for any reason, but that the Company shall have no liability for any damage or loss caused as a result of such downtime.
SAVINGS/FORCE MAJEURE A Force Majeure occurrence is an event or effect that cannot be reasonably anticipated or controlled and is not due to the negligence or willful misconduct of the affected party. Force Majeure includes, but is not limited to, acts of God, acts of war, acts of public enemies, terrorism, strikes, fires, explosions, actions of the elements, floods, or other similar causes beyond the control of the Contractor or the Commissioner in the performance of the Contract where non- performance, by exercise of reasonable diligence, cannot be prevented. The affected party shall provide the other party with written notice of any Force Majeure occurrence as soon as the delay is known and provide the other party with a written contingency plan to address the Force Majeure occurrence, including, but not limited to, specificity on quantities of materials, tooling, people, and other resources that will need to be redirected to another facility and the process of redirecting them. Furthermore, the affected party shall use its commercially reasonable efforts to resume proper performance within an appropriate period of time. Notwithstanding the foregoing, if the Force Majeure condition continues beyond thirty (30) days, the Parties shall jointly decide on an appropriate course of action that will permit fulfillment of the Parties’ objectives hereunder. The Contractor agrees that in the event of a delay or failure of performance by the Contractor, under the Contract due to a Force Majeure occurrence:
a. The Commissioner may purchase from other sources (without recourse to and by the Contractor for the costs and expenses thereof) to replace all or part of the Products which are the subject of the delay, which purchases may be deducted from the Contract quantities without penalty or liability to the State, or
b. The Contractor will make commercially reasonable efforts to provide Authorized Users with access to Products first in order to fulfill orders placed before the Force Majeure event occurred. The Commissioner agrees that Authorized Users shall accept allocated performance or deliveries during the occurrence of the Force Majeure event. Neither the Contractor nor the Commissioner shall be liable to the other for any delay in or failure of performance under the Contract due to a Force Majeure occurrence. Any such delay in or failure of performance shall not constitute default or give rise to any liability for damages. The existence of such causes of such delay or failure shall extend the period for performance to such extent as determined by the Contractor and the Commissioner to be necessary to enable complete performance by the Contractor if reasonable diligence is exercised after the cause of delay or failure has been removed. Notwithstanding the above, at the discretion of the Commissioner where the delay or failure will significantly impair the value of the Contract to the State or to Authorized Users, the Commissioner may terminate the Contract or the portion thereof which is subject to delays, and thereby discharge any unexecuted portion of the Contract or the relative part thereof. In addition, the Commissioner reserves the right, in his/her sole discretion, to make an equitable adjustment in the Contract terms and/or pricing should extreme and unforeseen volatility in the marketplace affect pricing or the availability of supply. "Extreme and unforeseen volatility in the marketplace" is defined as market circumstances which meet the following criteria: (i) the volatility is due to causes outside the control of Contractor; (ii) the volatility affects the marketplace or industry, not just the particular Contract source of supply; (iii) the effect on pricing or availability of supply is substantial; and (iv) the volatility so affects Contractor's performance that continued performance of the Contract would result in a substantial loss. Failure of the Contractor to agree to any adjustment shall be a dispute under the Disputes clause; provided however, that nothing in this clause shall excuse the Contractor from performing in accordance with the Contract as changed.
