Corrective Measures If the Participating Generator fails to meet or maintain the requirements set forth in this Agreement and/or the CAISO Tariff, the CAISO shall be permitted to take any of the measures, contained or referenced in the CAISO Tariff, which the CAISO deems to be necessary to correct the situation.
Accidents If a death, serious personal injury or substantial property damage occurs in connection with CONTRACTOR’s performance of this Agreement, CONTRACTOR shall immediately notify Mendocino County Risk Manager's Office by telephone. CONTRACTOR shall promptly submit to COUNTY a written report, in such form as may be required by COUNTY of all accidents which occur in connection with this Agreement. This report must include the following information: (1) name and address of the injured or deceased person(s); (2) name and address of CONTRACTOR's sub-contractor, if any; (3) name and address of CONTRACTOR's liability insurance carrier; and (4) a detailed description of the accident and whether any of COUNTY's equipment, tools, material, or staff were involved.
SAVINGS/FORCE MAJEURE A Force Majeure occurrence is an event or effect that cannot be reasonably anticipated or controlled and is not due to the negligence or willful misconduct of the affected party. Force Majeure includes, but is not limited to, acts of God, acts of war, acts of public enemies, terrorism, strikes, fires, explosions, actions of the elements, floods, or other similar causes beyond the control of the Contractor or the Commissioner in the performance of the Contract where non- performance, by exercise of reasonable diligence, cannot be prevented. The affected party shall provide the other party with written notice of any Force Majeure occurrence as soon as the delay is known and provide the other party with a written contingency plan to address the Force Majeure occurrence, including, but not limited to, specificity on quantities of materials, tooling, people, and other resources that will need to be redirected to another facility and the process of redirecting them. Furthermore, the affected party shall use its commercially reasonable efforts to resume proper performance within an appropriate period of time. Notwithstanding the foregoing, if the Force Majeure condition continues beyond thirty (30) days, the Parties shall jointly decide on an appropriate course of action that will permit fulfillment of the Parties’ objectives hereunder. The Contractor agrees that in the event of a delay or failure of performance by the Contractor, under the Contract due to a Force Majeure occurrence:
a. The Commissioner may purchase from other sources (without recourse to and by the Contractor for the costs and expenses thereof) to replace all or part of the Products which are the subject of the delay, which purchases may be deducted from the Contract quantities without penalty or liability to the State, or
b. The Contractor will make commercially reasonable efforts to provide Authorized Users with access to Products first in order to fulfill orders placed before the Force Majeure event occurred. The Commissioner agrees that Authorized Users shall accept allocated performance or deliveries during the occurrence of the Force Majeure event. Neither the Contractor nor the Commissioner shall be liable to the other for any delay in or failure of performance under the Contract due to a Force Majeure occurrence. Any such delay in or failure of performance shall not constitute default or give rise to any liability for damages. The existence of such causes of such delay or failure shall extend the period for performance to such extent as determined by the Contractor and the Commissioner to be necessary to enable complete performance by the Contractor if reasonable diligence is exercised after the cause of delay or failure has been removed. Notwithstanding the above, at the discretion of the Commissioner where the delay or failure will significantly impair the value of the Contract to the State or to Authorized Users, the Commissioner may terminate the Contract or the portion thereof which is subject to delays, and thereby discharge any unexecuted portion of the Contract or the relative part thereof. In addition, the Commissioner reserves the right, in his/her sole discretion, to make an equitable adjustment in the Contract terms and/or pricing should extreme and unforeseen volatility in the marketplace affect pricing or the availability of supply. "Extreme and unforeseen volatility in the marketplace" is defined as market circumstances which meet the following criteria: (i) the volatility is due to causes outside the control of Contractor; (ii) the volatility affects the marketplace or industry, not just the particular Contract source of supply; (iii) the effect on pricing or availability of supply is substantial; and (iv) the volatility so affects Contractor's performance that continued performance of the Contract would result in a substantial loss. Failure of the Contractor to agree to any adjustment shall be a dispute under the Disputes clause; provided however, that nothing in this clause shall excuse the Contractor from performing in accordance with the Contract as changed.
Ameliorative Allocations Any special allocations of income or gain pursuant to Sections 5.05(b) or 5.05(c) hereof shall be taken into account in computing subsequent allocations pursuant to Section 5.04 and this Section 5.05(g), so that the net amount of any items so allocated and all other items allocated to each Partner shall, to the extent possible, be equal to the net amount that would have been allocated to each Partner if such allocations pursuant to Sections 5.05(b) or 5.05(c) had not occurred.
Catastrophic Leave Program Leave credits, as defined below, may be transferred from one (1) or more employees to another employee, on an hour-for-hour basis, in accordance with departmental policies upon the request of both the receiving employee and the transferring employee and upon approval of the employee's appointing authority, under the following conditions:
A. The receiving employee is required to be absent from work due to injury or the prolonged illness of the employee, employee's spouse, registered domestic partner, a domestic partner listed on an “Affidavit for Enrollment of Domestic Partners,” submitted to employee benefits, parent or child, has exhausted all earned leave credits, including but not limited to sick leave, compensatory time, holiday credits and disability leave and is therefore facing financial hardship.
B. The transfers must be for a minimum of four (4) hours and in whole hour increments thereafter.
C. Transfers shall be allowed to cross-departmental lines in accordance with the policies of the receiving department.
D. The total maximum leave credits received by an employee shall normally not exceed five hundred twenty (520) hours; however, if approved by his/her appointing authority, the total leave credits may be up to one thousand forty (1,040) hours. Total leave credits in excess of one thousand forty (1,040) hours will be considered on a case-by-case basis by the appointing authority subject to the approval of the Chief Administrative Officer.
E. The transfers are irrevocable, and will be indistinguishable from other leave credits belonging to the receiving employee. Transfers will be subject to all taxes required by law.
F. Leave credits that may be transferred under this program are defined as the transferring employee’s vacation credits or up to twenty-four (24) hours of sick leave per fiscal year.
G. Transfers shall be administered according to the rules and regulations of the Auditor and Controller, and made on a form prescribed by the Auditor and Controller. Approvals of the receiving and donating employee, the donating employee's appointing authority and the receiving employee's appointing authority (in the case of an interdepartmental transfer) will be provided for on such form.
H. This program is not subject to the Grievance Procedure of this Agreement.
Corrective Allocations In the event of any allocation of Additional Book Basis Derivative Items or any Book-Down Event or any recognition of a Net Termination Loss, the following rules shall apply:
(A) In the case of any allocation of Additional Book Basis Derivative Items (other than an allocation of Unrealized Gain or Unrealized Loss under Section 5.5(d) hereof), the General Partner shall allocate additional items of gross income and gain away from the holders of Incentive Distribution Rights to the Unitholders and the General Partner, or additional items of deduction and loss away from the Unitholders and the General Partner to the holders of Incentive Distribution Rights, to the extent that the Additional Book Basis Derivative Items allocated to the Unitholders or the General Partner exceed their Share of Additional Book Basis Derivative Items. For this purpose, the Unitholders and the General Partner shall be treated as being allocated Additional Book Basis Derivative Items to the extent that such Additional Book Basis Derivative Items have reduced the amount of income that would otherwise have been allocated to the Unitholders or the General Partner under the Partnership Agreement (e.g., Additional Book Basis Derivative Items taken into account in computing cost of goods sold would reduce the amount of book income otherwise available for allocation among the Partners). Any allocation made pursuant to this Section 6.1(d)(xii)(A) shall be made after all of the other Agreed Allocations have been made as if this Section 6.1(d)(xii) were not in this Agreement and, to the extent necessary, shall require the reallocation of items that have been allocated pursuant to such other Agreed Allocations.
(B) In the case of any negative adjustments to the Capital Accounts of the Partners resulting from a Book-Down Event or from the recognition of a Net Termination Loss, such negative adjustment (1) shall first be allocated, to the extent of the Aggregate Remaining Net Positive Adjustments, in such a manner, as determined by the General Partner, that to the extent possible the aggregate Capital Accounts of the Partners will equal the amount that would have been the Capital Account balance of the Partners if no prior Book-Up Events had occurred, and (2) any negative adjustment in excess of the Aggregate Remaining Net Positive Adjustments shall be allocated pursuant to Section 6.1(c) hereof.
(C) In making the allocations required under this Section 6.1(d)(xii), the General Partner may apply whatever conventions or other methodology it determines will satisfy the purpose of this Section 6.1(d)(xii).
Termination Due to Force Majeure Event If the period of Force Majeure continues or is in the reasonable judgment of the Parties likely to continue beyond a period of 120 (one hundred and twenty) Days, the Parties may mutually decide to terminate this Agreement or continue this Agreement on mutually agreed revised terms. If the Parties are unable to reach an agreement in this regard, the Affected Party shall after the expiry of the said period of 120 (one hundred and twenty ) Days be entitled to terminate the Agreement in which event, the provisions of Articles 16 and 17 shall, to the extent expressly made applicable, apply.
Termination due to Force Majeure 13.5.1 If the Force Majeure Event or its effects continue to be present beyond the period as specified in Article 4.5.3, either Party shall have the right to cause termination of the Agreement. In such an event, this Agreement shall terminate on the date of such Termination Notice.
Emergency/Declared Disaster Requirements In the event of an emergency or if Orange County is declared a disaster area by the County, state or federal government, this Contract may be subjected to unusual usage. The Contractor shall service the County during such an emergency or declared disaster under the same terms and conditions that apply during non-emergency/disaster conditions. The pricing quoted by the Contractor shall apply to serving the County’s needs regardless of the circumstances. If the Contractor is unable to supply the goods/services under the terms of the Contract, then the Contractor shall provide proof of such disruption and a copy of the invoice for the goods/services from the Contractor’s supplier(s). Additional profit margin as a result of supplying goods/services during an emergency or a declared disaster shall not be permitted. In the event of an emergency or declared disaster, emergency purchase order numbers will be assigned. All applicable invoices from the Contractor shall show both the emergency purchase order number and the Contract number.
How Do I Correct an Excess Contribution? If you make a contribution in excess of your allowable maximum, you may correct the excess contribution and avoid the 6% penalty tax under Section 4973 of the Internal Revenue Code for that year by withdrawing the excess contribution and its earnings on or before the due date, including extensions, of the tax return for the tax year for which the contribution was made (generally October 15th). Any earnings on the withdrawn excess contribution may be subject to a 10% early distribution penalty tax if you are under age 59½. In addition, in certain cases an excess contribution may be withdrawn after the time for filing your tax return. Finally, excess contributions for one year may be carried forward and applied against the contribution limitation in succeeding years.
