Payment of Cost of Tenant’s Work Sample Clauses

Payment of Cost of Tenant’s Work. 1. Tenant shall pay or cause to be paid the total cost and expense of all work or improvements, as that phrase is defined in the mechanic’s lien law in effect at the place of construction when the work begins. No such payment shall be construed as rent. Tenant shall not permit to be enforced against the Premises or any part of it any mechanic’s, materialman’s, contractor’s or subcontractor’s lien arising out of any work or improvements, however it may arise. Landlord reserves a right to post and record notice of non-responsibility in conformity with California law. However, Tenant may in good faith and at Tenant’s own expense, contest the validity of any such asserted lien, claim or demand, provided Tenant has furnished the bond required by any statute enacted for providing a bond freeing the leased premises from the effect of such a lien claim. Tenant shall defend and indemnify Landlord against all liability and loss of any type arising out of work performed on the leased premises by Tenant, together with actual attorney’s fees and all costs and expenses incurred by Landlord in negotiating, settling, defending or otherwise protecting against such claims. If Tenant does not cause to be recorded the bond necessary to free the Premises from the effect of such a lien claim and a final judgment has been rendered against Tenant by a court of competent jurisdiction for the foreclosure of such a claim, and if Tenant fails to stay the execution of the judgment by lawful means or pay the judgment, Landlord shall have the right, but not the duty, to pay or otherwise discharge, stay or prevent the execution of any such judgment or lien or both. Tenant shall reimburse Landlord for all sums paid by Landlord under this Paragraph together with all Landlord’s actual attorney’s fees and costs plus interest on those sums, fees and costs at the rate of ten percent (10%) per annum from the date of payment until the date of reimbursement.
Sample 1
AutoNDA by SimpleDocs
Payment of Cost of Tenant’s Work a. Non-Cash Payment. Tenant has this day delivered to Landlord the Units in the Company described in Exhibit D, attached hereto and made a part hereof, which Units represent payment in full of the balance due to Landlord for the Tenant’s Work set forth in paragraph 7.c. of the Second Amendment to Lease in the amount of $90,000 together with additional work performed by Landlord for Tenant in the amount of $51,635 for a total of $141,635.00.
Sample 1

Related to Payment of Cost of Tenant’s Work

  • Cost of Tenant Improvements Unless specified otherwise herein, Landlord shall bear and pay the cost of the Tenant Improvements (which cost shall include, without limitation, the costs of construction, the cost of permits and permit expediting, the costs of code compliance work, if such work is required as a result of, or is a condition imposed by appropriate governmental authorities for, construction of the Tenant Improvements, and all architectural and engineering services obtained by Landlord in connection with the Tenant Improvements, the Contractor's fees, Landlord's fee for construction administration in an amount which shall not exceed three percent (3%) of hard costs, utilities, and Landlord's Insurance Costs (including, without limitation, course of construction insurance), from the date of this Work Letter until the Lease Commencement Date up to a maximum of $450,000.00 (the "Tenant Improvement Allowance"). The Tenant Improvement Allowance shall be utilized only for building improvements to the Building, and not for signage, furniture costs, any third party consulting or contracting fees, any telecom/cabling costs, or any other purpose. Tenant shall bear and pay the cost of the Tenant Improvements (including but not limited to all of the foregoing fees and costs) in excess of the Tenant Improvement Allowance, if any. The cost of the Tenant Improvements shall exclude the cost of furniture, fixtures and inventory and other items of Tenant's Work (as defined below). Tenant shall have the right to elect to increase the Tenant Improvement Allowance by up to an additional $450,000.00 (the "Additional Allowance"), subject to the following terms and conditions: (i) Tenant shall make such election, if at all, no later than August 15, 1998; (ii) such amount shall be paid to Landlord in equal monthly installments over the seven (7) year Lease Term with interest at 10%, as additional Base Monthly Rent in the manner specified by Article 3 of the Lease; and (iii) the Additional Allowance shall otherwise constitute a part of the Tenant Improvement Allowance and shall be subject to the restrictions and conditions on such Tenant Improvement Allowance provided in this Work Letter. Notwithstanding anything to the contrary contained herein or in the Lease, Landlord shall be responsible at its sole cost and expense for the incremental costs incurred by either Landlord or Tenant for asbestos removal within the interior of the Leased Premises required solely as a result of the construction of the Tenant Improvements. 5.

  • Construction of Tenant Improvements Promptly following approval of the Final TI Working Drawings, Landlord shall apply for and use reasonable efforts to obtain the necessary permits and approvals to allow construction of Landlord’s TI Work. Upon receipt of such permits and approvals, Landlord shall, at Tenant’s expense (subject to the application of the Tenant Improvement Allowance provided in this Workletter, and subject to any other applicable provisions of the Lease or of this Workletter expressly making any specific item of expense or cost the responsibility of Landlord), diligently construct and complete Landlord’s TI Work substantially in accordance with the Approved TI Plans, subject to Unavoidable Delays and Tenant Delays (if any). Such construction shall be performed in a good and workmanlike manner and shall conform to all applicable governmental codes, laws and regulations in force at the time such work is completed. Without limiting the generality of the foregoing, Landlord shall be responsible for compliance of Landlord’s TI Work with the requirements of the Americans with Disabilities Act and all similar or related requirements pertaining to access by persons with disabilities, but nothing in this sentence shall be construed to make Landlord responsible for bearing the cost of any such compliance, to the extent the compliance work is reasonably attributable to or related to the particular nature or design of the Tenant Improvements or is for any other reason expressly made Tenant’s cost or responsibility under any applicable provision of the Lease or of this Workletter. Landlord shall have the right, in its sole discretion, to decide whether and to what extent to use union labor on or in connection with Landlord’s Work, and shall use the TI General Contractor to construct all of Landlord’s TI Work. Landlord and Tenant shall each have a right to approve all subcontractors engaged in connection with the construction of the Tenant Improvements and to review and approve all competitive bids for any elements of the Tenant Improvements, such approval in each instance not to be unreasonably withheld, conditioned or delayed by either party.

  • Tenant Improvement Costs The Tenant Improvements’ cost (the “Tenant Improvement Costs”) shall mean and include any and all costs and expenses of the Work, including, without limitation, all of the following:

  • Construction of the Tenant Improvements Landlord shall construct the Tenant Improvements in accordance with this exhibit and the construction contract to be executed by Landlord and its contractor(s). The construction contract for constructing the Tenant Improvements and the contractor(s) to perform the work shall be approved and/or selected, as the case may be, by Landlord at its sole and absolute discretion without the consent of Tenant.

  • Disbursement of Tenant Improvement Allowance During the construction of the Tenant Improvements, Landlord shall make monthly disbursements of the Tenant Improvement Allowance for Tenant Improvement Allowance Items for the benefit of Tenant and shall authorize the release of monies for the benefit of Tenant as follows.

  • Construction of Improvements (A) Lessee warrants and agrees that the Building will be constructed on the Leased Premises, and all other improvements to the land, including the parking lot, approaches, and service areas, will be constructed in all material respects by Lessee substantially in accordance with the plot, plans, and specifications heretofore submitted to Lessor.

  • Tenant’s Work During the Term Tenant may not perform any work, alterations, installations, additions, improvements, structural repairs or restorations to the Property (“Tenant’s Work”) without the prior written consent of Landlord which (i) in the case of alterations, additions, installations or improvements of a structural nature or involving the Building systems, may be granted or withheld by Landlord in its sole and absolute discretion and (ii) in the case of alterations or improvements of a non-structural nature or not involving Building systems, shall not be unreasonably withheld or delayed. In connection with such consent, Tenant shall submit to Landlord such detailed plans, specifications, drawings and other materials reasonably requested by Landlord. Tenant may make such non-structural alterations and perform work of a decorative nature without Xxxxxxxx’s prior written consent. At Tenant’s sole cost, Xxxxxxxx agrees to cooperate with Xxxxxx (including signing applications) in obtaining any necessary permits for any Tenant’s Work that Xxxxxx is permitted to make hereunder. In all cases the Tenant’s Work shall be performed at Tenant’s sole cost and expense and by contractors selected by Xxxxxx. Tenant agrees that the Tenant’s plans and specifications shall be in compliance with applicable laws, rules and regulations, that Tenant shall not commence construction until it obtains (if required) a building permit for Tenant’s Work, and that such Tenant’s Work shall be performed in accordance with the building permit, in compliance with applicable law and in accordance with the Tenant’s plans and specifications. As a condition of approving such Tenant's Work the Landlord may require the Tenant to maintain such additional insurance coverages (in addition to those required in Article 8 hereof) as the Landlord may reasonably require.

  • Tenant Repairs and Maintenance Tenant shall, at its expense, throughout the Term, (i) maintain and preserve, in first-class condition (subject to normal and customary wear and tear), the Premises and the fixtures and appurtenances therein (including, but not limited to, the Premises' plumbing and HV AC systems, all doors, overhead or otherwise, glass and levelers located in the Premises or otherwise available in the Property for Tenant's sole use; and excluding, however, those components of the Premises for which Landlord is expressly responsible under Section 13.2); and (ii) maintain, in full force and effect, a preventative maintenance and service contract with a reputable 'service provider for maintenance of the HV AC systems of the Premises. Tenant shall also be responsible for all cost and expenses incurred to perform any and all repairs and replacements (whether structural or non-structural; interior or exterior; and ordinary or extraordinary), in and to the Premises and the Property and the facilities and systems thereof, if and to the extent that the need for such repairs or replacements arises directly or indirectly from any or all of: (a) the performance or existence of any Alterations, (b) the installation, use or operation of Tenant's Property in the Premises, (c) the moving of Tenant's Property in or out of the Property, and (d) any act, omission, misuse, or neglect of Tenant, any of its subtenants, or others entering into the Premises by act or omission of Tenant or any subtenant. Any repairs or replacements required to be made by Tenant to any or all of the structural components of the property and the :mechanical, electrical, sanitary; HVAC, or other systems of the Property or Premises shall be performed by appropriately licensed contractors approved by Landlord, which approval shall not be unreasonably withheld. All such repairs or replacements shall be subject to the supervision and control of Landlord, and all repairs and replacements shall be made with materials of equal or better quality than the items being repaired or replaced.

  • Tenant Improvements Subject to this Section 4, Tenant shall accept the Suite 110 Premises in its “as is” condition (subject to Landlord's continuing repair and maintenance obligations, as outlined in Section 10 of the Lease (as may be amended)), and Landlord shall have no obligation to make any alterations or improvements thereto whatsoever (provided that Landlord shall deliver same in good and tenantable condition, broom clean, with all systems serving same in good working order). Any alterations that Tenant desires to make in the Suite 110 Premises shall be subject to all the terms and conditions set forth in Section 11 of the Lease. Notwithstanding anything in the Lease to the contrary, Landlord hereby agrees to grant Tenant an allowance in the amount of $10,000 to be applied toward the cost (including architectural and engineering fees) of alterations performed by Tenant in the Suite 110 Premises (the “Granted Allowance”) in conjunction with Tenant’s initial occupancy of Suite 110 Premises. Provided no Event of Default then exists under the Lease, the Granted Allowance (or portions thereof) shall be disbursed to Tenant within thirty (30) days following Tenant's submission to Landlord of paid invoices for work related to alterations performed by Tenant in the Suite 110 Premises, accompanied by waivers of liens executed by all contractors employed by Tenant for the performance of such work. If the cost of Tenant's alterations in the Suite 110 Premises exceeds the amount of the Granted Allowance, the excess shall be paid by Tenant after the Granted Allowance is fully exhausted. Any portion of the Granted Allowance that has not been applied (or contracted to be applied) in the manner set forth above by the date which is twelve (12) months following the Eighth Amendment Commencement Date shall revert to Landlord, and Tenant shall have no further rights with respect thereto.

  • Completion of Improvements Landlord, through its general contractor (“Contractor”), shall furnish and install within the Premises those items of general design, engineering and construction, shown on the final plans and specifications approved by Landlord and Tenant pursuant to the Schedule of Approvals below, in compliance with all applicable laws, ordinances, codes, rules and regulations and matters of record, and complete any construction required in the Common Areas of the Building when such construction is required by or arises out of completion of such work (collectively the “Improvements”). The contractor constructing the Improvements in the Premises shall be selected pursuant to a procedure whereby the final Plans and Specifications (as such term is defined in this Exhibit B) are submitted to Xxxxxxx Xxxxxx Builders, Inc. (“XXX”) and Pinnacle Contracting Corporation (collectively, the “Approved Contractors”), who shall be requested to each submit to Landlord and to Tenant a sealed contract bid using such forms reasonably acceptable to Landlord in order to provide an “apples to apples” bidding process. The sealed bids shall be delivered to Tenant and Landlord and opened jointly by Landlord and Xxxxxx. Tenant, in Tenant’s sole and absolute discretion, shall select the Contractor from the two Approved Contractors (regardless of which has the lower bid). Each bid from the contractors shall specify any allowances for exclusions and shall further provide that said bids are without overtime premiums or bonuses necessary to complete the Improvements in accordance with the terms hereof. The architect engaged by Xxxxxx to prepare the Space Plan and Plans and Specifications and related design work for the Improvements shall be Xxxxxxx (the “Architect”). Landlord shall disburse amounts of the Allowance (up to the maximum specified below) to Architect within thirty (30) days after receipt of paid invoices from Architect or Tenant for Architect’s services; provided, however, notwithstanding the foregoing, Landlord shall pay $[***] for the Architect’s preparation of the Space Plan (as evidenced by the Architect’s invoice number 68045 dated October 15, 2010), at Landlord’s sole cost and expense (and without using the Allowance or any portion thereof). The definition of Improvements shall include all costs associated with completing the Improvements, including but not limited to, fees payable to Xxxxxxx, space planning, design, architectural, and engineering fees, contracting, labor and material costs, municipal fees, plan check and permit costs, and document development and/or reproduction, and all costs and expenses for any construction manager(s) engaged by Xxxxxx (provided such soft costs for architectural and engineering services charged against the Allowance shall not exceed $[***] per square feet of Usable Area in the Premises) at Tenant’s sole option. The Space Plan and the Plans and Specifications (each as defined in Section 3 of this Exhibit B) shall be subject to Landlord’s prior review and approval, which approval shall not be unreasonably withheld, conditioned or delayed. Landlord’s approval of any iteration of a Space Plan or Plans and Specifications shall be deemed granted unless Landlord provides a reasonable disapproval or approval to Tenant prior to the sixth (6th) business day after Landlord’s receipt of the Space Plan or Plans and Specifications. Without limiting Landlord’s discretion to reasonably withhold its approval, Tenant agrees that it shall be reasonable for Landlord to withhold its approval of any aspect of Tenant’s Space Plan or Plans and Specifications (or, in either case, any proposed changes thereto) which (i) adversely affect Building systems, the structure of the Building or the safety of the Building and/or its occupants, (ii) would violate any governmental laws, rules or ordinances; (iii) would require any changes that adversely impact the base, shell and core of the Building, and/or (iv) are inconsistent with the standards of first class office buildings in the vicinity of the Building, as reasonably determined by Landlord and the Contractor. Landlord shall provide a written statement of any disapproval of any Space Plan or Plans and Specifications stating the reasons for Xxxxxxxx’s disapproval. Tenant acknowledges and agrees that any change in the scope of work or details of construction after Xxxxxx’s and Landlord’s approval of the Plans and Specifications shall constitute a “Change Order”, the costs of which may be charged against any available amounts of the Allowance under this Exhibit B. To the extent the Change Order delays construction of the Improvements, the same shall be a Tenant Delay. [***] = CONFIDENTIAL INFORMATION HAS BEEN OMITTED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION. CONFIDENTIAL TREATMENT HAS BEEN REQUESTED WITH RESPECT TO THIS OMITTED INFORMATION.

Time is Money Join Law Insider Premium to draft better contracts faster.