Name Collision Occurrence Management 6.1. No-‐Activation Period. Registry Operator shall not activate any names in the DNS zone for the Registry TLD (except for "NIC") until at least 120 calendar days after the effective date of this agreement. Registry Operator may allocate names (subject to subsection 6.2 below) during this period only if Registry Operator causes registrants to be clearly informed of the inability to activate names until the No-‐Activation Period ends.
Name Collision Occurrence Assessment 6.2.1 Registry Operator shall not activate any names in the DNS zone for the Registry TLD except in compliance with a Name Collision Occurrence Assessment provided by ICANN regarding the Registry TLD. Registry Operator will either (A) implement the mitigation measures described in its Name Collision Occurrence Assessment before activating any second-‐level domain name, or (B) block those second-‐level domain names for which the mitigation measures as described in the Name Collision Occurrence Assessment have not been implemented and proceed with activating names that are not listed in the Assessment. 6.2.2 Notwithstanding subsection 6.2.1, Registry Operator may proceed with activation of names in the DNS zone without implementation of the measures set forth in Section 6.2.1 only if (A) ICANN determines that the Registry TLD is eligible for this alternative path to activation of names; and (B) Registry Operator blocks all second-‐level domain names identified by ICANN and set forth at <xxxx://xxxxxxxx.xxxxx.xxx/en/announcements-‐and-‐ media/announcement-‐2-‐17nov13-‐en> as such list may be modified by ICANN from time to time. Registry Operator may activate names pursuant to this subsection and later activate names pursuant to subsection 6.2.1. 6.2.3 The sets of names subject to mitigation or blocking pursuant to Sections 6.2.1 and 6.2.2 will be based on ICANN analysis of DNS information including "Day in the Life of the Internet" data maintained by the DNS Operations, Analysis, and Research Center (DNS-‐OARC) <xxxxx://xxx.xxx-‐xxxx.xxx/xxxx/xxxx/xxxx>. 6.2.4 Registry Operator may participate in the development by the ICANN community of a process for determining whether and how these blocked names may be released. 6.2.5 If ICANN determines that the TLD is ineligible for the alternative path to activation of names, ICANN may elect not to delegate the TLD pending completion of the final Name Collision Occurrence Assessment for the TLD, and Registry Operator’s completion of all required mitigation measures. Registry Operator understands that the mitigation measures required by ICANN as a condition to activation of names in the DNS zone for the TLD may include, without limitation, mitigation measures such as those described in Section 3.2 of the New gTLD Name Collision Occurrence Management Plan approved by the ICANN Board New gTLD Program Committee (NGPC) on 7 October 2013 as found at <xxxx://xxx.xxxxx.xxx/en/groups/board/documents/resolutions-‐ new-‐gtld-‐annex-‐1-‐07oct13-‐en.pdf>.
Extension of Sick Leave Unless an employee otherwise requests in writing, an employee who has used up her sick leave credits shall be granted advanced sick leave with pay for a period up to fifteen (15) days subject to the deduction of such advanced leave from any sick leave credits subsequently earned.
Sick Leave Use An employee shall be granted sick leave with pay to the extent of the employee's accumulation for absences necessitated by the following conditions:
Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).
Act of God Days Act of God" days beyond the allowance by Michigan Law and the Department of Education regulations will be made up by the students and assistants at the end of the school year or at other times as specified by the calendar. Assistants will only receive compensation for the "Act of God" days allowed. When a scheduled day of schoolwork is delayed, association members shall report as near as possible to their regular starting times. Assistants will receive their full day's pay when the school day is shortened due to weather or mechanical problems.
Accrual of Sick Leave a. A full-time employee shall accrue four (4) hours of sick leave for each biweekly pay period, or the number of hours that are directly proportionate to the number of days worked during less than a full-pay period, without limitation as to the total number of hours that may be accrued. b. A part-time employee shall accrue sick leave at a rate directly proportionate to the percent of time employed. c. An employee appointed under Other Personal Services (OPS) shall not accrue sick leave.
Tenant Delay Except as otherwise provided in the Lease, Delivery of the Premises shall occur when Landlord’s Work has been Substantially Completed, except to the extent that completion of Landlord’s Work shall have been actually delayed by any one or more of the following causes (“Tenant Delay”): (i) Tenant’s Representative was not available to give or receive any Communication or to take any other action required to be taken by Tenant hereunder within a reasonable period of time (not to exceed 2 business days) after written request from Landlord; (ii) Tenant’s request for changes to the Building Shell, whether or not such changes are actually performed; (iii) The construction of any changes to the Building Shell requested by Tenant and agreed upon by Landlord; (iv) Tenant’s request for Change Requests (as defined in Section 4(a) below) whether or not any such Change Requests are actually performed; (v) Construction of any Change Requests; (vi) Tenant’s request for materials, finishes or installations requiring unusually long lead times (provided Landlord will request that the General Contractor inform Tenant of any long lead time items and identify substitutes for such items as soon as reasonably possible); (vii) Tenant’s delay in reviewing, revising or approving plans and specifications beyond the periods set forth herein; (viii) Tenant’s delay in providing any information that is reasonably required to come from Tenant which is critical to the normal progression of the Project within a reasonable period of time after request. Tenant shall provide such information as soon as reasonably possible, but in no event longer than one week after receipt of any request for such information from Landlord; (ix) Tenant’s delay in making payments to Landlord for Excess TI Costs (as defined in Section 5(d) below) for more than 10 business days after such Excess TI Costs are required to be paid to Landlord; or (x) Any other act or omission by Tenant or any Tenant Party (as defined in the Lease), or persons employed by any of such persons that continues for more than 1 business day after Landlord’s notice thereof to Tenant. If Delivery is delayed for any of the foregoing reasons, then Landlord shall cause the TI Architect to certify the date on which the Tenant Improvements would have been Substantially Completed but for such Tenant Delay and such certified date shall be deemed to be the Commencement Date for purposes of Tenant’s obligation to pay Base Rent, Operating Expenses, Excess TI Costs and TI Rent; however, Tenant will not have any obligation to pay any amounts to third parties pursuant to the Lease (and will not occupy the Premises) until the date upon which the Premises is Delivered to Tenant with the Landlord’s Work Substantially Complete. Upon request, Landlord shall advise Tenant of any materials, finishes or installations which are required as part of any Change Request that will result in unusually long lead times.
Tenant Default (a) Any of the following occurrences or acts shall constitute an “Event of Default” (herein so called) under this Lease: if (i) Tenant shall fail to pay any scheduled installment of Fixed Rent or Additional Rent when due and such failure shall continue uncured for a period of ten (10) days after Landlord notifies Tenant in writing of such failure (each an “Installment Default Notice”); or if, within a twelve (12) month period following delivery of not less than two (2) Installment Default Notices by Landlord, Tenant shall fail to pay any scheduled installment of Fixed Rent or Additional Rent when due and such failure shall continue uncured for a period of five (5) days or (ii) Tenant shall default in the payment when due of any installment of Additional Rent payable hereunder and such default shall continue for ten (10) days after notice of such default is sent to Tenant by Landlord (or Lender); or (iii) the failure by Tenant to maintain insurance as required under this Lease; or (iv) Tenant shall default in fulfilling any of the other covenants, agreements or obligations of this Lease, and such default shall continue for more than thirty (30) days after written notice thereof from Landlord (or Lender) specifying such default, provided, that if Tenant has commenced to cure a default described in subparagraph (iv) above within said thirty (30) days, and thereafter is in good faith diligently prosecuting same to completion and such default is of a nature such that it cannot be cured within such thirty (30) day period, said thirty (30) day period shall be extended, for a reasonable time (not to exceed an additional ninety (90) days) or, with respect to a breach of Tenant’s obligations under Section 40 of this Part II, such longer period as may reasonably be necessary to cure such default so long as (A) Tenant delivers to Landlord a certificate of a qualified environmental remediation specialist that such default could not be cured within such one hundred eighty (180) days but is curable, and (B) Tenant is in good faith diligently prosecuting such cure to completion) where, due to the nature of a default, it is unable to be completely cured within thirty (30) days; or (v) any execution or attachment shall be issued against Tenant or any of its property whereby the Premises shall be taken or occupied or attempted to be taken or occupied by someone other than Tenant, and the same shall not be bonded, dismissed, or discharged as promptly as possible under the circumstances; or (vi) Tenant or Guarantor (A) shall make any assignment or other similar act for the benefit of creditors, (B) shall file a petition or take any other action seeking relief under any state or federal insolvency or bankruptcy Laws, or (C) shall have an involuntary petition or any other action filed against either of them under any state or federal insolvency or bankruptcy Laws which petition or other action is not vacated or dismissed within sixty (60) days after the commencement thereof; or (vii) the estate or interest of Tenant in the Premises shall be levied upon or attached in any proceeding and such estate or interest is about to be sold or transferred and such process shall not be vacated or discharged within sixty (60) days after such levy or attachment; or (viii) the Guarantor’s guaranty of Tenant’s obligations under this Lease is terminated for any reason, or the Guarantor asserts in any pleading or judicial or administrative proceeding that such guaranty is void or unenforceable or that Guarantor is not liable thereunder; or (ix) any material representation or warranty made by Tenant or Guarantor to Landlord or the Lender herein or in any document delivered pursuant to this Lease is misleading or false in material respect when made, or (x) a default beyond applicable notice and cure periods shall occur in the fulfillment of any of the covenants, agreements or obligations of the tenant under any of the Related Leases and the premises demised thereby are then owned by the entity that is Landlord on the Lease Commencement Date or by one of its Affiliates. (b) If an Event of Default shall have occurred and be continuing, Landlord shall be entitled to all remedies available at law or in equity. Without limiting the foregoing, Landlord shall have the right to give Tenant notice of Landlord’s termination of the Term of this Lease. Upon the giving of such notice, the Term of this Lease and the estate hereby granted shall expire and terminate on such date as fully and completely and with the same effect as if such date were the date herein fixed for the expiration of the Term of this Lease, and all rights of Tenant hereunder shall expire and terminate, but Tenant shall remain liable as hereinafter provided. (c) If an Event of Default shall have occurred and be continuing, Landlord shall have the immediate right, whether or not the Term of this Lease shall have been terminated pursuant to Section 23(b) of this Part II, to re-enter and repossess the Premises and the right to remove all persons and property therefrom by summary proceedings, ejectment, any other legal action or in any lawful manner Landlord determines to be necessary or desirable. Landlord shall be under no liability by reason of any such reentry, repossession or removal. No such re-entry, repossession or removal shall be construed as an election by Landlord to terminate this Lease unless a notice of such termination is given to Tenant pursuant to Section 23(b) of this Part II. (d) At any time or from time to time after a re-entry, repossession or removal pursuant to Section 23(c) of this Part II, whether or not the Term of this Lease shall have been terminated pursuant to Section 23(b) of this Part II, Landlord may (but, except to the extent expressly required by any applicable Law, shall be under no obligation to) relet the Premises for the account of Tenant, in the name of Tenant or Landlord or otherwise, without notice to Tenant, for such term or terms and on such conditions and for such uses as Landlord, in its absolute discretion, may determine. Landlord may collect any rents payable by reason of such reletting. Landlord shall not be liable for any failure to relet the Premises or for any failure to collect any rent due upon any such reletting, provided, however, that Landlord agrees to use reasonable efforts to relet the Premises for such rent and upon such terms as are not unreasonable under the circumstances, and if the full rental provided herein plus the reasonable costs, expenses and damages hereafter described shall not be realized by Landlord, Tenant shall be liable for all damages sustained by Landlord, including, without limitation, deficiency in base rent and additional rent, reasonable attorney’s fees, brokerage fees, and the expenses of placing the Premises in rentable condition. (e) No expiration or termination of the Term of this Lease pursuant to Section 23(b) of this Part II, by operation of law or otherwise, and no re-entry, repossession or removal pursuant to Section 23(c) of this Part II or otherwise, and no reletting of the Premises pursuant to Section 23(d) of this Part II or otherwise, shall relieve Tenant of its liabilities and obligations hereunder, all of which shall survive such expiration, termination, re-entry, repossession, removal or reletting. (f) In the event of any expiration or termination of the Term of this Lease or re-entry or repossession of the Premises or removal of persons or property therefrom by reason of the occurrence of an Event of Default, Tenant shall pay to Landlord all Fixed Rent, Additional Rent and other sums required to be paid by Tenant, in each case together with interest thereon at the Lease Default Rate from the due date thereof to and including the date of such expiration, termination, re-entry, repossession or removal; and thereafter, Tenant shall, until the end of what would have been the Term of this Lease in the absence of such expiration, termination, re-entry, repossession or removal and whether or not the Premises shall have been relet, be liable to Landlord for, and shall pay to Landlord, as liquidated and agreed current damages: (i) all Fixed Rent, Additional Rent and other sums which would be payable under this Lease by Tenant in the absence of any such expiration, termination, re-entry, repossession or removal, less (ii) the net proceeds, if any, of any reletting effected for the account of Tenant pursuant to Section 23(d) of this Part II, after deducting from such proceeds all reasonable expenses of Landlord in connection with such reletting, including, without limitation, all repossession costs, brokerage commissions, reasonable attorneys’ fees and expenses (including, without limitation, fees and expenses of appellate proceedings), alteration costs and expenses of preparation for such reletting. Tenant shall pay such liquidated and agreed current damages on the dates on which Fixed Rent would be payable under this Lease in the absence of such expiration, termination, re-entry, repossession or removal, and Landlord shall be entitled to recover the same from Tenant on each such date. At any time after any such expiration or termination of the Term of this Lease or re-entry or repossession of the Premises or removal of persons or property thereon by reason of the occurrence of an Event of Default, whether or not Landlord shall have collected any liquidated and agreed current damages pursuant to Section 23(f) of this Part II, Landlord shall be entitled to recover from Tenant, and Tenant shall pay to Landlord on demand, as and for liquidated and agreed final damages for Tenant’s default and in lieu of all liquidated and agreed current damages beyond the date of such demand (it being agreed that it would be impracticable or extremely difficult to fix the actual damages), an amount equal to the sum of (i) the excess, if any of (A) the aggregate of all Fixed Rent and Additional Rent which would be payable under this Lease, in each case from the date of such demand (or, if it be earlier, the date to which Tenant shall have satisfied in full its obligations under Section 23(f) of this Part II to pay liquidated and agreed current damages) for what would be the then-unexpired Term of this Lease in the absence of such expiration, termination, re-entry, repossession or removal, discounted at the rate equal to the then rate on U.S. Treasury obligations of comparable maturity to such Term (the “Treasury Rate”), but in no event greater than the non-default rate of interest for the Loan (such lower rate being referred to as the “Discount Rate”) over (B) the amount of such rental loss that Tenant proves could be reasonably avoided by commercially reasonable mitigation efforts by Landlord, discounted at the Discount Rate for the same period, plus (ii) all reasonable legal fees and other costs and expenses incurred by Landlord as a result of Tenant’s default under this Lease. If any Law shall limit the amount of liquidated final damages to less than the amount above agreed upon, Landlord shall be entitled to the maximum amount allowable under such Law. (g) Mention in this Lease of any particular remedy shall not preclude Landlord from any other remedy at law or in equity, including the right of injunction. Tenant waives any rights of redemption granted by any Laws if Tenant is evicted or dispossessed, for any cause, or if Landlord obtains possession of the Premises by reason of the violation by Tenant of any of the terms of this Lease. In addition, Tenant, on its own behalf and for its legal representatives, successors and assigns, and on behalf of all persons claiming through or under this Lease, together with creditors of all classes, and all other persons having an interest therein, does hereby waive, surrender and give up all right or privilege which it may or might have by reason of any present or future Law or decision, to redeem the Premises or have a continuance of this Lease for any part of the Term hereof after having been dispossessed or ejected therefrom by process of law or otherwise. (h) In addition to the foregoing remedies set forth in this Section 23 and all other remedies available at law or in equity, and regardless of whether or not an Event of Default has occurred under this Lease, if Tenant has failed to perform any of its duties, obligations, covenants or agreements under this Lease, Landlord may give notice to Tenant that it has failed to perform any such duty, obligation, covenant or agreement (herein called a “Notice of Breach”) and may thereafter pursue any rights or remedies available to it at law or in equity including, without limitation, filing a suit for damages as a result of such breach or a suit for specific performance of any such duties, obligations, covenants or agreements. Any Notice of Breach delivered under this Section 23(h) or any such rights or remedies pursued by Landlord shall not be deemed to be a notice of default under any provision of this Section 23 and shall not result, with or without the passage of time, in an Event of Default existing under this Lease; provided, that the delivery of any such Notice of Breach shall not limit Landlord’s right (which right will not be exercised without the consent of Lender so long as the Premises are subject to a Mortgage which requires Lender’s consent for the exercise thereof) to subsequently deliver notice (with respect to the same event or condition which is the subject of such Notice of Breach or any other event or condition) which will declare or, with the passage of time, result in an Event of Default hereunder.
Cumulative Sick Leave The normal cumulative sick leave allowance each year shall be ten (10) days for employees on thirty-eight (38) through forty-two (42) week assignments. Teachers on eleven (11) and twelve (12) month assignments shall receive one (1) day per month up to a maximum of twelve (12) days each year. A teacher shall be permitted to carry forward the unused portion of sick leave without limit. The balance of accumulated sick leave shall be printed on the teacher's bi-weekly statement of earnings.