Change of Contract Times. 17.2.1 The Contract Times (or Milestones) may only be changed by a Change Order. Approved Changes in the Contract Times or accepted Claims that affect the Contract Times will be addressed through the Change Order process provided in this Agreement.
17.2.2 Any adjustment of the Contract Times (or Milestones) covered by a Change Order or of any Claim for an adjustment in the Contract Times (or Milestones) will be determined in accordance with the provisions of this Article.
Change of Contract Times. A. The Contract Times for authorized Work can only be changed by Change Order. Any Change Proposal for an adjustment in the Contract Times must comply with the provisions of Paragraph 11.06. Any Claim for an adjustment in the Contract Times must comply with the provisions of Article 13.
B. An adjustment of the Contract Times is subject to the limitations described in Paragraph 4.04.
Change of Contract Times. A. The Contract Times may only be changed by a Change Order. Any Claim for an adjustment in the Contract Times shall be based on written notice submitted by the party making the claim to the ENGINEER and the other party to the Contract in accordance with the provisions of Paragraph 10.05.
B. Any adjustment of the Contract Times covered by a Change Order or of any Claim for an adjustment in the Contract Times will be determined in accordance with the provisions of this Article 12.
Change of Contract Times. A. The Contract Time(s) (or Milestones) may only be changed by a Change Order. Any claim for an adjustment of the Contract Time(s) (or Milestones) shall be based on written notice pursuant to Paragraph 15.
Change of Contract Times. The Contract Times may only be changed by a Change Order. All changes in the Contract Price and/or adjustments to the Contract Times related to each change shall be included in Contractor’s change order proposal. No cost or time will be allowed for cumulative effects of multiple changes. All Change Orders must state that the Contract Time is not changed or is either increased or decreased by a specific number of days. Failure to include a change to time shall waive any change to the time unless the parties mutually agree in writing to postpone a determination of the change to time resulting from the Change Order. Notice of the amount of the request for adjustment in the Contract Times with supporting data shall be delivered within seven (7) Days after such start of occurrence, unless MTS allows an additional period of time to ascertain more accurate data in support of the request. No extension of time or additional compensation shall be given for a delay if the Contractor failed to give notice in the manner and within the time prescribed. MTS may elect, at MTS’s sole discretion, to grant an extension in Contract Times, without Contractor’s request, because of delays or other factors. Float is for the benefit of the Project. Float shall not be considered for the exclusive use or benefit of either MTS or the Contractor. Contractor shall not be entitled to compensation, and MTS will not compensate Contractor, for delays which impact early completion. Any difference in time between the Contractor’s early completion and the Contract Time shall be considered a part of the Project float. Contractor’s entitlement to an extension of the Contract Times is limited to an MTS- caused extension of the critical path, reduced by the Contractor’s concurrent delays, and established by a proper time impact analysis. No time extension shall be allowed unless, and then only to the extent that, the MTS-caused delay extends the critical path beyond the previously approved Contract Time. If approved, the increase in time required to complete the Work shall be added to the Contract Time. Contractor shall not be entitled to an adjustment in the Contract Price or Contract Times for delays within the control of Contractor. Delays attributable to and within the control of a Subcontractor or Supplier shall be deemed to be delays within the control of Contractor. If Contractor is delayed in the performance or progress of the Work by fire, flood, epidemic, abnormal weather conditions (as...
Change of Contract Times. 1. The Contract Times (or milestones) may only be changed by Change Order or Written Amendment and all time limits stated in the Contract Documents are of the essence of the Agreement. The Contract Times (or milestones) will be adjusted in an amount equal to the time lost due to the following:
a. Changes in the Work ordered by City;
b. Acts or neglect by City, or its Project Manager, acts or neglect of utility owners, acts or neglect of other Contractors performing other Work, provided Contractor has fully and completely performed its responsibilities under the Contract Documents, including but not limited to, its cooperation and coordination responsibilities required by the Contract Documents;
c. Fires, floods, unusually severe weather conditions, earthquakes, civil disturbances, or acts of God, provided damage resulting therefrom is not the result of Contractor's failure to properly protect the Work as required by the Contract Documents. Notwithstanding the foregoing, the Contract Times (or milestones) shall not be extended unless Contractor has actually been prevented from completing any part of the Work within the Contract Times (or milestones) due to delay which is (i) beyond the control of Contractor and (ii) due to reasons for which Contractor is not responsible and (iii) a claim for delay is made as provided for herein. Delays attributable to and within the control of a Subcontractor, or its subcontractors, or supplier shall be deemed to be delays within the control of Contractor.
2. Where Contractor is prevented from completing any part of the Work within the Contract Times (or milestones) due to delay beyond the control of both City and Contractor, an extension of Contract Times (or milestones) in an amount equal to the time loss due to such delay shall be the Contractor's sole and exclusive remedy for such delay. City shall not be liable to Contractor, any Subcontractor, any supplier, or any other person or organization, or to any surety for or employee or agent of any of them, for damages or extra costs of any type arising out of or resulting from (i) delays caused by or within the control of Contractor, or (ii) delays beyond the control of both parties including but not limited to fires, floods, epidemics, unusually severe weather conditions, earthquakes and acts of God or acts or neglect by utility owners or other Contractors performing other work as contemplated by Paragraph 6.
3. a. Time of completion will be extended for the number of cale...
Change of Contract Times. A. The Contract Times (or Milestones) may only be changed by a Change Order or by a Written Amendment. Any Claim for an adjustment in the Contract Times (or Milestones) shall be based on written notice submitted by the party making the claim to the Owner’s Representative and the other party to the Contract in accordance with the provisions of paragraph 10.05.
B. Any adjustment of the Contract Times (or Milestones) covered by a Change Order or of any Claim for an adjustment in the Contract Times (or Milestones) will be determined in accordance with the provisions of this Article 12.
Change of Contract Times. A. The Contract Times may only be changed by a Change Order.
Change of Contract Times. The Contract Times (or Milestones) may only be changed by a Change Order or a Written Amendment. Any claim for an adjustment of the Contract Times (or Milestones) shall be based on written notice delivered by the party making the claim to the other party and to Project Manager promptly (but in no event later than fifteen days) after the occurrence of the event giving rise to the claim and stating the general nature of the claim. Notice of the extent of the claim with supporting data shall be delivered within thirty days after such occurrence (unless Project Manager allows an additional period of time to ascertain more accurate data in support of the claim) and shall be accompanied by the claimant's written statement that the adjustment claimed is the entire adjustment to which the claimant has reason to believe it is entitled as a result of the occurrence of said event. All claims for adjustment in the Contract Times (or Milestones) shall be determined by Project Manager in accordance with paragraph 8.2.5 if the Town and Contractor cannot otherwise agree. No claim for an adjustment in the Contract Times (or Milestones) will be valid if not submitted in accordance with the requirements of this paragraph.
Change of Contract Times
