Commencement Completion. Licensee shall commence the Work on or before the date specified on the Rider and shall continue the Work uninterrupted (except for interruption by reason of events constituting force majeure) until it is completed. Notwithstanding the occurrence of any events constituting force majeure, or any other cause, the Work shall be completed and the Hotel shall be furnished, equipped, and shall otherwise be in compliance with this Agreement not later than the date specified on the Rider. Licensor shall have the sole right to determine whether the Work has been completed in accordance with this Agreement, the approved Plans, the Manual and the PIP.
Commencement Completion. You will begin the Renovation Work on or before the date specified in the Rider and will continue the Renovation Work uninterrupted (except to the extent continuation is prevented by events beyond your control, such as acts of God, third party strikes, acts of terrorism, war, or general governmental restrictions (“Force Majeure”)) until it is completed. For purposes of this Paragraph E, Force Majeure does not include your own financial inability, inability to obtain financing, inability to obtain permits or any other events unique to you or the Hotel. Notwithstanding any Force Majeure, or any other matter, the Renovation Work must be completed and the Hotel must be furnished, equipped, and comply with this Agreement no later than the date specified in the Rider (the “Renovation Work Completion Date”). We will have the sole right to determine whether the Renovation Work has been completed in accordance with this Agreement, the approved Plans and Designs, the Manual and the PIP.
Commencement Completion. You will begin the Renovation Work on or before the Renovation Commencement Date specified in the Rider and will continue the Renovation Work uninterrupted, except to the extent continuation is prevented Force Majeure, until it is completed. Notwithstanding any Force Majeure, or any other matter, the Renovation Work must be completed and the Hotel must be furnished, equipped, and comply with this Agreement no later than the Renovation Work Completion Date specified in the Rider. We will have the sole right in our business judgment to determine whether the Renovation Work has been completed in accordance with this Agreement, the approved Plans and Designs, the Standards and the PIP.
Commencement Completion. Modification and Termination of Contract 63
Commencement Completion. You will begin construction of the Hotel on or before the date specified on the Rider (the “CCD”). For the Hotel to be considered under construction by the CCD, you must have begun to pour the concrete foundations for the Hotel (or for partially or fully constructed structures, you must have otherwise satisfied our site-specific criteria for “under construction” which criteria we will provide to you in writing based on the site-specific circumstances of the structure). Your failure to begin construction by the CCD will be an Event of Default, unless we extend the CCD. If you want to request an extension of the CCD, you must submit a written request and a Ten Thousand Dollar ($10,000) extension fee before the CCD. If we approve the extension, we will set a new CCD and the extension fee will become non-refundable. If we deny the extension, we will refund the extension fee. Once begun, construction of the Hotel will continue uninterrupted (except to the extent continuation is prevented by events beyond Licensee’s control, such as acts of God, third party strikes, acts of terrorism, war, or general governmental restrictions (“Force Majeure”)) until it is completed. For purposes of this Paragraph F, Force Majeure does not include your own financial inability, inability to obtain financing, inability to obtain permits or any other events unique to you or the Hotel. Upon our request, you will promptly provide us with evidence that construction has commenced. Notwithstanding any Force Majeure, or any other matter, Construction Work must be completed and the Hotel must be furnished, equipped, and otherwise made ready to Open (as defined in Paragraph O) in accordance with this Agreement no later than the date specified on the Rider (the “Construction Work Completion Date”). If you fail to complete the Construction Work in accordance with this Agreement on or before the Construction Work Completion Date and this failure to meet the Construction Work Completion Date is due solely to Force Majeure, the Pre-Opening Termination Fee (as defined in Paragraph T below) will not be assessed. We will have the sole right to determine whether the Construction Work has begun and has been completed in accordance with this Agreement, the approved Plans, and Designs, the Manual, and our standards for System hotels.
Commencement Completion. The operation of the agreement will commence on …………201? and will be completed on ………………20?? Call-outs will be responded to within the times included in the Contractor’s tender.
Commencement Completion. 4.1 The provision of the services will be commenced on …………………. and will be completed by ……………………...
Commencement Completion. Construction of Phase 1 will commence no later than 12 months after the opening of the Temporary Facility to the general public and must be completed no later than 36 months after the opening of the Temporary Facility, in accordance with IGB requirements.
Commencement Completion. Contractor shall complete the Work within the agreed time (the “Contract Time”), provided, however, that neither party shall be responsible for delays due to causes arising from strikes, riots, inclement weather, fire, earthquake, war measures of the United States or other governments, or contingencies beyond their control. If Contractor is obstructed or delayed in the prosecution of completion of the Work due to any of: (i) neglect, delay, or fault of any other contractor having a contract with Owner for adjoining or contiguous work; (ii) abnormal weather conditions, or (iii) any delay on the part of Owner in furnishing materials or sites for the Work, or any delay not the fault of Contractor, then in any such event, Owner shall have no claim for damages for any such cause or delay, and Contractor shall be entitled to an extension of the Contract Time which is reasonable under the circumstances, and Contractor shall receive reasonable compensation for such delay.
Commencement Completion. 2.1.1. The Contractor shall commence the Work no later than the Commencement Date and shall Substantially Complete the Work no later than the Substantial Completion Date or Scheduled Completion Dates. Should the Commencement Date be changed, the Contractor shall commence work within (3) days of notification and the Work durations per the Schedule shall not change.
2.1.2. On or before the Substantial Completion Date, the Owner, the Construction Manager and the Contractor shall prepare and sign a punch list setting forth portions of the Work that are known to be incomplete or defective. The Contractor shall fully complete all of the Work, including all punchlist items, shall be completed by the Final Completion Date.
