Delays and Complaints Sample Clauses

Delays and Complaints. Delivery delays and service complaints will be monitored on a continual basis. Documented inability to perform under the conditions of the contract, via the Complaint to Vendor process (PUR 7017 form) contemplated for this Contract, may result in default proceedings and cancellation.
Sample 1Sample 2Sample 3See All (256)
AutoNDA by SimpleDocs
Delays and Complaints. The Contractor will promptly notify the Customer upon becoming aware of any circumstances that may reasonably be expected to jeopardize the timely and successful completion (or delivery) of any product, including any commodity, service, deliverable, or project. The Contractor will use commercially reasonable efforts to avoid or minimize any delays in performance and will inform the Customer of the steps the Contractor is taking or will take to do so, and the projected actual completion (or delivery) time. If the Contractor believes a delay in performance by the Customer has caused or will cause the Contractor to be unable to perform its obligations on time, the Contractor will promptly so notify the Customer and use commercially reasonable efforts to perform its obligations on time notwithstanding the Customer’s delay. (For example if a facility is on lock down) The Contractor acknowledges that untimely performance or other material non-compliance will damage the Customer, but by their nature such damages are difficult to ascertain. Accordingly, the on-going liquidated damages will apply to this Contract. Ongoing liquidated damages are not intended to be a penalty and are solely intended to compensate for damages caused by failure to complete or perform on the Contract. Documented inability to timely and successfully complete (or deliver) any Products may result in ongoing liquidated damages, default proceedings, and possible termination via the established Complaint to Vendor process (PUR 7017) per 60A-1.006 F.A.C. The Department or Customer may impose ongoing liquidated damages up to one thousand dollars ($1000.00) per calendar day of non-compliance, until such non-compliance is remedied to the satisfaction of the Department or Customer, as applicable. Ongoing liquidated damages may be adjusted based on total damages realized by the Department or Customer as specified in Section 4.6.
Sample 1Sample 2Sample 3See All (5)
Delays and Complaints. Service delays and service complaints will be monitored on a continual basis. Documented inability to perform under the conditions of the contract may result in default proceedings and/or termination.
Sample 1
Delays and Complaints. Delivery delays and service complaints will be monitored on a continual basis by the Customer. Documented inability to perform under the conditions of the Contract, via the established Complaint to Vendor process (PUR 7017 form), may result in default proceedings and cancellation. SPECIAL CONTRACT CONDITIONS‌ SECTION 1. DEFINITION 2 SECTION 2. CONTRACT TERM AND TERMINATION 2 SECTION 3. PAYMENT AND FEES. 3 SECTION 4. CONTRACT MANAGEMENT 4 SECTION 5. COMPLIANCE WITH LAWS 6 SECTION 6. MISCELLANEOUS. 8 SECTION 7. WORKERS’ COMPENSATION AND GENERAL LIABILITY INSURANCE, AND INDEMNIFICATION 9 SECTION 8. PUBLIC RECORDS, TRADE SECRETS, DOCUMENT MANAGEMENT AND INTELLECTUAL PROPERTY. 10 SECTION 9. DATA SECURITY AND SERVICES. 12 SECTION 10. GRATUITIES, LOBBYING, AND COMMUNICATIONS 14 SECTION 11. CONTRACT MONITORING 14 SECTION 12. CONTRACT AUDITS 16 SECTION 13. BACKGROUND SCREENING AND SECURITY 17 SECTION 14. INFORMATION TECHNOLOGY 18
Sample 1

Related to Delays and Complaints

  • Complaints If you have a complaint relating to the sale of energy by us to you, or this contract generally, you may lodge a complaint with us in accordance with our standard complaints and dispute resolution procedures. Note: Our standard complaints and dispute resolution procedures are published on our website.

  • Customer Complaints Each party hereby agrees to promptly provide to the other party copies of any written or otherwise documented complaints from customers of Dealer received by such party relating in any way to the Offering (including, but not limited to, the manner in which the Shares are offered by the Dealer Manager or Dealer), the Shares or the Company.

  • Complaints and Appeals As a Premera member, you have the right to offer your ideas, ask questions, voice complaints and request a formal appeal to reconsider decisions we have made. Our goal is to listen to your concerns and improve our service to you. If you need an interpreter to help with oral translation, please call us. Customer Service will be able to guide you through the service. We would like to hear from you. If you have an idea, suggestion, or opinion, please let us know. You can contact us at the addresses and telephone numbers found on the back cover. Please call us when you have questions about a benefit or coverage decision, our services, or the quality or availability of a healthcare service. We can quickly and informally correct errors, clarify benefits, or take steps to improve our service. We suggest that you call your provider of care when you have questions about the healthcare they provide.

  • Adverse Events Subsequent to the date hereof, there shall not have occurred any of the following: (i) a suspension or material limitation in trading in securities generally on the New York Stock Exchange, the NASDAQ National Market or the NASDAQ Global Market, (ii) a general moratorium on commercial banking activities in the People’s Republic of China or New York, (iii) the outbreak or escalation of hostilities involving the United States or the People’s Republic of China or the declaration by the United States or the People’s Republic of China of a national emergency or war if the effect of any such event specified in this clause (iii) in your reasonable judgment makes it impracticable or inadvisable to proceed with the public offering or the delivery of the Shares on the terms and in the manner contemplated in the Prospectus, or (iv) such a material adverse change in general economic, political, financial or international conditions affecting financial markets in the United States or the People’s Republic of China having a material adverse impact on trading prices of securities in general, as, in your reasonable judgment, makes it impracticable or inadvisable to proceed with the public offering of the Shares or the delivery of the Shares on the terms and in the manner contemplated in the Prospectus.

  • Grievance on Layoffs and Recalls Grievances concerning layoffs and recalls shall be initiated at Step 2 of the grievance procedure.

  • COMPLAINT PROCEDURES CONTRACTOR shall maintain and adhere to its written procedures for responding to parent complaints. These procedures shall include annually notifying and providing parents of LEA students with appropriate information (including complaint forms) for the following: (1) Uniform Complaint Procedures pursuant to Title 5 of the California Code of Regulations section 4600 et seq.; (2) Nondiscrimination policy pursuant to Title 5 of the California Code of Regulations section 4960 (a); (3) Sexual Harassment Policy, California Education Code 231.5 (a) (b) (c); (4) Title IX Pupil Grievance Procedure, Title IX 106.8 (a) (d) and 106.9 (a); and (5) Notice of Privacy Practices in compliance with Health Insurance Portability and Accountability Act (HIPAA), if applicable. CONTRACTOR shall include verification of these procedures to the LEA upon request. CONTRACTOR shall immediately notify LEA of any complaints filed against it related to LEA students and provide LEA with all documentation related to the complaints and/or its investigation of complaints, including any and all reports generated as a result of an investigation.

  • Grievances Where an Employee alleges that she has been suspended or discharged in violation of Article 23.01, she may within ten (10) days of the date on which she was notified in writing or within twenty (20) days of the date of her discharge or suspension, whichever is later, invoke the grievance procedure including provisions for Arbitration contained in Article 26, and for the purpose of a grievance, alleging violation of Article 23.01 she may lodge her grievance at the final level of the grievance procedure.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!