General Conditions (i) Each party will make each payment or delivery specified in each Confirmation to be made by it, subject to the other provisions of this Agreement.
(ii) Payments under this Agreement will be made on the due date for value on that date in the place of the account specified in the relevant Confirmation or otherwise pursuant to this Agreement, in freely transferable funds and in the manner customary for payments in the required currency. Where settlement is by delivery (that is, other than by payment), such delivery will be made for receipt on the due date in the manner customary for the relevant obligation unless otherwise specified in the relevant Confirmation or elsewhere in this Agreement.
(iii) Each obligation of each party under Section 2(a)(i) is subject to (1) the condition precedent that no Event of Default or Potential Event of Default with respect to the other party has occurred and is continuing, (2) the condition precedent that no Early Termination Date in respect of the relevant Transaction has occurred or been effectively designated and (3) each other applicable condition precedent specified in this Agreement.
General Conditions Applicable to Option to Build If the Interconnection Customer assumes responsibility for the design, procurement and construction of the Participating TO's Interconnection Facilities and Stand Alone Network Upgrades,
(1) the Interconnection Customer shall engineer, procure equipment, and construct the Participating TO's Interconnection Facilities and Stand Alone Network Upgrades (or portions thereof) using Good Utility Practice and using standards and specifications provided in advance by the Participating TO;
(2) The Interconnection Customer’s engineering, procurement and construction of the Participating TO's Interconnection Facilities and Stand Alone Network Upgrades shall comply with all requirements of law to which the Participating TO would be subject in the engineering, procurement or construction of the Participating TO's Interconnection Facilities and Stand Alone Network Upgrades;
(3) the Participating TO shall review, and the Interconnection Customer shall obtain the Participating TO’s approval of, the engineering design, equipment acceptance tests, and the construction of the Participating TO's Interconnection Facilities and Stand Alone Network Upgrades, which approval shall not be unreasonably withheld, and the CAISO may, at its option, review the engineering design, equipment acceptance tests, and the construction of the Participating TO's Interconnection Facilities and Stand Alone Network Upgrades;
(4) prior to commencement of construction, the Interconnection Customer shall provide to the Participating TO, with a copy to the CAISO for informational purposes, a schedule for construction of the Participating TO's Interconnection Facilities and Stand Alone Network Upgrades, and shall promptly respond to requests for information from the Participating TO;
(5) at any time during construction, the Participating TO shall have the right to gain unrestricted access to the Participating TO's Interconnection Facilities and Stand Alone Network Upgrades and to conduct inspections of the same;
(6) at any time during construction, should any phase of the engineering, equipment procurement, or construction of the Participating TO's Interconnection Facilities and Stand Alone Network Upgrades not meet the standards and specifications provided by the Participating TO, the Interconnection Customer shall be obligated to remedy deficiencies in that portion of the Participating TO's Interconnection Facilities and Stand Alone Network Upgrades;
(7) the Interconnection Customer shall indemnify the CAISO and Participating TO for claims arising from the Interconnection Customer's construction of the Participating TO's Interconnection Facilities and Stand Alone Network Upgrades under the terms and procedures applicable to Article 18.1
General Condition The Aircraft will:
(a) be clean by international airline standards;
(b) have installed the full complement of engines and other material equipment, parts and accessories and loose equipment required under the Agreed Maintenance Program and installed in the other Boeing/XxXxxxxxx Xxxxxxx MD-87 aircraft operated by Lessee (together with any additions and improvements thereto, or replacements thereof, effected pursuant to and in accordance with this Agreement) and be in a condition suitable for immediate operation in commercial service;
(c) be airworthy, conform to type design and be in a condition for safe operation with all equipment, components and systems operating in accordance with their intended use and within limits established by the manufacturer and approved by the Aviation Authority, and all pilot discrepancies and deferred maintenance items cleared on a terminating action basis;
(d) have a U.S. Standard Transport Category Certificate of Airworthiness issued by the FAA in accordance with FAR Part 129 (or if required by the Lessor, be eligible for a valid export certificate of airworthiness with respect to the Aircraft issued by the Aviation Authority) and unconditionally meet all FAA requirements for immediate operations under FAR Part 129;
(e) comply with the manufacturer's original specification to the extent that it so complied on the date of this Agreement and subject to any alterations made pursuant to and in accordance with this Agreement after such date;
(f) have undergone, immediately prior to redelivery, the MSG-3 equivalent of a "C" Check in accordance with the Agreed Maintenance Program so that all Airframe inspections falling due within the next 3,000 hours, 3,000 cycles or twelve months (whichever is applicable and most limiting) of operation in accordance with the Agreed Maintenance Program have been accomplished;
(g) if the Flight Hours of the Airframe remaining until the scheduled completion of the Major Checks (collectively, a "Complete Heavy Work Package") on the Expiry Date are:
(i) less than on the Delivery Date, then the Lessee shall pay to the Lessor an amount equal to the product of (a) the number of Flight Hours remaining until the scheduled completion of a Complete Heavy Work Package as of the Expiry Date that are less than the number of Flight Hours that were remaining until the scheduled completion of a Complete Heavy Work Package as of the Delivery Date (b) multiplied by US$50.00, provided, however, that no payment shall be due from -------- ------- Lessee under this clause (g)(i) if, immediately preceding the redelivery of the Aircraft, the Lessee has performed a Complete Heavy Work Package;
(ii) more than on the Delivery Date, then the Lessor shall pay to the Lessee an amount equal to the product of (a) the number of Flight Hours remaining until the scheduled completion of a Complete Heavy Work Package as of the Expiry Date that are more than the number of Flight Hours that were remaining until the scheduled completion of a Complete Heavy Work Package as of the Delivery Date (b) multiplied by US$50.00; For the avoidance of doubt, any amounts due to the Lessor pursuant to this clause (g) may be set off against any amounts due to Lessee pursuant to paragraphs (b) or (d) of Schedule 10 and a payment made for the net amount due;
(h) have complied with all airworthiness directives and mandatory orders affecting that model of Aircraft issued by the Aviation Authority (and, if different, the FAA) that are required terminating action during the Term;
(i) no special or unique manufacturer inspection or check requirements specific to the Aircraft will exist unless there is no terminating action available from any source;
(j) have installed all applicable vendor's and manufacturer's service bulletin kits received free of charge by the Lessee that are appropriate for the Aircraft and, to the extent not installed, those kits which have been received with respect to this Aircraft will be furnished free of charge to the Lessor;
(k) be free of any system-related leaks which are outside maintenance manual limitations;
(l) all fluid reservoirs (including fuel, oil, oxygen, hydraulic and water) will be full, and the waste tank serviced in accordance with the manufacturer's instructions;
(m) if required under the Approved Maintenance Program, all fuel tanks will have recently undergone an anti-fungus/biological growth contamination laboratory evaluation, and any excessive levels of contamination corrected;
(n) have an FAA-approved aging aircraft program in operation and up-to-date; and
(o) have all signs and decals clean, secure and legible.
GENERAL WORKING CONDITIONS Section 18-1. Employment begins and ends at each project site.
Section 18-2. The selection of craft foremen and/or general foremen and the number of foremen required shall be entirely the responsibility of the Employer, it being understood that in the selection of such foremen and/or general foremen the Employer will give primary consideration to the qualified individuals available in the local area. After giving such consideration, the Employer may select such individuals from other areas. All foremen shall take orders from the designated Employer representatives. Craft foremen shall be designated working foremen at the request of the Employer.
Section 18-3. There shall be no limit on production by employees nor restrictions on the full use of tools or equipment. Employees using tools shall perform any of the work of the trade and shall work under the direction of the craft foremen. There shall be no restrictions on efficient use of manpower other than as may be required by safety regulations.
Section 18-4. Employees shall be at their place of work at the starting time and shall remain at their place of work performing their assigned functions under the supervision of the Employer until quitting time. The parties reaffirm their policy of a fair day’s work for a fair day’s wage.
Section 18-5. All equipment assigned to a project shall be under the control of the Employer. The Employer shall have the right to determine how many pieces of equipment an individual employee shall operate. In an emergency, foremen shall operate any equipment assigned by the Employer, and there shall be no restriction on foremen in the use of the tools of his or her craft in such emergency. The foremen shall be from the craft normally operating the equipment. In accordance with currently recognized craft jurisdiction, the Employer shall determine the assignment of employees to start, stop, and maintain small portable construction equipment. Such work may be assigned to craft employees within a reasonable distance of their primary duties or an employee may be assigned full time to start, stop and maintain the Employer’s small, portable equipment on the job site. There shall be no over xxxxxxx of this type of equipment. The number of employees assigned to rigging and scaffolding operations shall be at the sole discretion of the Employer. The ratio of journeyperson to welders shall be determined solely by the Employer.
Section 18-6. The Employer may utilize the most efficient methods or techniques of construction, tools or other labor saving devices to accomplish the work. Practices not a part of the terms and conditions of this Agreement, stand by crews and feather bedding practices will not be recognized.
Section 18-7. It is recognized that specialized or unusual equipment may be installed and/ or serviced by individuals who have special training, skill, or qualifications and are not covered by this Agreement. Testing, inspection, or service performed on plant equipment under warranty may be performed by the vendor’s personnel.
Section 18-8. Neither the Union nor its local unions shall coerce or in any way interfere with the Owner’s personnel, operation or facilities at the plant site. The Owner’s right to contract directly with other companies for work at the plant site shall not be limited, and the Union shall cooperate and not interfere with the Employer’s operations.
Section 18-9. It is agreed that overtime is undesirable and not in the best interest of the industry or the employees; therefore, except in unusual circumstances, overtime will not be worked. Where unusual circumstances do exist, however, the Employer will have the right to assign specific employees and/or crews to perform such overtime work as is necessary to accomplish the job.
Section 18-10. There will be no rest periods, organized coffee breaks or other non-working time established during working hours.
Section 18-11. Individual seniority shall not be recognized or applied to employees working on projects under this Agreement.
Section 18-12. The Employer shall establish such reasonable project rules as the Employer deems appropriate. These rules will be reviewed at the pre-job conference and posted at the project site by the Employer, and may be amended thereafter as necessary.
General conditions precedent The agreement of the Finance Parties referred to in clause 2 (Agreement of the Finance Parties) shall be further subject to:
(a) the representations and warranties in clause 4 (Representations and warranties) being true and correct on the Effective Date as if each was made with respect to the facts and circumstances existing at such time; and
(b) no Event of Default or Default having occurred and continuing at the time of the Effective Date.
General Conditions Applicable to Insurance All policies of insurance required by this section shall comply with the following requirements:
General Conditions Costs Contractor is entitled to receive payment for the actual cost of the allowable General Conditions items incurred after receipt of a Notice to Proceed with Construction from Owner through Substantial Completion of the Project, plus 30 calendar days. Contractor is not entitled to reimbursement for General Conditions Costs incurred before receipt of the Notice to Proceed. General Conditions Costs incurred after Substantial Completion, plus 30 calendar days, must be approved in advance by Owner. Allowable General Conditions items are identified below and in Exhibit “D” attached to this Agreement. These items shall be included in the General Conditions Cost amount shown as a line item in the Guaranteed Maximum Price Proposal and as detailed on the Schedule of Values. Items not specifically included below or in Exhibit “D” will not be allowed as General Condition Costs.
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
General Compliance This Agreement is intended to comply with Section 409A or an exemption thereunder and shall be construed and administered in accordance with Section 409A. Notwithstanding any other provision of this Agreement, payments provided under this Agreement may only be made upon an event and in a manner that complies with Section 409A or an applicable exemption. Any payments under this Agreement that may be excluded from Section 409A either as separation pay due to an involuntary separation from service or as a short-term deferral shall be excluded from Section 409A to the maximum extent possible. For purposes of Section 409A, each installment payment provided under this Agreement shall be treated as a separate payment. Any payments to be made under this Agreement upon a termination of employment shall only be made upon a “separation from service” under Section 409A. Notwithstanding the foregoing, the Company makes no representations that the payments and benefits provided under this Agreement comply with Section 409A, and in no event shall the Company be liable for all or any portion of any taxes, penalties, interest, or other expenses that may be incurred by the Executive on account of non-compliance with Section 409A.
Geographic Area and Sector Specific Allowances, Conditions and Exceptions The following allowances and conditions shall apply where relevant. Where the Employer does work which falls under the following headings, the Employer agrees to pay and observe the relevant respective conditions and/or exceptions set out below in each case.
