MINIMUM INFORMATION REQUIRED OF TENANT CONSTRUCTION DOCUMENTS Sample Clauses

MINIMUM INFORMATION REQUIRED OF TENANT CONSTRUCTION DOCUMENTS. The completed Phase I Tenant Construction Documents will include Architectural, Structural (if required due to the scope of work), Mechanical, Electrical, Plumbing and Fire Protection sheets, including specifications, details and elevations necessary to fully describe the leasehold improvements. The Phase I Tenant Construction Documents will be prepared, sealed and stamped by a State of Georgia registered architect and mechanical, electrical and plumbing engineers. The completed Phase I Tenant Construction Documents will be marked “For Construction.” The standard size for all drawings will be 30” x 42.” Designers will include all information on the plan sheets so that users do not have to refer to separate specification booklets to obtain information. At a minimum, the Architectural and MEP Construction Documents will include the following information: 1. Floor Plan with the location and type of all partitions (1/8 = 1’-0” scale). 2. Location and type of all doors with hardware and keying information provided (door and hardware schedule). 3. Location and type of glass partitions, windows and framing. 4. Location of telephone equipment room (note type of telephone system, square feet of mounting boards and HVAC and electrical requirements). 5. Critical dimensions necessary for construction. 6. Location of all Building Standard electrical items—outlets, switches, telephone outlets. 7. Reflected ceiling plan showing location and switching of all Building Standard lighting, exit signs, emergency lighting and life safety devices. 8. Location and type of all non-Building Standard electrical items, including lighting, security and data/voice communication work. 9. Location and type of equipment that will require special electrical requirements (i.e., dedicated circuits, data, GFI, etc.). Provide manufacturers specifications for use and operation. 10. Electrical panel schedule with total rated electrical design load calculation in xxxxx. 11. Location, weight per square foot and description of any exceptionally heavy equipment or filing system exceeding 50 pounds per square foot live load. 12. Requirement for any special air conditioning, ventilation or exhaust. 13. HVAC Reflected Ceiling Plan. 14. Mechanical equipment schedule indicating sizes, specifications and characteristics of all equipment. 15. Complete heating and cooling load calculation for all equipment. 16. Type and color of floor covering (including type of padding). 17. Location, type and color of wal...
Sample 1
AutoNDA by SimpleDocs
MINIMUM INFORMATION REQUIRED OF TENANT CONSTRUCTION DOCUMENTS. The completed Phase II Tenant Construction Documents will include Architectural, Structural (if required due to the scope of work), Mechanical, Electrical, Plumbing and Fire Protection sheets, including specifications, details and elevations necessary to fully describe the leasehold improvements. The Phase II Tenant Construction Documents will be prepared, sealed and stamped by a State of Georgia registered architect and mechanical, electrical and plumbing engineers. The completed Phase II Tenant Construction Documents will be marked “For Construction.” The standard size for all drawings will be 30” x 42.” Designers will include all information on the plan sheets so that users do not have to refer to separate specification booklets to obtain information. At a minimum, the Architectural and MEP Construction Documents will include the following information:
Sample 1
MINIMUM INFORMATION REQUIRED OF TENANT CONSTRUCTION DOCUMENTS. Floor Plans Indicating: 1. Location and type of all partitions (1/8" = 1'-0" scale). 2. Location and types of all doors with hardware and keying information provided (door and hardware schedule). 3. Location and type of glass partitions, windows and framing. 4. Location of telephone equipment room (note type of telephone system, square feet of mounting boards and HVAC and electrical requirements). 5. Critical dimensions necessary for construction. 6. Location and type of all Building Standard electrical items including outlets, switches, and telephone outlets. 7. Reflected ceiling plan showing location and switching of all Building Standard lighting, exit signs, emergency lighting and life safety devices. 8. Location and type of all non-Building Standard electrical items, including lighting, security and data/voice communication work. 9. Location and type of equipment that will require special electrical requirements (i.e., dedicated circuits, data, GFI, special grounding, etc.). Provide manufacturers specifications for use and operation. 10. Electrical panel schedule with total rated electrical design load calculation in xxxxx. 11. Location, weight per square foot and description of any exceptionally heavy equipment or filing system exceeding 50 pounds per square foot live load. 12. Requirement for any special air conditioning, ventilation or exhaust. 13. HVAC Reflected Ceiling Plan. 14. Mechanical equipment schedule indicating sizes, specifications and characteristics of all equipment. 15. Complete heating and cooling load calculation for all equipment. 16. Type and color of floor covering (including type of padding). 17. Location, type and color of wall covering. 18. Location, type and color of paint and all other finishes. 19. Location and type of plumbing (including all fixtures). 20. Location and type of kitchen, pantry or coffee bar equipment, millwork and shelving. 21. All millwork and built-in equipment fully dimensioned. 22. Corridor entrance doors and frame, as well as work required in the adjacent corridor and elevator lobby. 23. Bracing or support of special walls, glass partitions, etc. 24. All connections to or modifications of the Base Building mechanical, electrical, plumbing and fire protection systems. 25. All new mechanical, electrical and plumbing metering devices or systems.
Sample 1
MINIMUM INFORMATION REQUIRED OF TENANT CONSTRUCTION DOCUMENTS. The completed Tenant Construction Documents will include Architectural, Structural, Mechanical, Electrical, Plumbing, Fire Protection and Fire Alarm sheets (only if required by the Authority Having Jurisdiction), including specifications, details and elevations necessary to fully describe the leasehold improvements. The Tenant Construction Documents will be prepared, sealed and stamped by a registered architect and structural, mechanical, electrical and plumbing engineer in the State of Maryland. Tenant architect must furnish Landlord with a complete set of drawings in hard-copy, PDF and CAD/Revit/SketchUp (or similar software) format. Tenant architect will include all information on the plan sheets so that users do not have to refer to separate specification booklets to obtain information. At a minimum, the Tenant Construction Documents will include the following information drawn at scale: 1. Floor Plan with the location and type of all partitions. 2. Location and type of all doors with hardware and keying information. 3. Location and type of glass partitions, windows and framing. 4. Location of server/telecom room (note HVAC and electrical requirements). 5. Critical dimensions necessary for construction. 6. Location of all electrical items (outlets, switches, etc.). AFDOCS//21459967 7. Reflected ceiling plan showing location and switching of all lighting, exit signs, emergency lighting and life safety devices. 8. Location and type of all other electrical items, including security and data/voice communication work. 9. Location and type of equipment that will require special electrical requirements (i.e., dedicated circuits, data, GFI, etc.). Provide manufacturers specifications for use and operation. 10. Electrical panel schedule with total rated electrical design load calculation in xxxxx. 11. Location, weight per square foot and description of any exceptionally heavy equipment or filing system exceeding 50 pounds per square foot live load. 12. Requirement for any special air conditioning, ventilation or exhaust. 13. Reflected ceiling plan showing location of all HVAC equipment. 14. Mechanical equipment schedule indicating sizes, specifications and characteristics of all equipment. 15. [Intentionally Omitted]. 16. Location, type and color of floor covering. 17. Location, type and color of wall finishes. 18. Location, type and color of all other finishes. 19. Location and type of plumbing (including all fixtures). 20. Location and type of break room equi...
Sample 1

Related to MINIMUM INFORMATION REQUIRED OF TENANT CONSTRUCTION DOCUMENTS

  • Construction Requirements (a) All Life and Safety and applicable Building Codes will be strictly enforced (i.e., tempered glass, fire dampers, exit signs, smoke detectors, alarms, etc.). Prior coordination with the Building Manager is required. (b) Electric panel schedules must be brought up to date identifying all new circuits added. (c) All electrical outlets and lighting circuits are to be properly identified. Outlets will be labeled on back side of each cover plate. (d) All electrical and phone closets being used must have panels replaced and doors shut at the end of each day’s work. Any electrical closet that is opened with the panel exposed must have a work person present. (e) All electricians, telephone personnel, etc. will, upon completion of their respective projects, pick up and discard their trash leaving the telephone and electrical rooms clean. If this is not complied with, a clean-up will be conducted by the building janitors and the general contractor will be back-charged for this service. (f) Welding or burning with an open flame will not be done without prior approval of the Building Manager. Fire extinguishers must be on hand at all times. (g) All “anchoring” of walls or supports to the concrete are not to be done during normal working hours (7:30 AM—6:00 PM, Monday through Friday). This work must be scheduled before or after these hours during the week or on the weekend. (h) All core drilling is not to be done during normal working hours (7:30 AM—6:00 PM, Monday through Friday). This work must be scheduled before or after these hours during the week or on the weekend. (i) All HVAC work must be inspected by the Building Engineer. The following procedures will be followed by the general contractor: i) A preliminary inspection of the HVAC work in progress will be scheduled through the Building Office prior to the reinstallation of the ceiling grid. ii) A second inspection of the HVAC operation will also be scheduled through the Building Office and will take place with the attendance of the HVAC contractor’s Air Balance Engineer. This inspection will take place when the suite in question is ready to be air-balanced. [***] = CONFIDENTIAL INFORMATION HAS BEEN OMITTED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION. CONFIDENTIAL TREATMENT HAS BEEN REQUESTED WITH RESPECT TO THIS OMITTED INFORMATION. iii) The Building Engineer will inspect the construction on a periodic basis as well. (j) All existing thermostats, ceiling tiles, lighting fixtures and air conditioning grilles shall be saved and turned over to the Building Engineer.

  • Construction Documents Phase Bidding or Negotiation Phase:

  • Complete Agreement; Construction This Agreement, including the Schedules hereto, shall constitute the entire agreement between the Parties with respect to the subject matter hereof and shall supersede all previous negotiations, commitments and writings with respect to such subject matter. In the event of any inconsistency between this Agreement and any Schedule, the Schedule shall prevail. The rights and remedies of the Parties herein provided shall be cumulative and in addition to any other or further remedies provided by law or equity.

  • Construction Documents The architectural and engineering documents setting forth the design for the Project prepared by the Design Professional. Construction Documents include, but are not limited to, the Specifications, the Drawings, the Supplementary Conditions, the General Conditions, and all Addenda.

  • Connecting Transmission Owner’s Attachment Facilities Construction The Connecting Transmission Owner’s Attachment Facilities shall be designed and constructed in accordance with Good Utility Practice. Upon request, within one hundred twenty (120) Calendar Days after the Commercial Operation Date, unless the Connecting Transmission Owner and Developer agree on another mutually acceptable deadline, the Connecting Transmission Owner shall deliver to the Developer “as-built” drawings, relay diagrams, information and documents for the Connecting Transmission Owner’s Attachment Facilities set forth in Appendix A. The Connecting Transmission Owner [shall/shall not] transfer operational control of the Connecting Transmission Owner’s Attachment Facilities and Stand Alone System Upgrade Facilities to the NYISO upon completion of such facilities.

  • Applicable Law and Construction This Lease may be executed in counterparts, shall be construed as a sealed instrument, and shall be governed exclusively by the provisions hereof and by the laws of the state where the Property is located without regard to principles of choice of law or conflicts of law. A facsimile signature to this Lease shall be sufficient to prove the execution by a party. If any provisions shall to any extent be invalid, the remainder shall not be affected. Other than contemporaneous instruments executed and delivered of even date, if any, this Lease contains all of the agreements between Landlord and Tenant relating in any way to the Premises and supersedes all prior agreements and dealings between them. There are no oral agreements between Landlord and Tenant relating to this Lease or the Premises. This Lease may be amended only by instrument in writing executed and delivered by both Landlord and Tenant. The provisions of this Lease shall bind Landlord and Tenant and their respective successors and assigns, and shall inure to the benefit of Landlord and its successors and assigns and of Tenant and its permitted successors and assigns, subject to Article 13. The titles are for convenience only and shall not be considered a part of this Lease. This Lease shall not be construed more strictly against one party than against the other merely by virtue of the fact that it may have been prepared primarily by counsel for one of the parties, it being recognized that both Landlord and Tenant have contributed substantially and materially to the preparation of this Lease. If Tenant is granted any extension or other option, to be effective the exercise (and notice thereof) shall be unconditional; and if Tenant purports to condition the exercise of any option or to vary its terms in any manner, then the purported exercise shall be ineffective. The enumeration of specific examples of a general provision shall not be construed as a limitation of the general provision. Unless a party’s approval or consent is required by the express terms of this Lease not to be unreasonably withheld, such approval or consent may be withheld in the party’s sole discretion. The submission of a form of this Lease or any summary of its terms shall not constitute an offer by Landlord to Tenant; but a leasehold shall only be created and the parties bound when this Lease is executed and delivered by both Landlord and Tenant and approved by the holder of any mortgage of the Premises having the right to approve this Lease. Nothing herein shall be construed as creating the relationship between Landlord and Tenant of principal and agent, or of partners or joint venturers or any relationship other than landlord and tenant. This Lease and all consents, notices, approvals and all other related documents may be reproduced by any party by any electronic means or by facsimile, photographic, microfilm, microfiche or other reproduction process and the originals may be destroyed; and each party agrees that any reproductions shall be as admissible in evidence in any judicial or administrative proceeding as the original itself (whether or not the original is in existence and whether or not reproduction was made in the regular course of business), and that any further reproduction of such reproduction shall likewise be admissible. If any payment in the nature of interest provided for in this Lease shall exceed the maximum interest permitted under controlling law, as established by final judgment of a court, then such interest shall instead be at the maximum permitted interest rate as established by such judgment.

  • Project Construction The Contractor agrees to provide continuous on-site supervision on each Job Order, while progress on the project is being accomplished. The Contractor’s Project Manager will ensure: 1. Coordination and providing supervision to all Subcontractor and workers; 2. Posting of the prevailing wage scale; 3. Maintaining a copy of the Contractors safety program manual made available to all construction personnel; 4. Conducting weekly on-site safety meetings; 5. Completing the daily labor and construction progress log on a daily basis and submit copies to the County on a daily basis. Copies of the previous day’s reports must be submitted by 9:00AM of the following day. a. Daily labor log is to include a listing of Subcontractor(s) and a count of workers by trade providing services for the day. b. Construction progress log is to include a narrative of the Work provided by trade(s). Narrative agrees to include the various areas of the jobsite where Work was performed and any problems or conditions that were encountered. c. In the event the Contractor fails to provide a daily log and/or construction progress log, the County may impose damages against the Contractor in the amount of fifty dollars ($50.00) for each log and deduct from the Contractor’s payment request, for each day the Contractor does not provide the documentation. 6. County may suspend Contractor operations if no Contractor Superintendent is observed. All delays caused by the suspension will be the responsibility of the Contractor. No time extension or claims for cost(s) associated with the suspension will be granted by the County.

  • Award of Construction Contract and Other Future Contracts 6.2.1 A-E is hereby informed that provisions of the Public Contract Code, the Political Reform Act of 1974, other statutes, regulations, and COUNTY policy prohibit, as an impermissible conflict of interest, the award of a contract for the construction of the project(s) on which A-E performed architectural-engineering services under this A-E CONTRACT. A-E is hereby informed that these statutes and regulations could also prohibit the award to A-E of design or other contracts on future phases related to tasks performed by A-E under this CONTRACT. This prohibition applies also to a subcontractor of or parent company of the firm that performed architectural-engineering tasks under this CONTRACT.

  • During Construction Upon request of the Owner the Contractor shall submit written proposals for unit prices to be applied in the event Change Order Work is authorized by the Owner to be performed under Case (b).

  • Construction Reports Each Constructing Entity shall issue reports to each other Construction Party on a monthly basis, and at such other times as reasonably requested, regarding the status of the construction and installation of the Interconnection Facilities. Each Construction Party shall promptly identify, and shall notify each other Construction Party of, any event that the Construction Party reasonably expects may delay completion, or may significantly increase the cost, of the Interconnection Facilities. Should a Construction Party report such an event, Transmission Provider shall, within fifteen days of such notification, convene a technical meeting of the Construction Parties to evaluate schedule alternatives.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!