Settlement Amount If the Non-Defaulting Party has declared an Early Termination Date pursuant to Section 7.2(b), the Non-Defaulting Party shall have the right to (i) accelerate all amounts owing between the Defaulting Party and the Non-Defaulting Party and to liquidate and terminate the undertakings set forth in this Agreement as between the Defaulting Party and the Non-Defaulting Party; and (ii) withhold any payments due to the Defaulting Party under this Agreement pending payment of the Termination Payment. The Non-Defaulting Party will calculate, in a commercially reasonable manner, the Settlement Amount with respect to the Defaulting Party’s obligations under the Agreement and shall net the Settlement Amount in the manner provided for in Section 7.3(c).
Payment Amount Payment for the Services shall be as follows: (choose one) ☐ - $______________________ for the Services (“Payment”). ☐ - At an hourly rate of $____ per hour (“Payment”). ☐ - Other. ______________________________________________ (“Payment”) If the Subcontractor asserts a claim which involves, in whole or in part, acts or omissions which are the responsibility of the Client or another person for whom a claim may be submitted, including but not limited to, claims for failure to pay, an extension of time, impacts, delay damages, or extra work, the Contractor shall present the Subcontractor's claim to the Client or other responsible party provided the Subcontractor presents to Contractor competent supporting evidence and in sufficient time for the Contractor to do so. The Subcontractor shall cooperate fully with the Contractor in any and all steps the Contractor takes in connection with prosecuting such a claim and shall hold harmless and reimburse the Contractor for all expenses, including legal expenses, incurred by the Contractor which arise out of the Contractor's submission of the Subcontractor's claims to the Client or other responsible party(ies). The Subcontractor shall be bound by any adjudication or award in any action or proceeding resolving such a claim.