Professional Expert Sample Clauses

Professional Expert. A professional expert is used for the temporary employment of a person in conjunction with a specific, limited term project requiring professional knowledge, skill, or technical expertise. The District agrees that it will not employ a professional expert to perform work that has been customarily and routinely performed by employees in the bargaining unit. CSEA will be provided details of the specific project, an estimate of length of assignment and individual qualifications of the proposed expert in their specific field, at least five (5) working days prior to presentation and approval by the Board of Trustees.
Sample 1Sample 2Sample 3See All (4)
AutoNDA by SimpleDocs
Professional Expert. An “expert” is a person who is specially qualified by education and experience to perform difficult and challenging tasks in a particular field beyond the usual range of achievement of competent persons in that field. (See 5 CFR 304.102(d). 1. Faculty stipend assignments that require subject-matter expertise shall be paid at the faculty rate on the Part-Time Overload Salary Schedule. A flat rate may also be used and shall be negotiated between YFA and the District, prior to the commencement of work.
Sample 1Sample 2Sample 3
Professional Expert. 37.1 In any event of a difference of opinion between the parties in any matter relating to the execution of the Work and/or the Finishing Work and/or the completion of the repairs and/or the nature of the repairs and/or the determination of the cost for the execution of the required alterations by the Lessee, such matters shall be brought before a professional expert for his ruling, a building engineer by profession, who shall be appointed by the parties, and in the absence of such consent as to the identity of the Professional Expert within 7 days, he shall be appointed at the request of one of the parties by the chairman of the Israeli Institute of Architects and Engineers (above and below: “the Professional Expert”). 37.2 The Professional Expert shall be entitled to approve the Lessor’s Representative’s instructions and/or determinations, cancel or alter them, however he shall not have the power to order a stay or cessation of the execution of the Work, and this without derogating from his rights to instruct the Lessor to carry out repairs and/or alterations the execution of which may delay the execution of the Work. 37.3 The Professional Expert shall be entitled to instruct the Lessor to carry out repairs to the Leased Premises. Similarly the Professional Expert shall be entitled to determine whether the Leased Premises are fit or are unfit for Delivery and as well as discuss and decide upon any other issue in connection with the execution of the Work and/or the Finishing Work and/or the Delivery of the Leased Premises and/or the execution of repairs to the Leased Premises and/or any other engineering matter brought before him as stated above. 37.4 In these actions as stated above and/or acting within the framework of any other power or any other additional power vested in him under this Agreement, the expert shall act as the Professional Expert and not as an arbitrator and his decision shall be final and absolute and shall bind the parties as though agreed by them from the very outset. 37.5 The Professional Expert shall act to the best of his ability in order to provide his decision on any matter brought before him for his ruling as soon as possible from the date at which any of the parties has made the request to him to receive his decision and after he has enabled each of the parties to detail before him their position, but in any event no later than 14 days from the date at which the dispute has been brought before him for his ruling. 37.6 The part...
Sample 1Sample 2
Professional Expert. 33.1. In any event of disagreement between the parties in any matter relating to the execution of the works by the Lessor and / or the works by the Lessee and / or the handing over of possession and / or the completion of repairs and / or the nature of repairs - these matters shall be brought for decision by a professional expert, as this is defined in clause 1.28 above. 33.2. The professional expert shall not have the authority to order a delay or suspension of the execution of works, but he shall have the right to instruct the Lessor to implement repairs and / or changes, the execution of which might delay the execution of the works. 33.3. In his actions as aforesaid and / or in his practice within the framework of any other or additional authority conferred on him pursuant to this Agreement, the expert shall act as a professional expert and his decision shall be final and absolute and shall be binding on the parties, as if this had been agreed between them from the outset. There shall be no appeal against his decision.
Sample 1

Related to Professional Expert

  • Expert Subject to Clause 16.1, where any matter may be referred to an expert pursuant to Clause 11.2 or is required by this Agreement to be referred to an expert then except as otherwise provided for in this Agreement, the matter must be referred for determination by a person: (a) who is appointed by the Parties, or in default of such appointment within ten (10) Business Days after either Party giving notice in writing to the other Party requiring the appointment of an expert then that person is to be nominated at either Party’s request by: (i) if the Parties agree that the Dispute is of a financial nature, the President for the time being of CPA Australia; (ii) if the Parties agree that the Dispute is of a non-financial nature, the President for the time being of the Engineers Australia – Queensland Division; and (iii) in any other case, by the President for the time being of the Queensland Law Society Incorporated; (b) who has appropriate qualifications and practical experience having regard to the nature of the Dispute; (c) who has no interest or duty which conflicts or may conflict with his function as expert, he being required to fully disclose any such interest or duty by written notice to the Parties before his appointment; (d) who is not an employee of the End User, any Operator or Aurizon Network or of a Related Body Corporate of any of them; (e) who shall not be permitted to act until he has given written notice to both Parties that he is willing and able to accept the appointment; (f) who shall have regard to the provisions of this Agreement and consider all submissions (including oral submissions by either Party provided that such oral submissions are made in the presence of the other Party), supporting documentation, information and data with respect to the matter submitted by the Parties or submitted by the Parties as soon as reasonably practicable at his request and who must provide both Parties with a copy of his determination in the form of a report within a reasonable time after his appointment; (g) who shall be required to undertake to keep confidential all matters coming to his knowledge by reason of his appointment and performance of his duties; (h) who shall be deemed to be and shall act as an expert and not an arbitrator and the law relating to arbitration (including, without limitation, the Commercial Arbitration Act 1990 (Qld)) shall not apply to him or his determination or the procedures by which he may reach his determination; (i) whose decision, in the absence of manifest error, shall be final and binding upon the Parties; and (j) whose costs (and the costs of any advisers to the expert) shall be borne by the Parties in equal shares with each Party bearing its own costs of participating in the dispute resolution process (unless otherwise agreed by the Parties). Any determination made by an expert must be consistent with the provisions of this Agreement.

  • Independent Expert The Parties and the other signatories may, upon written agreement, resort to an independent expert in order to obtain a well-grounded opinion that may lead to the settlement of the dispute or controversy. In case such agreement is signed, arbitration may only be filed after issuance of the expert’s opinion.

  • Professional Expenses Each calendar year during the Employment Term, the Company agrees to reimburse the Executive for up to $10,000 of reasonable professional expenses (i.e., accounting, financial planning, estate planning expenses) incurred by the Executive during such year for personal advice rendered to the Executive.

  • Independent Accountant Xxxxxxxx LLP (the “Accountant”), which has expressed its opinions with respect to the audited financial statements (which term as used in this Agreement includes the related notes thereto) of the Company filed with the Commission as a part of the Registration Statement and included in the Disclosure Package and the Prospectus, is an independent registered public accounting firm as required by the Securities Act and the Exchange Act.

  • Professional Services Fees You agree to pay us the professional services fees in the amounts set forth in the Investment Summary. Those amounts are payable in accordance with our Invoicing and Payment Policy. You acknowledge that the fees stated in the Investment Summary are good-faith estimates of the amount of time and materials required for your implementation. We will bill you the actual fees incurred based on the in-scope services provided to you. Any discrepancies in the total values set forth in the Investment Summary will be resolved by multiplying the applicable hourly rate by the quoted hours.

  • Professional Engineering and Architect’s Services Professional Engineering and Architect’s Services are not permitted to be provided under this Agreement. Texas statutes prohibit the procurement of Professional Engineering and Architect’s Services through a cooperative agreement.

  • Professional Liability insurance shall be written with limits no less than $1,000,000 per claim and $1,000,000 policy aggregate limit, as applicable.

  • Professional Services Bodily injury" or "property damage" arising out of the rendering of or failure to render profes- sional services;

  • Audit Dispute In the event of a dispute with respect to any audit conducted under Section 6.10.1, Xxxxxxx and Forest shall work in good faith to resolve the disagreement. If the Parties are unable to reach a mutually acceptable resolution of any such dispute within [*] days, the dispute shall be submitted for resolution to a certified public accounting firm jointly selected by each Party’s certified public accountants or to such other Person as the Parties shall mutually agree (the “Accountant”). The decision of the Accountant shall be final and the costs of such arbitration as well as the initial audit shall be borne between the Parties in such manner as the Accountant shall determine. If the Accountant concludes that additional payments were owed, or that excess payments were made during such period, then the Party owing such additional payments shall pay such additional amounts, or the Party that received such excess payments shall reimburse such excess payments, as applicable, in either case, within [*] days after the date on which such decision is made by the Accountant.

  • Contract for Professional Services of Physicians Optometrists, and Registered Nurses

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!