Unsafe Conditions In accordance with 29 CFR § 1977, occasions might arise when an employee is confronted with a choice between not performing assigned tasks or subjecting himself/herself to serious injury or death arising from a hazardous condition at the workplace. If the employee, with no reasonable alternative, refuses in good faith to expose himself/herself to the dangerous condition, he/she would be protected against subsequent discrimination. The condition causing the employee's apprehension of death or injury must be of such a nature that a reasonable person, under the circumstances then confronting the employee, would conclude that there is a real danger of death or serious injury and that there is insufficient time, due to the urgency of the situation, to eliminate the danger by resorting to regular statutory enforcement channels. In addition, in such circumstances, the employee, where possible, must also have sought from his Employer, and been unable to obtain, a correction of the dangerous condition.
Unsafe Work Conditions No Employee shall be disciplined for refusal to work on a job which in the opinion of: (a) A member of a safety committee; or (b) A person designated by a safety committee; or (c) A safety officer after an on-site inspection and following discussion with a representative of the Employer, does not meet the standards established pursuant to the Workers' Compensation Act.
Subsurface Conditions Unless the Contract Documents stipulate specific quantities and units of rock or unsuitable soils, the Contractor shall assume material below the surface of the Earth to be earth and other material that can be removed by power shovel or similar equipment. Should conditions encountered below the surface of the ground be at variance to the number of unit requirements as indicated by drawings or specifications, and absent an agreed-upon unit price established prior to the bid by Addendum, or after contract execution by Change Order, the Contract Sum and/or time shall be adjusted as provided in the Contract Documents for changes in the work.
FUTURE ACTIVITIES AND UNKNOWN CONDITIONS This Agreement shall not operate to shield the Respondent from liability arising from future activities, as of the date of execution of this Agreement.
Geographic Area and Sector Specific Allowances, Conditions and Exceptions The following allowances and conditions shall apply where relevant. Where the Employer does work which falls under the following headings, the Employer agrees to pay and observe the relevant respective conditions and/or exceptions set out below in each case.
Suspension of unsafe Construction Works (i) Upon recommendation of the Authority’s Engineer to this effect, the Authority may by notice require the Contractor to suspend forthwith the whole or any part of the Works if, in the reasonable opinion of the Authority’s Engineer, such work threatens the safety of the Users and pedestrians. (ii) The Contractor shall, pursuant to the notice under Clause 11.17 (i), suspend the Works or any part thereof for such time and in such manner as may be specified by the Authority and thereupon carry out remedial measures to secure the safety of suspended works, the Users and pedestrians. The Contractor may by notice require the Authority’s Engineer to inspect such remedial measures forthwith and make a report to the Authority recommending whether or not the suspension hereunder may be revoked. Upon receiving the recommendations of the Authority’s Engineer, the Authority shall either revoke such suspension or instruct the Contractor to carry out such other and further remedial measures as may be necessary in the reasonable opinion of the Authority, and the procedure set forth in this Clause 11.17 shall be repeated until the suspension hereunder is revoked. (iii) Subject to the provisions of Clause 21.6, all reasonable costs incurred for maintaining and protecting the Works or part thereof during the period of suspension (the “Preservation Costs”), shall be borne by the Contractor; provided that if the suspension has occurred as a result of any breach of this Agreement by the Authority, the Preservation Costs shall be borne by the Authority. (iv) If suspension of Works is for reasons not attributable to the Contractor, the Authority’s Engineer shall determine any Time Extension to which the Contractor is reasonably entitled.
Hazardous Conditions Whenever the Contractor’s operations create a condition hazardous to traffic or to the public, the Contractor shall provide flagmen and furnish, erect and maintain control devices as are necessary to prevent accidents or damage or injury to the public at Contractor’s expense and without cost to the County. The Contractor shall comply with County directives regarding potential hazards. Emergency lights and traffic cones must also be readily available at all times and must be used in any hazardous condition. Emergency traffic cones must be placed in front of and behind vehicles to warn oncoming traffic. Signs, lights, flags, and other warning and safety devices shall conform to the requirements set forth in Chapter 5 of the current traffic manual, Traffic Control for Construction and Maintenance Work Zones, published by the state of California Department of Transportation. The Contractor shall take proper safety and health precautions to protect the Work, the workers, the public, and the property of others. The Contractor shall also be responsible for all materials delivered and Work performed until completion and acceptance of the entire construction Work, except for any completed unit of construction thereof which theretofore may have been accepted.
– OTHER SPECIAL CONDITIONS I. 12.1 Exchange rate applicable for the conversion of currencies into euro Payments shall be made by the Commission in euro. The co-ordinator shall submit the payment requests in accordance with article I.5.3, including the underlying financial statements, in euro. By way of derogation from article II.16.1, any conversion of actual costs into euro shall be made by the beneficiary at the monthly accounting rate established by the Commission and published on its website applicable on the day when the cost was incurred.
Unsafe Working Conditions Employees shall be recognized by the Employer to have the competence to determine what constitutes unsafe working conditions within their discipline. No employee shall be disciplined for refusal to work in a situation which is deemed unsafe beyond the reasonable requirements of the employee's job.
HAZARDOUS SUBSTANCE CONDITIONS If a Hazardous Substance Condition occurs, unless Lessee is legally responsible therefor (in which case Lessee shall make the investigation and remediation thereof required by Applicable Requirements and this Lease shall continue in full force and effect, but subject to Lessor's rights under Paragraph 6.2(c) and Paragraph 13), Lessor may at Lessor's option either (i) investigate and remediate such Hazardous Substance Condition, if required, as soon as reasonably possible at Lessor's expense, in which event this Lease shall continue in full force and effect, or (ii) if the estimated cost to investigate and remediate such condition exceeds twelve (12) times the then monthly Base Rent or $100,000 whichever is greater, give written notice to Lessee within thirty (30) days after receipt by Lessor of knowledge of the occurrence of such Hazardous Substance Condition of Lessor's desire to terminate this Lease as of the date sixty (60) days following the date of such notice. In the event Lessor elects to give such notice of Lessor's intention to terminate this Lease, Lessee shall have the right within ten (10) days after the receipt of such notice to give written notice to Lessor of Lessee's commitment to pay for the excess costs of (a) investigation and remediation of such Hazardous Substance Condition to the extent required by Applicable Requirements, over (b) an amount equal to twelve (12) times the then monthly Base Rent or $100,000, whichever is greater. Lessee shall provide Lessor with the funds required of Lessee or satisfactory assurance thereof within thirty (30) days following said commitment by Lessee. In such event this Lease shall continue in full force and effect, and Lessor shall proceed to make such investigation and remediation as soon as reasonably possible after the required funds are available. If Lessee does not give such notice and provide the required funds or assurance thereof within the time period specified above, this Lease shall terminate as of the date specified in Lessor's notice of termination.