Withdrawal from the Contract Sample Clauses

Withdrawal from the Contract. 1. UPJŠ LF is entitled to unilaterally withdraw from this Contract in the event that: a) the student has not paid the fees or payment associated with studying under Art. (IV),

Withdrawal from the Contract. The Sponsee has the right to withdraw from this contract at any time for reasons of public interest and /or for reasons of foreign policy, upon simple request, without conditions or limitations of any kind, free of charge and without prejudice to the right to the return of advances of price paid previously and exceeding the consideration for services already rendered and delivered.

Withdrawal from the Contract. The Buyer may, beyond the scope of the general regulation laid down in valid and effective legal regulations, withdraw from the Contract in case the Seller is in delay in the delivery of the subject of performance for longer than 30 days and fails to arrange rectification even within 15 days of the delivery of a written notification from the Buyer of such delay. The Seller may, beyond the scope of the general regulation laid down in valid and effective legal regulations, withdraw from the Contract in case the Buyer is in delay in the payment of an invoice for longer than 30 days and fails to arrange rectification even within 15 days of the delivery of a written notification from the Seller of such delay. Either of the Contracting Parties is authorised to withdraw from the Contract if a circumstance of vis major laid down in paragraph 5 herein, which the Contracting Party could not have foreseen or prevented, continues for longer than 2 months and the Contracting Parties fail to reach agreement on the corresponding amendments to the Contract. Xxxxxxxxxx must be done in writing, stating the reason for the withdrawal, and delivered to the other Contracting Party. Withdrawal from the Contract enters into effect on the date of its delivery to the other Contracting Party. All rights and obligations of the Contracting Parties arising from the Contract cease to exist upon withdrawal from the Contract. Withdrawal from the Contract shall be without prejudice to the right to compensation for damages established as a result of a breach of the Contract, the resolution of disputes between the Contracting Parties, rights to contractual penalties and other claims which, according to this Contract or in light of the nature thereof, should continue even following the expiration of the Contract. If the Seller was provided with an advance, or the full purchase price, prior to withdrawal from the Contract, it is obliged to return this to the Buyer within 10 days of the effective date of withdrawal from the Contract. The withdrawing Contracting Party has the right to seek from the other Contracting Party payment of the costs incurred in connection with the withdrawal, if not a case of withdrawal on the grounds of continuation of an obstacle of vis major. For the purposes of this Contract, vis major is primarily considered to be: natural disasters, fires, earthquake, landslide, flood, storm or other atmospheric disturbances, war, revolution, uprising, civil unrest or strikes, de...

Withdrawal from the Contract. The Buyer may withdraw from this Contract if: a) the System is not supplied or installed or commissioned within 1 month of the lapse in vain of agreed terms due to reasons attributable to the Seller. This shall be without prejudice to the provision under Art. VIII(1) hereof; b) the technical specifications of the System given in Annex 1 hereto are not complied with; c) the System is supplied with defects that are not removable or defects, the removal of which would bring about excessive costs or take an inappropriately long period of time. Either Contracting Party may withdraw from the present Contract by serving a written notice if the other Contracting Party breaches the provisions hereof in a material way. The withdrawal becomes effective on the date of delivery of a written withdrawal notice to the other Contracting Party. This shall be without prejudice to the withdrawing party's right to damages or a contractual fine or default interest.

Withdrawal from the Contract. 1. If the Executor has abandoned the Works, refuses or fails to comply with the applicable Contract Engineer and / or the Customer, breaks or performs the Contract of Work in a manner that is inconsistent, incompatible with the Contract or otherwise acts against the Contract despite written reminder, the Customer is entitled to withdraw from the Contract with justifying type of failure in writing. 2. The Customer's notice of termination should be served to the Executor within 42 days of its occurrence, but not later than five months after the date of signing this Contract. In case of delay in completion of work beyond the stated date, the date of such withdrawal will be extended by the number of days corresponding to this delay.

Withdrawal from the Contract. 1. The Customer who has concluded the Agreement at a distance has the right to withdraw from the contract within 14 days from the date of signing the contract. 2. The Customer who has requested to perform services before the deadline for withdrawal from the contract may withdraw from it, but is obliged to pay for the services provided until the withdrawal.

Withdrawal from the Contract. 9.1 The BUYER has the right to withdraw from this CONTRACT in the case of a gross breach of the provisions thereof by the CONTRACTOR, particularly in the case of: a) Non-performance or material improper performance of the WORKS AND/OR EQUIPMENT by the CONTRACTOR, particularly in the case of non-conformity with the technical specification (Appendix no. 1 and 13), construction practices, in the case of using any technology, materials, subassemblies and devices with: (i) inadequate quality, (ii) used, (iii) without approvals for use in Poland or not suitable for use or not accepted for use in the WORKS AND/OR EQUIPMENT (iv) inconsistent with the CONTRACT and its appendices; b) A significant delay in performance of the WORKS AND/OR EQUIPMENT by the CONTRACTOR as compared to the contractual events described in the CONTRACTUAL TIME SCHEDULE; c) A serious breach of OHS principles, in particular, in the case of a serious, fatal or collective accident at work, or any hazard of such accident being caused; d) A crime committed by the employees, managers, co-workers of the CONTRACTOR against the interests (including property and employees) of the BUYER, or such attempted crime; e) Breach of section 7.6. of the CONTRACT by the CONTRACTOR; f) Breach of section 7.2 - 7.5 of the CONTRACT by the CONTRACTOR; g) Failure to transfer the intellectual property rights to the BUYER, in the scope required by the CONTRACT and the GENERAL CONDITIONS h) a justified statement that the CONTRACTOR's financial situation could be interpreted as preventing proper implementation of the given CONTRACT by the CONTRACTOR, in particular in the event of withholding or ceasing, for no valid reason, payments to the subcontractors, prolonged or repeated material shortcomings in the CONTRACTOR's personnel, seizures of liabilities owed to the CONTRACTOR from the BUYER, seizures of the CONTRACTOR's assets introduced to the SITE. 9.2 The BUYER is entitled to withdraw from the CONTRACT in case of termination, by any party and for any reason, of the Project Co-Financing Agreement, concluded between the BUYER and the National Centre for Research and Development;

Withdrawal from the Contract. If facts preventing the proper performance of this Contract occur in respect of any of the Parties, the Party affected is obliged to notify the other Party thereof without undue delay and initiate negotiations of the representatives authorised to sign the Contract. If any of the Parties wishes to withdraw from the Contract on the basis of the provisions arising from the Contract, it is obliged to notify the other Party thereof in writing, stating the date on which it shall withdraw from the Contract. The withdrawal must also include the reason for which the Party withdraws from the Contract and the exact citation of the provision of the Contract that entitles it to do so. Without these requirements, the withdrawal shall be invalid. If any of the Parties does not agree with the reason for the withdrawal of the other Party or if it denies the existence thereof, it is obliged to notify it in writing not later than ten days after the receipt of the notice of withdrawal. If it fails to do so, it shall be deemed to agree with the reason for the withdrawal. The withdrawal from the Contract shall take place on the day following the day on which the written notice of withdrawal was delivered to the other Party, unless the other Party denies the reason for the withdrawal within the specified period. Otherwise, the date agreed between the Parties or resulting from a decision by the competent authority shall be the effective date of withdrawal from the Contract.

Withdrawal from the Contract. In the case of withdrawal from the contract or a binding order by the customer, the supplier is entitled to a compensation charge in the amount of 10% of the agreed price. If the goods have already been dispatched, the supplier has the right to demand a contractual penalty in accordance with Article 4 hereof. Withdrawal from the contract is only possible in writing and becomes valid on the third day after the date on which the other party received the written notice of withdrawal.

Withdrawal from the Contract. 1. The Parties may only withdraw from the Contract in cases of material breach of the Contract, or in cases explicitly specified in the Contract or herein, or in cases explicitly provided for in legal regulations. The withdrawal shall take effect as of the day of delivery of a written withdrawal notice to the other Party. 2. A material breach of the Contract shall mean, in particular, the following: (i) the Buyer is in default with any payment or invoiced sum for more than 30 days; (ii) the Buyer is in default with providing assistance of his for more than 30 days; (iii) the Buyer has breached the confidentiality obligation under Art. VII (3) hereof; and (iv) PBS is in default with fulfilling its obligation under the Contract for more than 90 days, and such an obligation has not been fulfilled even after the prior written notification by the Buyer and providing with additional reasonable grace period for the fulfilment of the respective obligation. 3. Any of the Parties is also entitled to withdraw from the Contract if: (i) insolvency proceedings have been initiated against the Buyer, or (ii) the court refused an application for the establishment of a decision of bankruptcy of the Buyer due to the lack of the Buyer’s assets, or (iii) the other Party becomes an unreliable payer. 4. The Parties are also entitled to withdraw from the Contract if any Force Majeure event prevents delivery of the Supply for more than 3 months.