Acceptance Review Period definition

Acceptance Review Period. Has the meaning given in Section 4.6(b)(i) of the Agreement, provided that any provisions of written notice alerting DIR that a Milestone Deliverable is complete and ready for review that is submitted outside a Business Day shall be considered to be submitted, for the purposes of DIR internal review, on the next Business Day immediately following the day on which such notice was submitted. Actual Uptime Means, of the Critical Uptime, the aggregate number of minutes during which the applicable Service component defined in Attachment 3-A is Available. Additional Resource Charge (ARC) Means the incremental charges set forth in Exhibit 4 for the use of the Services above the Monthly Resource Baselines for such Services. Affiliate Means with respect to an Entity, any other Entity that directly or indirectly Controls, is Controlled by, or is under common Control with that Entity at the time in question. Agreement Means the final version of any contractually binding agreement between DIR and the Service Provider relating to the subject matter of the RFO; references to the Agreement include all Exhibits, Attachments and other documents attached thereto or incorporated therein by reference. Notwithstanding the foregoing, unless expressly provided or the context otherwise requires, references to the Agreement in conjunction with section or article references shall be deemed references to the body of the Agreement (that is, Articles 1 through 21). Allocation of Pool Percentage Means the portion of the respective Pool Percentage Available for Allocation that is specified for a Performance Category. The total of all Allocation of Pool Percentages shall not exceed the Pool Percentage Available for Allocation. Annual Base Charges or Base Charges Means the annual fixed charges for Service Provider's provision of the Services and includes the quantity of Resource Units set forth under the Resource Baselines in Attachment 4-D. The Annual Base Charges are set forth in Attachment 4-A and described as such. Base Charges are invoiced in monthly increments. Antivirus Software Means all software programs and programming (and all modifications, replacements, Upgrades, enhancements, documentation, materials and media related thereto) that are used to monitor for, filter and detect the presence of Malicious Code and repair or remediate the effects of Malicious Code. Antivirus Software shall include all such programs and programming in use or required to be used as of the Commencemen...
Sample 1Sample 2Sample 3
Acceptance Review Period. Has the meaning given in Section 4.6(b)(i) of the that of written notice DIR that a Milestone Deliverable is and for review that is submitted outside
Sample 1
Acceptance Review Period has the meaning given in Section 4.6(b)(ii).
Sample 1

Examples of Acceptance Review Period in a sentence

  • The Acceptance Review Period shall begin on the date that Service Provider provides written notification to DIR that the Milestone Deliverable is ready to be reviewed by DIR.

  • During the Acceptance Review Period, DIR and DIR Customers shall review and may further test each Milestone Deliverable, individually and collectively, to determine whether such item(s) contain any type of Noncompliance.

  • If DIR does not accept or deliver a notice of noncompliance by the end of such additional Acceptance Review Period, Service Provider may escalate such issue for expedited resolution through governance in accordance with Exhibit 6.

  • Unless otherwise specified in the applicable plan, the Acceptance Review Period for Milestone Deliverables identified as Interim Milestones (in the Transition Plan or the Transformation Plan) shall be ten (10) days.

  • Dispatching should be carried out in a manner which maximizes the productivity of drivers and vehicles while meeting the standards for service established by ACT.

  • If DIR does not identify any Noncompliance relating to a Milestone Deliverable during its Acceptance Review Period, DIR shall inform Successful Respondent in writing that the Milestone Deliverable is Accepted, subject to the other provisions of this Agreement.

  • If DIR does not Accept or deliver a notice of Noncompliance to Service Provider by the end of the Acceptance Review Period, Service Provider shall so inform the DIR Contract Manager and the DIR Data Center Services Manager and provide DIR an additional Acceptance Review Period of at least fourteen (14) days.

  • Beginning upon receipt of notice from Service Provider that a Milestone Deliverable is again ready to be Accepted, the applicable Acceptance Review Period shall begin again and the Parties shall re-perform their obligations under Sections 4.8(b)(i) through (iii).

  • If DIR or DIR Customer does not accept or deliver a notice of noncompliance by the end of such additional Acceptance Review Period, Service Provider may escalate such issue for expedited resolution through governance in accordance with Exhibit 6.

  • If DIR does not identify any Noncompliance relating to a Milestone Deliverable during its Acceptance Review Period, DIR shall inform Service Provider in writing that the Milestone Deliverable is Accepted, subject to the other provisions of this Agreement.


More Definitions of Acceptance Review Period

Acceptance Review Period. Has the meaning given in Section 4.5(a)(i) of the Agreement. Affiliate Means with respect to an Entity, any other Entity that directly or indirectly controls, is controlled by, or is under common control with that Entity at the time in question. Agreement Means the final version of the Master Services Agreement between OCA and Contractor relating to the subject matter of the RFO, to which this Exhibit 1 is attached. Assistance Event Means (i) any termination (in whole or in part) under, or the expiration of, the Agreement, or (ii) the discontinuance of the provision of the Services (in whole or in part) in respect of OCA.
Sample 1
Acceptance Review Period shall have the meaning given to it in Section 9.10.1 of the Agreement.
Sample 1
Acceptance Review Period. Has the meaning given in Section 10.6 Acceptance Review Period, provided that any provisions of written notice alerting DIR that a Milestone or Deliverable is complete and ready for review that is submitted outside a Business Day shall be considered to be submitted, for the purposes of DIR internal review, on the next Business Day immediately following the day on which such notice was submitted. ADC Austin Data Center ADDF Application Development Decision Framework – High level information about the ADDF is available at this link: xxxxx://xxxxxx.xxx.xxxxx.xxx/portal/internal/resources/DocumentLibrary/Texas%20ADDF%20 Pamphlet.pdf Administration Services The act of managing planning, directing, and coordinating supportive services for an activity and/or organization. Affiliate With respect to an Entity, any other Entity that directly or indirectly Controls, is Controlled by, or is under common Control with that Entity at the time in question. Agreement (also Master Services Agreement and MSA and Contract) The final version of any contractually binding agreement between DIR and the Successful Respondent relating to the subject matter of the RFO; references to the Agreement include all Exhibits, Attachments and other documents attached thereto or incorporated therein by reference. Notwithstanding the foregoing, unless expressly provided or the context otherwise requires, references to the Agreement in conjunction with Section or Article references shall be deemed references to the body of the Agreement. AIMS Asset Inventory and Management System.
Sample 1
Acceptance Review Period. Has the meaning given in Section 4.8(b)(i) of the Agreement, provided that any provision of written notice alerting DIR that a Milestone Deliverable is complete and ready for review that is submitted outside a Business Day shall be considered to be submitted for the purpose of DIR internal review, on the Business Day immediately following the day on which such notice was submitted. ACD Automatic Call Distributor Actual Uptime Means, of the Critical Uptime, the aggregate number of minutes during which the applicable Service component defined in Exhibit 3.1 Service Level Matrix is Available. ADC Austin Data Center Addendum A modification of the Request for Offer (RFO) issued by the Department of Information Resources (DIR) and posted on the Electronic State Business Daily (ESBD). Affiliate With respect to an Entity, any other Entity that directly or indirectly Controls, is Controlled by, or is under common Control with that Entity at the time in question. Agreement (also Master Services Agreement and MSA) The final version of any contractually binding agreement between DIR and the Successful Respondent relating to the subject matter of the RFO; references to the Agreement include all Exhibits, Attachments and other documents attached thereto or incorporated therein by reference. Notwithstanding the foregoing, unless expressly provided or the context otherwise requires, references to the Agreement in conjunction with section or article references shall be deemed references to the body of the Agreement (that is, Articles 1 through 21). AIMS Asset Inventory and Management System
Sample 1
Acceptance Review Period. Has the meaning given in Section 4.8(b)(i) of the Agreement, provided that any provision of written notice alerting DIR that a Milestone Deliverable is complete and ready for review that is submitted outside a Business Day shall be considered to be submitted for the purpose of DIR internal review, on the Business Day immediately following the day on which such notice was submitted. Actual Uptime Means, of the Critical Uptime, the aggregate number of minutes during which the applicable Service component defined in Attachment 3-A is Available. Affiliate Means with respect to an Entity, any other Entity that directly or indirectly Controls, is Controlled by, or is under common Control with that Entity at the time in question. Agreement Means the final version of any contractually binding agreement between DIR and the Service Provider relating to the subject matter of the RFO; references to the Agreement include all Exhibits, Attachments and other documents attached thereto or incorporated therein by reference. Notwithstanding the foregoing, unless expressly provided or the context otherwise requires, references to the Agreement in conjunction with Term Definition section or article references shall be deemed references to the body of the Agreement (that is, Articles 1 through 21). Antivirus Software Means all software programs and programming (and all modifications, replacements, Upgrades, enhancements, documentation, materials and media related thereto) that are used to monitor for, filter and detect the presence of Malicious Code and repair or remediate the effects of Malicious Code. Antivirus Software shall include all such programs and programming in use or required to be used as of the Commencement Date, including those as to which the license, maintenance or support costs are included in the Financial Base Case and those as to which Service Provider received reasonable notice and/or access prior to the Commencement Date. Antivirus Software also shall include all such programs and programming developed and/or introduced by or for DIR, any DIR Customer, or Service Provider during the Term. Appliances Means a specialized computing device with pre-integrated and pre- configured hardware and/or software packaged to provide a “turn-key” solution. The computing function in an Appliance, though configurable, is designed by the manufacturer to provide a specific function with little or no support. Computer appliances differ from general purpose computers such as...
Sample 1
Acceptance Review Period. Has the meaning given in Section 4.8(b)(i) of the Agreement, provided that any provision of written notice alerting DIR that a Milestone Deliverable is complete and ready for review that is submitted outside a Business Day shall be considered to be submitted for the purpose of DIR internal review, on the Business Day immediately following the day on which such notice was submitted. Actual Uptime Means, of the Critical Uptime, the aggregate number of minutes during which the applicable Service component defined in Attachment 3-A is Available. Affiliate Means with respect to an Entity, any other Entity that directly or indirectly Controls, is Controlled by, or is under common Control with that Entity at the time in question. Agreement Means the final version of any contractually binding agreement between DIR and the Service Provider relating to the subject matter of the RFO; references to the Agreement include all Exhibits, Attachments and other documents attached thereto or incorporated therein by reference. Notwithstanding the foregoing, unless expressly provided or the context otherwise requires, references to the Agreement in conjunction with section or article references shall be deemed references to the body of the Agreement (that is, Articles 1 through 21).
Sample 1

Related to Acceptance Review Period

  • Review Period has the meaning set forth in Section 2.04(c)(i).

  • Title Review Period shall have the meaning set forth in Section 4.3.

  • Acceptance Test is a test of the Features executed by the Customer to prepare the acceptance.

  • Acceptance period, as used in this provision, means the number of calendar days available to the PHA/IHA for awarding a contract from the date specified in this solicitation for receipt of bids.

  • Application Review Start Date means the later date of either the date on which the District issues its written notice that the Applicant has submitted a completed Application or the date on which the Comptroller issues its written notice that the Applicant has submitted a completed Application and as further identified in Section 2.3.A of this Agreement.

  • Acceptance Testing mean the tests, reviews and other activities that are performed by or on behalf of Agency to determine whether the Deliverables meet the Acceptance Criteria or otherwise satisfy the Agency, as determined by the Agency in its sole discretion.

  • Acceptance Tests means those tests performed during the Performance Period which are intended to determine compliance of Equipment and Software with the specifications and all other Attachments incorporated herein by reference and to determine the reliability of the Equipment.

  • Review Package A package of documents consisting of a memorandum outlining the analysis and recommendation (in accordance with the Servicing Standard) of the Master Servicer or the Special Servicer, as the case may be, with respect to the matters that are the subject thereof, and copies of all relevant documentation.

  • Inspection Period means the period beginning on the Effective Date and expiring at 5:00 p.m. eastern time on the forty-fifth day after the Effective Date.

  • Acceptance Day shall have the meaning specified in paragraph 2B(5).

  • Acceptance Date has the meaning set forth in Section 2.05(a)(v)(D)(2).

  • Study Period means the period commencing at 9:00 a.m. on the date hereof, and continuing through 5:00 p.m. on the Closing Date.

  • Acceptance Notice has the meaning set forth in Section 9.2(d)(iii).

  • Notice of Completion means a document issued by the Department or Delegated Agency at the end of project construction when all items and conditions of the approved Sediment and Stormwater Management Plan have been satisfied, post construction verification documents demonstrate that the stormwater management systems have been constructed in accordance with the approved Sediment and Stormwater Management Plan, and final stabilization of disturbed areas on the site has been achieved.

  • Response Period has the meaning set forth in Section 9.6(a).

  • Final Completion Date means the date on which Final Completion occurs.

  • Final Completion means the date determined and certified by A/E and Owner on which the Work is fully and satisfactorily complete in accordance with the Contract.

  • Acceptance Window shall have the meaning specified in paragraph 2B(5).

  • Completion Period means the period starting from the date of issue of "Order" and required to complete the work in all respect.

  • Notice Deadline means 2.30 p.m. (Dublin time), provided that the Notice Deadline in respect of any Series of ETP Securities may be adjusted by agreement between the Issuer and the Margin Loan Provider with effect from the fifth calendar day following the date on which notice of such adjustment is given to the holders in accordance with Condition 17.

  • Completion Notice means a notice issued by the Developer in accordance with clause 6.1.

  • Operational Acceptance Tests means the tests specified in the Technical Requirements and Agreed Project Plan to be carried out to ascertain whether the System, or a specified Sub system, is able to attain the functional and performance requirements specified in the Technical Requirements and Agreed Project Plan, in accordance with the provisions of GCC Clause 27.2 (Operational Acceptance Test).

  • The Completion Date means the date of completion of the Works as certified by the Employer’s Representative.

  • Acceptance Letter means the letter from Adviser to BD pursuant to which the Adviser appoints BD as a Broker Dealer for each series of MuniPreferred issued by any Fund that has executed a Request Letter.

  • Certification period means the period for which an individual is certified eligible for a program.

  • Commencement Notice means a written notice, given by any Secured Party to the other Secured Parties in accordance with the notice provisions set forth in the Securities Purchase Agreement, pursuant to which such Secured Party notifies the other Secured Parties of the existence of one or more Events of Default and of such Secured Party’s intent to commence the exercise of one or more of the remedies provided for under this Agreement with respect to all or any portion of the Collateral as a consequence thereof, which notice shall incorporate a reasonably detailed description of each Event of Default then existing and of the remedial action proposed to be taken.