Add is unable to take full responsibility for the adequacy, stability and safety of all Site operations and methods of construction as stipulated in sub-clause 8.2 of the conditions of contract.
a) Fails to comply with Subclause 10.1 and 10.2 of the Conditions of Contract
b) Fails to comply with Sub-Clause 14.2 and Sub-Clause 14.3 of the Conditions of Contract and Appendix to Form of Bid.
c) Fails to observe the safety as stipulated in Subclause 19.1 and amendments therein.
d) Fails to Conform to Service levels as detailed in the Appendix to Form of Bid and as required in subclause 13.1.
e) Incurs the maximum amount of Liquidated damages as stated in the Appendix to Form of Bid or the liquidated damages amount, exceeds the performance security then the contract would be automatically Terminated.
f) Has not completed the works despite the lapse of the Contract Period as stated in the Appendix to form of Bid SUBCLAUSE 67.1 – ENGINEER’S DECISION Delete the entire sub clause 67.1 and add the following; “If a dispute of any kind whatsoever arises between the Employer and the Contractor in any connection with, or arising out of, the Contract or the execution of the works, whether during the execution of the works or after their completion and whether before or after repudiation or other termination of the Contract including any dispute as to any opinion, instruction, determination, certificate or valuation of the Engineer, the matter in dispute shall, in the first place, be referred in writing to the Engineer, with a copy to the other party. Such reference shall state it is made pursuant to this clause. No later than 28 (twenty eight) day after the day on which he received such reference the Engineer shall give notice of his decision to the Employer and the Contractor. Such decision shall state it is made pursuant to this clause. Unless the Contract has already been repudiated or terminated, the Contractor shall, in every case, continue to proceed with the works with all due diligence and the Contractor and the Employer shall give effect forthwith to every such decision of the Engineer unless and until the same shall be revised, as hereinafter provided, in an Amicable Settlement, Adjudicator’s or Arbitrator’s award. If either the Employer or the Contractor be dissatisfied with the any decision of the Engineer, or if the Engineer fails to give notice of his decision on or before the 28th (twenty eighth) after the day on which he received the reference, then either th...
Add. The Employer agrees that the function of a supervisor is the supervision of employees and not the work of the employees they supervise.
Add on: a software add-on that extends the core functionality of the eLabNext Software.
Add. Chief Executive Officer': The expression Add.Chief Executive Officer' as used in the tender papers shall mean the officer of Additional Chief Executive Officer ranks (by whatever designation he may be known) under whose control the work lies for the time being.
Add is unable to take full responsibility for the adequacy, stability and safety of all Site operations and methods of construction as stipulated in subclause 8.2 of the conditions of contract.
Add. ENGINEER shall not commence performance of any services under this Agreement until the LA has issued a written Notice to Proceed. Blivin Bridge over Nippersink Creek – Phase II Supplement #1 3/29/11 *Firm’s approved rates on file with IDOT’S Bureau of Accounting and Auditing: Overhead Rate (OH) 147.41 % Complexity Factor (R) 0.00 Calendar Days Route: (Blivin - Phase II Supplement #1)
Add. In the event a bid time start time is changed by one (1) hour or more permanently for thirty (30) consecutive calendar days, the job shall be re-bid.
Add. ENGINEER shall not commence performance of any services under this Agreement until the LA has issued a written Notice to Proceed.
Add. Reduce net monthly earnings by:
Add. Forecast, Buyer will provide a rolling monthly forecast of Buyer's demand for the Product with visibility for the next six (6) months. This forecast will be for planning purposes only."
