Before Commencement of Construction Sample Clauses

Before Commencement of Construction. 1.1 The Contractor shall, before commencement of construction; (a) have mobilised the requisite resources, personnel and organisation necessary for the same and designated and appointed suitable officers/ representatives as it may deem appropriate with responsibility to supervise execution of the Works and for exchange of information with the Project Engineer and PWD; (b) provide and maintain a reasonably flirnished site office accommodation for the Project Engineer, at the Works Site up to the Taking Over Date; (c) in consultation with the Project Engineer workout an appropriate schedule for submission of documents set out in 1.1 above to the Project Engineer for review; (d) finalise an implementation plan for the Works (Implementation Plan) in consultation with the Project Engineer. The Implementation Plan shall, inter alia, include a detailed schedule of implementation for putting up the Works covering all stages/ aspects of the Works implementation including design and engineering, procurement of materials and equipment, installation, construction and testing; (e) finalise in consultation with the Project Engineer a method statement setting out details of the actual methods that would be adopted by the Contractor for the construction of such Works including details of equipment and machinery that would be used, their locations, and arrangements for conveying and handling materials; (f) finalise such Drawings as are necessary and the Implementation Schedule in consultation with the Project Engineer; (g) obtained all such Applicable Permits as are necessary to commence construction of such Works; (h) manpower deployment plan, including the designation of key personnel for the management and supervision of all Works activities. (This would include the designation of suitably qualified personnel for areas such as contract administration and supervision, construction management, safety, 46
Sample 1
Before Commencement of Construction. Prior to commencement of construction of any of the Project Facilities, the Concessionaire shall obtain all applicable permits and approvals from Concessioning Authority & concerned local authorities, necessary to commence construction of such Project Facilities; Concessionaire must get the main design approved by the Concessioning authority before undertaking any construction.
Sample 1
Before Commencement of Construction. Prior to the commencement of any construction activity, the Concessionaire shall finalise and furnish an implementation plan for the Project (Construction Plan) in consultation with the Project Officer. The Construction Plan shall, inter alia, include: A detailed schedule of implementation for putting up and operationalising the Parking Facilities, and which shall specify at least 4 major milestones; Advise to CoC on alternate regulation of parking, if applicable, until such time that the parking facility is operational and operate the approved Scheme by CoC during the construction period; Advise CoC on the details of the utilities that are necessary to be shifted, including suggestions on the alternate routing, and the estimates of the costs associated with such shifting; The Critical Path Method (CPM) / Program Evaluation and Review Technique (PERT) charts or similar activity planning techniques / methods for monitoring. This shall cover all stages and aspects of the Project Implementation including design and engineering, procurement of materials and equipment, installation, construction, testing, etc. Manpower deployment plan, including the designation of Key Personnel for the management and supervision of all Project Activities. This would include the designation of suitably qualified and experienced personnel for areas such as Contract Administration and Supervision, Construction Management, Traffic & Safety, Environmental Management, Plant & Equipment Maintenance, Procurement, Materials Management, Quality Control & Assurance, etc. The manpower to be provided by the Concessionaire, shall match that of IE, in qualification and experience. A broad method statement for key items setting out methodology of construction, materials and construction equipment mobilization, utilization plans, broad output calculations and details of the quality assurance and quality control procedures. Format of the monthly report giving details of the physical progress in implementation of the Project and Operations & Maintenance Activities undertaken (Monthly Progress Report). The Concessionaire shall, in consultation with the Project Officer workout an appropriate schedule for submission of documents set out in 2.1 above to the Project Officer for review. Prior to commencement of construction of any of the Project Facilities, the Concessionaire shall: Obtain all such applicable permits as mentioned in Schedule II as are necessary to commence construction of Project Facil...
Sample 1
Before Commencement of Construction. Tenant shall cause the Approved General Contractor to provide to Landlord evidence of the following insurance: Comprehensive General Liability must include Premises/Operations, Products/Completed Operations, Contractual, Personal Injury, Broad Form PD, Explosion, Collapse and Underground Damage. This General Liability must be a minimum of $2,000,000. It must cover a minimum of all operations other than Auto and Worker’s Compensation, and must carry a minimum rating of “A plus VII” or better. General Liability must be the “Occurrence” type. The occurrence coverage provided must apply to covered losses that occur during the policy period regardless of when the claim is reported. Certificates showing “Claims Made” and “Modified Occurrence” coverage shall not be acceptable. The Auto insurance policy shall be for “any auto”, thus providing coverage for owned, rented or hired vehicles of the insured and the insured’s liability arising from the use of his employees vehicles for a required minimum of $2,000,000. If the entity (contractor) obtaining the certificate claims to not own any vehicles, the minimum general liability insurance acceptable policy shall cover “Non-Owned” and “Hired” vehicles. The Owner (Landlord) prefers the Umbrella Form of Excess Liability coverage for a minimum of $2,000,000.
Sample 1

Related to Before Commencement of Construction

  • Commencement of Construction Construction of the Project will start within thirty (30) days after notification to the Developer by the Owner, or as soon thereafter as weather and ground conditions permit.

  • Completion of Construction Within 60 days of the completion of construction of the Project, Project Owner shall deliver to DoD copies of the FAA form 7460-2 for each ASN, including the final coordinates for each turbine erected.

  • Manner of Construction Landlord may impose, as a condition of its consent to any and all Alterations or repairs of the Premises or about the Premises, such requirements as Landlord in its reasonable discretion may deem desirable, including, but not limited to, the requirement that Tenant utilize for such purposes only contractors reasonably approved by Landlord, and the requirement that upon Landlord’s request made at the time such consent is granted, Tenant shall, at Tenant’s expense, remove such Alterations upon the expiration or any early termination of the Lease Term and return the affected portion of the Premises to a building standard tenant improved condition as determined by Landlord. Tenant shall construct such Alterations and perform such repairs in a good and workmanlike manner, in conformance with any and all applicable federal, state, county or municipal laws, rules and regulations and pursuant to a valid building permit, issued by the City of Mountain View, all in conformance with Landlord’s construction rules and regulations; provided, however, that prior to commencing to construct any Alteration, Tenant shall meet with Landlord to discuss Landlord’s design parameters and code compliance issues. In the event Tenant performs any Alterations in the Premises which require or give rise to governmentally required changes to the “Base Building,” as that term is defined below, then if Tenant shall not succeed in contesting such governmentally required change, Landlord shall, at Tenant’s expense, make such changes to the Base Building; provided that in the event that Tenant’s request for approval of any Alteration shall indicate Tenant’s desire for Landlord to notify Tenant of any such Base Building changes, Landlord shall notify Tenant (to the extent Landlord is then aware of any such required changes), in its approval of such Alterations (if applicable), and Tenant shall be permitted, at its option, to promptly elect to not have the Alterations performed. The “Base Building” shall include the structural portions of the Building, and the public restrooms, elevators, exit stairwells and the systems and equipment located in the internal core of the Building on the floor or floors on which the Premises are located. In performing the work of any such Alterations, Tenant shall have the work performed in such manner so as not to obstruct access to the Project or any portion thereof, by any other tenant of the Project, and so as not to obstruct the business of Landlord or other tenants in the Project. Tenant shall not use (and upon notice from Landlord shall cease using) contractors, services, workmen, labor, materials or equipment that, in Landlord’s reasonable judgment, would disturb labor harmony with the workforce or trades engaged in performing other work, labor or services in or about the Building or the Common Areas. In addition to Tenant’s obligations under Article 9 of this Lease, upon completion of any Alterations, Tenant agrees to cause a Notice of Completion to be recorded in the office of the Recorder of the County of Santa Xxxxx in accordance with Section 3093 of the Civil Code of the State of California or any successor statute, and Tenant shall deliver to the Project construction manager a reproducible copy of the “as built” drawings of the Alterations, to the extent applicable, as well as all permits, approvals and other documents issued by any governmental agency in connection with the Alterations. 24 Mountain View Research Park ViewRay, Inc. SF Legal

  • Legal Construction If one or more of the provisions contained in this Agreement shall for any reason be held invalid, illegal, or unenforceable in any respect, such invalidity, illegality, or unenforceability shall not affect any other provisions and this Agreement shall be construed as if it did not contain the invalid, illegal, or unenforceable provision.

  • Interpretation and Construction 2.1 This Agreement includes this Agreement and all Exhibits appended hereto, each of which is hereby incorporated by reference in this Agreement and made a part hereof. All references to Sections and Exhibits shall be deemed to be references to Sections of, and Exhibits to, this Agreement unless the context shall otherwise require. The headings and numbering of Sections and Exhibits used in this Agreement are for convenience only and will not be construed to define or limit any of the terms in this Agreement or affect the meaning and interpretation of this Agreement. Unless the context shall otherwise require, any reference to any statute, regulation, rule, Tariff, technical reference, technical publication, or any publication of Telecommunications industry administrative or technical standards, shall be deemed to be a reference to the most recent version or edition (including any amendments, supplements, addenda, or successor) of that statute, regulation, rule, Tariff, technical reference, technical publication, or any publication of Telecommunications industry administrative or technical standards that is in effect. Provided however, that nothing in this Section 2.1 shall be deemed or considered to limit or amend the provisions of Section 2.2. In the event a change in a law, rule, regulation or interpretation thereof would materially change this Agreement, the terms of Section 2.2 shall prevail over the terms of this Section 2.1. In the case of any material change, any reference in this Agreement to such law, rule, regulation or interpretation thereof will be to such law, rule, regulation or interpretation thereof in effect immediately prior to such change until the processes set forth in Section 2.2 are implemented. The existing configuration of either Party's network may not be in compliance with the latest release of technical references, technical publications, or publications of Telecommunications industry administrative or technical standards.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!