Creative Work The Executive agrees that all creative work and work product, including but not limited to all technology, business management tools, processes, software, patents, trademarks, and copyrights developed by the Executive during the term of this Agreement, regardless of when or where such work or work product was produced, constitutes work made for hire, all rights of which are owned by the Employer. The Executive hereby assigns to the Employer all rights, title, and interest, whether by way of copyrights, trade secret, trademark, patent, or otherwise, in all such work or work product, regardless of whether the same is subject to protection by patent, trademark, or copyright laws.
Tenant Improvement Plans Any work proposed by Tenant (the “Tenant Improvements”) shall be subject to Landlord’s reasonable prior approval and shall be subject to the other terms and conditions of this Exhibit C; provided that it will be reasonable for Landlord to withhold its approval or consent (as and when applicable under this Exhibit C) if Landlord’s Mortgagee has not consented to the matter that is the subject of such approval or consent. All architectural, engineering and other design fees shall be paid by Tenant. Tenant shall use its architect, engineers and other design professionals, all of whom shall comply with any applicable licensing or governmental requirements of the City of Seattle and the State of Washington; Tenant’s architect shall be approved by Landlord (“Tenant’s Architect”), which approval shall not be unreasonably withheld, conditioned or delayed. Landlord shall also be entitled to receive a copy of the agreement between Tenant and Tenant’s Architect (the “Architect Agreement”). Tenant shall cause Tenant’s Architect to prepare a draft space plan (the “Space Plan”) for the Tenant Improvements and shall submit the proposed Space Plan to Landlord for the latter’s approval (not to be unreasonably withheld) in a time period to allow Tenant to timely complete its Tenant Improvements under this Lease. Landlord shall deliver to Tenant any written objections, questions or comments of Landlord with regard to the Space Plan within ten (10) business days of receipt; Landlord’s consent thereto shall be deemed given if not denied in writing within said ten (10) business day period. If Landlord denies its approval, it shall specify the reasons for doing so in detail. Tenant shall cause the Space Plan to be revised to address such written comments and shall resubmit said Space Plan to Landlord for approval. Such process shall continue until Landlord has approved the Space Plan. Tenant’s Architect shall then prepare working drawings and specifications for the Tenant Improvements, including architectural, structural, plumbing, mechanical, electrical, and fire protection drawings as required, suitable for permit application (the “Working Drawings”) and shall submit the proposed Working Drawings to Landlord for the latter’s approval in a time period to allow Tenant to timely complete its Tenant Improvements under this Lease. The Space Plan and Working Drawings shall be subject to Landlord’s approval, which Landlord agrees shall not be unreasonably withheld, conditioned, or delayed. Landlord shall not be deemed to have acted unreasonably if it withholds its approval thereof because, in Landlord’s reasonable opinion, the work, as described in any such item: (i) is likely to adversely affect Building Systems, the structure of the Building or the safety of the Building and/or their occupants; (ii) might impair Landlord’s ability to furnish services to Tenant or other tenants in the Building; (iii) would materially increase the cost of operating the Building; (iv) would violate any governmental laws, rules or ordinances (or interpretations thereof); (v) contains or uses hazardous or toxic materials or substances; (vi) would negatively affect the appearance of the Building; (vii) is reasonably likely to adversely affect another tenant’s premises; or (viii) is prohibited by any ground lease affecting the Building or any mortgage, trust deed or other instrument encumbering the Building. Landlord shall deliver to Tenant any written objections, questions or comments of Landlord with regard to the Working Drawings, within ten (10) business days of Landlord’s receipt of the Working Drawings; Landlord’s consent thereto shall be deemed given if not denied in writing within said ten (10) business day period. If Landlord denies its approval, it shall specify the reasons for doing so in detail. Tenant shall cause the Working Drawings to be revised to address such written comments and shall resubmit said Working Drawings to Landlord for approval. Landlord may, when approving the Tenant Improvement Plans, elect to require Tenant to remove any Non-Standard Improvements which are made to the Premises. If Landlord so elects, Tenant shall, at its own cost, restore the Premises to the condition designated by Landlord in its election, before the last day of the Term. Such process shall continue until both parties have approved the Working Drawings. Landlord’s approval of the Space Plan and/or the Working Drawings shall not be deemed any representation or warranty that the same comply with applicable codes.
Tenant Improvements Subject to the terms and conditions hereof, Landlord agrees, at its cost and expense to complete a “turnkey” interior build-out (“Tenant Improvements”) of the Leased Premises in accordance with the conditions stated in the Work Letter attached hereto as Exhibit C and incorporated hereby pursuant to the Approved Final Plans to be finalized and approved in accordance with the Work Letter and upon approval attached thereto. Any changes or modifications to the Approved Final Plans thereafter must be done in writing and signed by both Tenant and Landlord in accordance with the Work Letter. So long as in accordance with Article 19 of this Lease, Tenant agrees that Landlord shall be entitled to select, in its reasonable discretion and acting in good faith, all architects, engineers, contractors and material suppliers necessary to furnish the labor and materials for the construction of the Tenant Improvements. Landlord shall be the sole contracting party with respect to the employment of contractors which perform the work necessary to construct the Tenant Improvements. Tenant shall not be entitled to access to the Leased Premises prior to the Date of Substantial Completion and Tenant shall not interfere with or impair in any material way the construction of the Tenant Improvements, and any such interference or impairment shall be included within a Tenant Delay as defined in the Work Letter and shall entitle Landlord to all remedies provided herein for breach of this Lease. Prior to the Possession Date, Tenant shall not enter into any contract for construction of any improvements within the Leased Premises with any person other than Landlord without Landlord's prior written consent. Tenant, at Tenant's expense, shall obtain and maintain any and all necessary permits and licenses to enable Tenant to conduct Tenant’s Permitted Use, and the failure of Tenant to obtain or maintain same shall not in any manner affect the Tenant’s obligations hereunder. Landlord shall be solely responsible, at its cost and expense, for obtaining all permits and approvals related to the Tenant Improvements.
Building Services Labor Law Article 9 applies to Contracts for building service work over $1,500 with a public agency, that: (i) involve the care or maintenance of an existing building, or (ii) involve the transportation of office furniture or equipment to or from such building, or (iii) involve the transportation and delivery of fossil fuel to such building, and (iv) the principal purpose of which is to furnish services through use of building service employees.
Base Building Work Landlord shall construct the Base Building Work as further set forth on Exhibit 10.03, attached.
Additional Work If changes in the work seem merited by Consultant or the City, and informal consultations with the other party indicate that a change is warranted, it shall be processed in the following manner: a letter outlining the changes shall be forwarded to the City by Consultant with a statement of estimated changes in fee or time schedule. An amendment to this Agreement shall be prepared by the City and executed by both Parties before performance of such services, or the City will not be required to pay for the changes in the scope of work. Such amendment shall not render ineffective or invalidate unaffected portions of this Agreement.
Tenant’s Work After the Commencement Date, Tenant at its sole cost and expense intends to construct leasehold improvements in the Demised Premises (“Tenant’s Work”) as detailed in the plans and specifications to be prepared by Tenant’s architect (“TI Architect”). Tenant shall be allowed to select a general contractor to perform the Tenant’s Work, provided said general contractor shall be properly licensed, bonded and of a reputation reasonably acceptable to Landlord. An affiliate of Landlord, Minkoff Development Corporation (“MDC”), shall act as Landlord’s construction manager to review plans and oversee construction of the Tenant’s Work by the general contractor. MDC shall receive a fee equal to one percent (1%) of the cost of the Tenant’s Work, which fee shall not exceed $50,000. Tenant shall have the right to submit plans for the Tenant’s Work in stages for portions of the Demised Premises. Tenant shall cause the TI Architect to prepare and deliver to Landlord for Landlord’s or MDC’s review preliminary plans (architectural, mechanical, electrical, plumbing and structural, if necessary) and specifications for the proposed leasehold improvements (the “Preliminary Plans”). Landlord shall have five (5) business days after its receipt thereof (or such additional time as may reasonably be necessary) to review the Preliminary Plans, request any changes it deems reasonably appropriate, and indicate on the Preliminary Plans which portions of the leasehold improvements are to be removed by Tenant prior to the expiration or termination of the Lease. The TI Architect shall modify the Preliminary Plans to accommodate Landlord’s changes, and resubmit the revised plans (the “Revised Preliminary Plans”) to Landlord for approval. If Tenant or the TI Architect elect not to make said changes to the Preliminary Plans, then Landlord shall have the right to require Tenant to perform corresponding restoration work to effect said changes prior to the expiration or termination of the Lease. Upon receipt of Landlord’s approval of the Revised Preliminary Plans, the TI Architect shall prepare a complete set of construction drawings and specifications for the construction of the proposed leasehold improvements (the “Working Drawings”). The Working Drawings shall be in sufficient detail for (i) Tenant’s general contractor to obtain bids from all trades for and to perform the work described on the Working Drawings; (ii) Tenant’s general contractor to secure building permits from the requisite governmental authorities having jurisdiction over same; and (iii) Landlord or MDC to indicate the portion of Tenant’s Work, if any, which Tenant is to remove by expiration or termination of the Lease. The Working Drawings shall conform to and be consistent with the Revised Preliminary Plans and comply with all applicable Laws and Insurance Requirements, as those terms are defined in the Lease. The Working Drawings shall be submitted to MDC for review and approval, which approval (or a request for changes to be made) shall be given within ten (10) days after receipt thereof. Within five (5) business days after MDC’s approval of the Working Drawings, as modified by any revisions requested by MDC, Landlord and Tenant shall initial same to confirm their mutual approval thereof (the “Approved Working Drawings ”). The Approved Working Drawings will indicate which portions of the Tenant’s Work, if any, will have to be removed by Tenant prior to the expiration or termination of the Lease, and Tenant will timely comply with such requirement and repair any damage to the Land or the Building caused thereby at its own expense. Tenant will have no obligation to remove any other portion of the Tenant’s Work.
Building Systems The term “Building Systems” shall mean collectively the mechanical, electrical, plumbing, sanitary, sprinkler, heating, ventilation and air conditioning, security, life safety, elevator and other service systems or facilities of the Building and the finished ceiling and Building standard lighting fixtures in the Leased Premises, that are excluding any Premises Fixtures.
Final Working Drawings After the Final Space Plan has been approved by Landlord, Tenant shall supply the Engineers with a complete listing of standard and non-standard equipment and specifications, including, without limitation, Title 24 calculations, electrical requirements and special electrical receptacle requirements for the Premises, to enable the Engineers and the Architect to complete the “Final Working Drawings” (as that term is defined below) in the manner as set forth below. Upon the approval of the Final Space Plan by Landlord and Tenant, Tenant shall promptly cause the Architect and the Engineers to complete the architectural and engineering drawings for the Premises, and Architect shall compile a fully coordinated set of architectural, structural, mechanical, electrical and plumbing working drawings in a form which is sufficiently complete to allow all of Tenant’s Agents to bid on the work and to obtain all applicable permits (collectively, the ‘‘Final Working Drawings”) and shall submit the same to Landlord for Landlord’s approval, which shall not be unreasonably withheld, conditioned, or delayed. Tenant shall supply Landlord with four (4) copies signed by Tenant of such Final Working Drawings, Landlord shall not unreasonably withhold, condition, or delay its approval of the Final Working Drawings. Landlord shall approve or reasonably EXHIBIT A disapprove of the Final Working Drawings within ten (10) business days after Landlord’s receipt thereof. If Landlord reasonably withholds its approval, Landlord shall provide Tenant with the specific reasons therefor.
Tenant Work Before commencing any repair or Alteration (“Tenant Work”), Tenant shall deliver to Landlord, and obtain Landlord’s approval of, (a) names of contractors, subcontractors, mechanics, laborers and materialmen; (b) evidence of contractors’ and subcontractors’ insurance; and (c) any required governmental permits. Tenant shall perform all Tenant Work (i) in a good and workmanlike manner using materials of a quality reasonably approved by Landlord; (ii) in compliance with any approved plans and specifications, all Laws, the National Electric Code, and Landlord’s construction rules and regulations; and (iii) in a manner that does not impair the Base Building. If, as a result of any Tenant Work, Landlord becomes required under Law to perform any inspection, give any notice, or cause such Tenant Work to be performed in any particular manner, Tenant shall comply with such requirement and promptly provide Landlord with reasonable documentation of such compliance. Landlord’s approval of Tenant’s plans and specifications shall not relieve Tenant from any obligation under this Section 7.3. In performing any Tenant Work, Tenant shall not use contractors, services, labor, materials or equipment that, in Landlord’s reasonable judgment, would disturb labor harmony with any workforce or trades engaged in performing other work or services at the Project.
