Certain Notifications Until Closing From the Signing Date until the Closing, the Company shall promptly notify the Investor of (i) any fact, event or circumstance of which it is aware and which would reasonably be expected to cause any representation or warranty of the Company contained in this Agreement to be untrue or inaccurate in any material respect or to cause any covenant or agreement of the Company contained in this Agreement not to be complied with or satisfied in any material respect and (ii) except as Previously Disclosed, any fact, circumstance, event, change, occurrence, condition or development of which the Company is aware and which, individually or in the aggregate, has had or would reasonably be expected to have a Company Material Adverse Effect; provided, however, that delivery of any notice pursuant to this Section 3.4 shall not limit or affect any rights of or remedies available to the Investor; provided, further, that a failure to comply with this Section 3.4 shall not constitute a breach of this Agreement or the failure of any condition set forth in Section 1.2 to be satisfied unless the underlying Company Material Adverse Effect or material breach would independently result in the failure of a condition set forth in Section 1.2 to be satisfied.
Obligation to Notify Owner of Existing Hazardous Materials The Contractor shall immediately notify the Owner and the Design Professional, both orally and in writing, of the presence and location of any physical evidence of, or information regarding the presence of Hazardous Materials at the Site of which it becomes aware. If the Contractor encounters Hazardous Materials on the Site the Contractor shall (i) immediately stop performance of Work or that portion of the Work affected by or affecting such Hazardous Materials; (ii) secure the contaminated area against intrusion; (iii) not disturb or remove the Hazardous Materials; (iv) not proceed, or allow any subcontractor or supplier to proceed, with any Work or other activities in the area affected by such Hazardous Materials until such materials have been properly remediated and until directed in writing to do so by the Owner; and, (v) take any other steps necessary to protect life and health and the surrounding environment. The Contractor shall be entitled to adjustment of the Contract Time and the Contract Sum pursuant to Section 5, Part 2 of these General Conditions in order to compensate for the impact of any required demolition, re-work, shutdown, delay, protection of work, disruption, and start-up resulting from the encountering of such Hazardous Materials on the Site for which the Contractor is not responsible.
CONDITION SUBSEQUENT/NON-APPROPRIATION OF FUNDING The compensation paid to CONTRACTOR pursuant to this Agreement is based on COUNTY’S continued appropriation of funding for the purpose of this Agreement, as well as the receipt of local, county, state and/or federal funding for this purpose. The parties acknowledge that the nature of government finance is unpredictable, and that the rights and obligations set forth in this Agreement are therefore contingent upon the receipt and/or appropriation of the necessary funds. In the event that funding is terminated, in whole or in part, for any reason, at any time, this Agreement and all obligations of the COUNTY arising from this Agreement shall be immediately discharged. COUNTY agrees to inform CONTRACTOR no later than ten (10) calendar days after the COUNTY determines, in its sole judgment, that funding will be terminated and the final date for which funding will be available. Under these circumstances, all billing or other claims for compensation or reimbursement by CONTRACTOR arising out of performance of this Agreement must be submitted to COUNTY prior to the final date for which funding is available. In the alternative, COUNTY and CONTRACTOR may agree, in such circumstance, to a suspension or modification of either party's rights and obligations under this Agreement. Such a modification, if the parties agree thereto, may permit a restoration of previous contract terms in the event funding is reinstated. Also in the alternative, the COUNTY may, if funding is provided to the COUNTY in the form of promises to pay at a later date, whether referred to as “government warrants,” “IOUs,” or by any other name, the COUNTY may, in its sole discretion, provide similar promises to pay to the CONTRACTOR, which the CONTRACTOR hereby agrees to accept as sufficient payment until cash funding becomes available.
Related Provisions in Bidding Documents and Works Contracts 10. The Borrower shall ensure that all bidding documents and contracts for Works contain provisions that require contractors to:
Adoption of Subsequent Orders to Incorporate Terms That a State Mortgage Regulator, if deemed necessary under the laws and regulations of the corresponding Participating State, may issue a separate administrative order to adopt and incorporate the terms and conditions of this Agreement. A State Mortgage Regulator may sua sponte issue such subsequent order without the review and approval of Respondent provided the subsequent order does not amend, alter, or otherwise change the terms of the Agreement. In the event a subsequent order amends, alters, or otherwise changes the terms of the Agreement, the terms of the Agreement, as set forth herein, will control.
JOINT SETTLEMENT RECOMMENDATION 2. Staff conducted an investigation of the Respondent’s activities. The investigation disclosed that the Respondent had engaged in activity for which the Respondent could be penalized on the exercise of the discretion of the Hearing Panel pursuant to s. 24.1 of By-law No. 1.
COMPLIANCE WITH BREACH NOTIFICATION AND DATA SECURITY LAWS Contractor shall comply with the provisions of the New York State Information Security Breach and Notification Act (General Business Law § 899-aa and State Technology Law § 208) and commencing March 21, 2020 shall also comply with General Business Law § 899-bb.
Amendments and Rights Under the Federal Power Act This Interconnection Service Agreement may be amended or supplemented only by a written instrument duly executed by all Interconnection Parties. An amendment to the Interconnection Service Agreement shall become effective and a part of this Interconnection Service Agreement upon satisfaction of all Applicable Laws and Regulations. Notwithstanding the foregoing, nothing contained in this Interconnection Service Agreement shall be construed as affecting in any way any of the rights of any Interconnection Party with respect to changes in applicable rates or charges under Section 205 of the Federal Power Act and/or FERC’s rules and regulations thereunder, or any of the rights of any Interconnection Party under Section 206 of the Federal Power Act and/or FERC's rules and regulations thereunder. The terms and conditions of this Interconnection Service Agreement and every appendix referred to therein shall be amended, as mutually agreed by the Interconnection Parties, to comply with changes or alterations made necessary by a valid applicable order of any Governmental Authority having jurisdiction hereof.
Surviving Provisions Notwithstanding any termination of this Agreement, each party’s obligations under Article VIII to indemnify other parties shall survive and not be affected by any termination of this Agreement. In addition, with respect to Existing Contracts, all provisions of this Agreement shall also survive and not be affected by any termination of this Agreement.
Fundamental Changes Merge, dissolve, liquidate, consolidate with or into another Person, or Dispose of (whether in one transaction or in a series of transactions) all or substantially all of its assets (whether now owned or hereafter acquired) to or in favor of any Person, except that, so long as no Default exists or would result therefrom:
