CUSTOMER INSTALLATION Sample Clauses

CUSTOMER INSTALLATION. ‌ 6.1 The Customer shall furnish, maintain, and operate the facilities between the Delivery Point and the Customer’s equipment, unless otherwise agreed upon in writing by the Company and the Customer.‌ 6.2 The Company reserves the right to disconnect its service at any time without notice or to refuse to connect its service if, to its knowledge and in its judgment, the Customer's installation has become or is dangerous, defective or in violation of the Company's requirements. 6.3 The Company shall not be required to commence or continue service unless and until the Customer has complied with all requirements of any and all governmental authorities and the Company with reference to the use of Gas on the premises. All inspections, reports and approvals (where required), must be received in writing by the Company before service shall be commenced or reconnected. 6.4 The Customer assumes full responsibility for the proper use of Gas delivered by the Company and for the condition, suitability and safety of any and all equipment on the Customer's premises, or owned or controlled by the Customer, which is not the Company's property. The Customer shall indemnify and save harmless the Company from and against any and all claims, expenses, legal fees, losses, suits, awards or judgments for injuries to or deaths of persons or damage of any kind, whether to property or otherwise, arising directly or indirectly by reason of: (i) the routine presence in or use of Gas from pipes owned or controlled by the Customer; or (ii) the failure of the Customer to perform any of its duties and obligations as set forth in the Schedule of Rates where such failure creates safety hazards; or (iii) the Customer's improper use of Gas or gas appliances. The Company shall be liable only for direct damages resulting from the Company's conduct of its business pursuant to this section to the extent set forth in Section 20.2. 6.5 The Customer shall notify the Company in writing before making any significant change in the Customer's gas equipment, which would affect the Company's facilities required to serve the Customer. The Customer shall be liable for any damage to the Company's property caused by Customer's additional or changed installation if made without prior notification to the Company. 6.6 The Customer shall not install, own or maintain gas piping across or in the public way or any recorded private way without the prior written consent of the Company in each case obtained.
Sample 1Sample 2
AutoNDA by SimpleDocs
CUSTOMER INSTALLATION. The installation date and time will be determined by Accelerate and communicated to Subscriber as early as possible. Prior to or during installation, Subscriber and Accelerate will determine if Subscriber’s computer(s) are configured appropriately for the Wireless Internet Access Service connection. If not, Subscriber will be required to purchase or provide the appropriate hardware for the service to work. Installation of said equipment can be installed by Accelerate for a fee. Note: It is your responsibility to make sure you have permission to attach the wireless receiver to outside of property for which you have subscribed to Accelerate for.
Sample 1Sample 2
CUSTOMER INSTALLATION. (a) Subject to Section 1.1 and Sections 6.2(c), TWC will be responsible for and provide all Installation Services, if any, to successfully allow each Service Subscriber to access and use the EarthLink High-Speed Service through a Device, regardless of which Party completes the sale. (b) The Party completing the sale for the applicable EarthLink High-Speed Service will decide whether and how much to charge the Service Subscriber for an installation fee, set-up fee or other upfront fee or charge, it being understood that there is no requirement to assess such a fee or charge. TWC hereby acknowledges and agrees that it shall not assess an installation fee to Service Subscribers if TWC does not assess an installation fee to similarly situated Road Runner customers. For Service Subscribers sold by EarthLink, EarthLink shall pay TWC, within thirty (30) days of the end of the calendar month in which an installation fee, set-up fee or other upfront fee or charge is charged by EarthLink, an amount equal to fifty percent (50%) of the amount charged, whether payable as a lump sum or otherwise. (c) TWC and EarthLink will work together toward achieving self- provisioning by Service Subscribers, and to implement self-provisioning in accordance with TWC’s generally applicable requirements regarding protection of the System Facilities as soon as available. TWC shall make all decisions regarding implementation in its reasonable business judgment; provided that TWC shall not make such decisions based upon whether a particular high-speed service customer is a Service Subscriber or a customer of another Online Provider or Road Runner. The Parties will work together toward the goal of achieving seamless self-provisioning. (d) If EarthLink or its third party installer provides any installation services for Devices or otherwise provides services that include any contact with the System Facilities, EarthLink will indemnify TWC for all damages, costs and expenses incurred by TWC resulting therefrom, including but not limited to repair of the System Facilities and fines or fees payable to the FCC for signal leakage violations.
Sample 1Sample 2
CUSTOMER INSTALLATION. The installation date and time will be determined by Provider and communicated to Subscriber as early as possible. Prior to or during installation, Subscriber and Provider will determine if Subscribers’ computer(s) are configured appropriately for the Internet Access Service connection. If not, Subscriber will be required to purchase or provide the appropriate hardware for the service to work. Installation of said equipment can be installed by Provider for a fee. SERVICE CALLS. If Provider is called to Subscriber’s site and it is determined that the problem is other than the Internet Access Service and/or the Internet Access interface, a minimum service fee of $135.00 will be charged. An additional hourly fee of $135 will be charged beyond the first hour (in half hour increments). The stated rates apply during regular business hours. Overtime, weekend, and holiday rates will be higher. Travel and related charges may also apply.
Sample 1
CUSTOMER INSTALLATION. 11.1 Both parties shall be We accept no responsibility for the adequacy, safety or other characteristics of Your Installation. 11.2 All Installations, (other than Your installation) belong to NIE at all times and must be kept at the premises and used in line with Our or NIE’s instructions. We accept no responsibility for maintaining any such Installation. 11.3 You must allow NIE authorised personnel, agents or contractors, at all reasonable times and at any time in an emergency, to enter any premises to which electricity is supplied for the purposes of reading, inspecting, testing, repairing, replacing or removing the meter or meters, Withdrawing Supply and for all other purposes in connection with supplying electricity. You must also give Us similar rights of access.
Sample 1
CUSTOMER INSTALLATION. The installation date and time will be determined by Provider and communicated to Subscriber as early as possible. Prior to or during installation, Subscriber and Provider will determine if Subscriber’s computer(s) are configured appropriately for the Wireless Network Access Service connection. If not, Subscriber will be required to purchase or provide the appropriate hardware for the service to work. Installation of said equipment can be installed by Provider for a fee. In the event a Subscriber installs a network utilizing the provided Wireless Network Access Service modem/router or any other equipment beyond the first connection, it is with the clear understanding that Provider is not responsible for any problems that may occur. Provider will not dispatch a technician to Subscriber’s location to resolve any computer and/or network-related problems without an associated fee. Provider will not perform work on any of Subscriber’s computers without an associated fee.
Sample 1
CUSTOMER INSTALLATION. Customer is responsible for installation of the Software and the installation of any required disk storage systems, network software, application servers, systems and computer terminals or workstations prior to installation of the Software.
Sample 1
AutoNDA by SimpleDocs
CUSTOMER INSTALLATION. Customer (itself or through a subcontractor) shall be solely responsible for the installation of the Products and Product Components (other than as specified in Attachment 2 of an Accepted Purchase Order) in accordance with the Installation Manuals, Technical Specifications, Applicable Law, and Standards of Practice (the “Installation Requirements”). Customer is responsible for all other work including civil, engineering, interconnect, and permitting relating to the Project other than the Work (“Work” means all activities, services, and obligations to be performed and all Product to be Delivered by or on behalf of Supplier under an Accepted Purchase Order, including but not limited to those set forth in Attachment 1 and Attachment 2 of an Accepted Purchase Order). (a) Upon Customer’s completion of installation in accordance with the Installation Requirements, Customer shall provide Supplier with a written notice of such completion (such notice, the “Notice of Installation Completion”) in the form provided in Exhibit J. (b) Supplier, within five (5) Business Days of its receipt of a Notice of Installation Completion, shall review (either virtually or at the Project Site) Customer’s installation work and either accept or reject the Notice of Installation Completion. Supplier’s approval of Customer’s Notice of Installation Completion shall not be unreasonably delayed, conditioned, or withheld. Supplier’s rejection of the Notice of Installation Completion, if applicable, shall be accompanied by a written description of the basis for such rejection in sufficient detail and scope to permit Customer (itself or through a subcontractor) to correct any errors or deficiencies. (c) Supplier shall accept the Notice of Installation Completion if the following requirements are met to Supplier’s satisfaction: i. all civil work relating to the installation of the Product has been completed, and safe access provided to the Project Site has been provided to Supplier for its performance of the Commissioning work; ii. backfeed power is available to provide power to the Product, auxiliary circuit, and balance of system, and the connection, including all permissions received, is ready for pushing or pulling power when needed; iii. all Customer-furnished equipment (e.g., switchgear) has been commissioned (in conformance with Exhibit H Attachment 1), tested, and is ready to be energized; iv. internet service1 is available with sufficient bandwidth for remote access by Supplier and...
Sample 1

Related to CUSTOMER INSTALLATION

  • Installation of Equipment You represent that there are no legal, contractual or similar restrictions on the installation of the Equipment in the location(s) you have authorized. It is your responsibility to ensure compliance with all applicable building codes, zoning ordinances, homeowners’ association rules, covenants, conditions, and restrictions related to the Service, to pay any fees or other charges, and to obtain any permits or authorizations necessary for the installation or use of the Service (collectively "Legal Requirements"). You are solely responsible for any fines or similar charges for violation of any applicable Legal Requirements. You acknowledge and agree that Viasat or its designated service provider will be required to access your premises and computer to install and maintain the Equipment, including, without limitation, the antenna and its components. Standard Equipment installations performed by Viasat-authorized installers include: (i) installation of the antenna to an outside wall or sloped roof; (ii) travel to and from your Service location within 50 miles of the installer’s office; (iii) cable routed through one exterior wall and one interior wall or floor; (iv) connection of the antenna to the modem using up to 150 feet of cable; (v) connection of the modem to one computer using up to 7 feet of cable; and (vi) required mounting and cabling hardware. Any different or additional installation services or hardware are non-standard and may result in additional charges to be agreed upon between you and the installer. All installations include attaching the Equipment to your computer, installing software on your computer and configuring your computer to optimize the performance of the Internet Service. You confirm that you have reviewed the installation plan and agreed to any associated charges. If you approved a roof mount, you acknowledge the potential risks associated with this type of installation (including, without limitation, with respect to any warranty that applies to your roof or roof membrane). By signing this Agreement, scheduling one or more service or installation visits, and permitting us or our service provider to enter your home, you are authorizing Viasat and its service provider to perform all of the above actions. You are responsible for backing up the data on your computer and we highly recommend that you do so prior to permitting access to us or one of our designated service providers. NEITHER VIASAT NOR ITS SERVICE PROVIDER SHALL HAVE ANY LIABILITY WHATSOEVER FOR ANY LOSSES RESULTING FROM THE EQUIPMENT OR ANY INSTALLATION, REPAIR OR OTHER SERVICES ASSOCIATED WITH THE EQUIPMENT, INCLUDING WITHOUT LIMITATION, DAMAGE TO YOUR PREMISES OR LOSS OF SOFTWARE, DATA OR OTHER INFORMATION FROM YOUR COMPUTER. This limitation does not apply to any damages arising from the gross negligence or willful misconduct of us or one of our designated service providers. Time frames for installation, if any, are not guaranteed and may vary depending on the types of services requested and other factors.

  • Utility Installations Trade Fixtures Alterations 8.3.1 The term “Utility Installations” refers to all floor and window coverings, air and/or vacuum lines, power panels, electrical distribution, security and fire protection systems, communication cabling, lighting fixtures, HVAC equipment, plumbing, and fencing in or on the Premises. The term “Trade Fixtures” shall mean Lessee’s machinery and equipment that can be removed without doing material damage to the Premises. The term “Alterations” shall mean any modification of the improvements, other than Utility Installations or Trade Fixtures, whether by addition or deletion. “Lessee Owned Alterations and/or Utility Installations” are defined as Alterations and/or Utility Installations made by Lessee that are not yet owned by Lessor pursuant to Section 8.4.1.

  • Installation Waiver Company will waive the one-time installation charges associated with the implementation of Services within the 48 contiguous States of the U.S. provided under this Agreement except for the following services: (i) eDSL, (ii) VPN, (iii) Internet Dedicated OC3, OC12, OC48, Gig-E, (iv) PTT / third party services (including International Access and Company International), (v) Data Center, (vi) Paging, (vii) Managed Services, (viii) CPE, (ix) Enhanced Call Routing, (x) Local Disaster Recovery, (xi) Audio, Video and Net Conferencing, (xii) Voice over IP Services, (xiii) Security Services, (xiv) Non-Listing/Non-Published Service, (xv) Telecommunications Service Priority, and (xvi) Services provided by Company incumbent local exchange carriers (“ILECs”) or by Cellco Partnership and its affiliates d/b/a Company Wireless. Usage charges, monthly recurring charges, expedite charges, change charges, surcharges, charges for an unlisted or non-published number, any charges imposed by third parties (including access, egress, jack, or wiring charges), taxes or tax-like surcharges, or other Governmental Charges will not be waived.

  • Customer Equipment Customer represents and warrants that it owns or has the legal right and authority, and will continue to own or maintain the legal right and authority during the term of this Agreement, to place and use the Customer Equipment as contemplated by this Agreement. Customer further represents and warrants that its placement, arrangement, and use of the Customer Equipment in the Internet Data Centers complies with the Customer Equipment Manufacturer's environmental and other specifications.

  • Software Installation The AGENCY shall request approval in writing from the COUNTY prior to installation of any software on COUNTY computer equipment. All software installations must be supervised by COUNTY technical support staff and proof of licensing is required. Upon completion, the AGENCY is responsible for reconfiguring the computers back to the original state.

  • Maintenance Repairs Utility Installations Trade Fixtures and Alterations (a) Section 8.1(a) is amended in its entirety to read as follows: Subject to the provisions of Sections 8.2, 10, and 15, Tenant shall, at Tenant's sole cost and expense and at all times, keep the Building Complex and every part thereof in good order, condition and repair (whether or not the need for such repairs occurs as a result of Tenant's use, any prior use, the elements or the age of such portion of the Building Complex), including, without limiting the generality of the foregoing, plumbing, electrical lighting facilities, boilers, fired or unfired pressure vessels, fire hose connections, fixtures, interior walls, exterior walls, roof, ceilings, floors, windows, doors, plate glass, and skylights, parking areas and lighting, driveways, sidewalks, landscaping, irrigation systems, and subject to Section 8.1(b) below, heating, air conditioning and ventilating systems, but excluding any items which are the responsibility of Landlord pursuant to Section 8.2 below. Tenant, in keeping the Building Complex in good order, condition and repair, shall exercise and perform good maintenance practices, including, without limitation, providing janitorial services to the Building Complex substantially equivalent to those attached hereto as Exhibit I and, snow, ice and trash removal service. Tenant's obligations shall include restorations, replacements or renewals when necessary to keep the Building Complex and all improvements thereon or a part thereof in good order, condition and state of repair. (b) Section 8.1(b) is amended in its entirety to read as follows: Tenant shall procure and pay the cost of a contract for maintenance of the heating, air conditioning and ventilating systems for the Building Complex with a reputable contractor licensed in the State of Colorado and reasonably satisfactory to Landlord. (c) Section 8.1(c) is amended to replace, in both places where it is used, the word "Premises" with the words "Building Complex" and to add the words "including, without limitation, the Premises," before the words "after twenty". (d) Section 8.2 is amended in its entirety to read as follows:

  • Installation Where installation is required, Contractor shall be responsible for placing and installing the equipment or parts in the required locations at no additional charge, unless otherwise specified in the Price Sheets. All materials used in the installation shall be of good quality and shall be free of defects that would diminish the appearance of the equipment or render it structurally or operationally unsound. Installation includes the furnishing of any equipment, rigging, and materials required to install or replace the equipment or parts in the proper location. Contractor shall protect the site from damage and shall repair damages or injury caused during installation by Contractor or its employees or agents. If any alteration, dismantling, excavation, etc., is required to achieve installation, the Contractor shall promptly restore the structure or site to its original condition. Contractor shall perform installation work so as to cause the least inconvenience and interference with Customers and with proper consideration of others on site. Upon completion of the installation, the location and surrounding area of work shall be left clean and in a neat and unobstructed condition, with everything in satisfactory repair and order.

  • Equipment Installation In order to meet its obligations under this Agreement, a Party that owns, rents, or leases equipment (the equipment owner) may require installation of such equipment on property owned by another Party (the property owner), provided that the property is being used for an electric utility purpose and that the property owner shall not be required to do so if it would thereby be prevented from performing its own obligations or exercising its rights under this Agreement.

  • System Upgrade Facilities and System Deliverability Upgrades Connecting Transmission Owner shall design, procure, construct, install, and own the System Upgrade Facilities and System Deliverability Upgrades described in Appendix A hereto. The responsibility of the Developer for costs related to System Upgrade Facilities and System Deliverability Upgrades shall be determined in accordance with the provisions of Attachment S to the NYISO OATT.

  • Installation Services The Bitstream 2a Service includes a Standard Install as set out below (in each case to the extent that the relevant provisioning works are not already complete for the relevant Service Order).1

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!