Frequency and Purpose Sample Clauses

Frequency and Purpose. Staff committees shall meet at least monthly to discuss issues relevant to the teaching staff of the school. Any employee may bring forward an issue for discussion by the staff committee at any time.
Sample 1Sample 2Sample 3See All (9)
AutoNDA by SimpleDocs
Frequency and Purpose. 1. Each employee will receive at least one (1) performance review a year. This review will be due no later than forty-five (45) calendar days beyond the employee’s performance review due date to ensure the review includes the full prior twelve (12) months’ performance. For performance reviews completed beyond the forty-five (45) calendar day date, employees will be determined to have performed at “acceptable” levels and any appropriate step increase will be processed retroactively to the employee’s performance review due date, if not already applied. More frequent performance reviews may be completed to address performance issues, or to be used as a letter of recommendation. a. The performance review should be created with input from the employee as to accomplishments achieved in the prior twelve (12) months, recognized areas of improvement, suggestions for training, and performance objectives for the next twelve (12) months. b. Completed employee performance reviews become a permanent part of the employee’s personnel file. c. The employee performance review will be discussed with the employee, and the employee may provide a written response to be included in the personnel file. 2. Probationary employees shall receive a performance review at approximately three (3) month intervals until they have successfully completed their probationary period. A probationary employee may be dismissed at any time during probation upon recommendation of their supervisor. 3. Newly promoted employees, or employees who have transferred laterally to a different job title shall complete a four (4) month probation period in the new position. They will receive a performance review completed by their supervisor approximately two (2) months and approximately four (4) months following their new performance review date. 4. For job titles not possessing a standardized performance review tool, the supervisor and employee(s) will identify performance objectives for the position. The objectives should be made known with sufficient time to show progress prior to the employee’s performance review due date, preferably one (1) year in advance. 5. If the performance review identifies performance issues which need to be addressed, a Corrective Action Plan (CAP) may be created to provide the employee with information as to how to correct the performance issues. If a step increase is due to the employee, the increase will be placed on “hold” during the term of the Corrective Action Plan. If the ...
Sample 1

Related to Frequency and Purpose

  • Introduction and Purpose Introduction • Neighbourhood Development Plans • Neighbourhood Development Orders

  • Scope and Purpose 1.01 This document is intended to set out general guidelines and principles regarding child welfare sector integrations during the term of this agreement which are mandated by the Ministry and for which local Human Resources Adjustment Plans (HRAP) are required to be negotiated. Subject to the following terms, these principles will serve as the framework for the treatment of bargaining unit employees and will apply to subsequent negotiations with unions, as may be required, as part of an integration arising within the context of the Ontario Labour Relations Act (OLRA) or PSLRTA, whichever is applicable. 1.02 Employees who may be impacted by an integration are valued and are to be treated fairly and respectfully. The parties agree that they will make reasonable efforts to reduce any negative affect on employees as a result of an integration in accordance with the following.

  • PRE-CONSTRUCTION PHASE SERVICES The Pre-Construction Phase shall be deemed to commence upon the date specified in a written Notice to Proceed with Pre-Construction Phase Services issued by Owner and shall continue through completion of the Construction Documents and procurement of all major Subcontractor agreements. Contractor is not entitled to reimbursement for any costs incurred for Pre-Construction Phase Services performed before issuance of the written Notice to Proceed. Pre-Construction Phase Services may overlap Construction Phase Services. Contractor shall perform the following Pre-Construction Phase Services:

  • INTENT AND PURPOSE The Employer and the Union each represent that the purpose and the intent of this Agreement is to promote cooperation and harmony, to recognize mutual interests, to provide a channel through which information and problems may be transmitted from one to the other, to formulate rules to govern the relationship between the Union and the Employer, to promote efficiency and service, and to set forth herein the basic agreements covering rates of pay, hours of work, and conditions of employment.

  • Formation and Purpose Promptly following the Effective Date, the Parties shall confer and then create the JSC and the IPC, and, optionally, create one or more of the other Committees listed in the chart below. Each Committee shall have the purpose indicated in the chart. To the extent that after conferring both Parties agree to not create a Committee (other than the JSC and the IPC), the creation of such Committee shall be deferred until one Party informs the other Party of its then desire to create the so-deferred Committee, at which point the Parties will thereafter promptly create the so-deferred Committee. Joint Steering Committee (“JSC”) Establish projects for the Bacteriophage Program and establish the priorities, as well as approve budgets for such projects. Approve all subcommittee projects and plans (except for decisions of the IPC). The JSC shall establish budgets not less than on a quarterly basis. Chemistry, Manufacturing and Controls Committee (“CMCC”) Establish project plans and review and approve activities and budgets for chemistry, manufacturing, and controls under the Bacteriophage Program. Regulatory Committee (“RC”) Review and approve all research and development plans and projects, including clinical projects, associated with any necessary regulatory approvals, all associated publications, and all regulatory filings and correspondence relating to gaining regulatory approval for new Ampliphi Products under the Bacteriophage Program; and review and approve itemized budgets with respect to the foregoing. Commercialization Committee (“CC”) Establish project plans and review and approve activities and budgets for Commercialization activities under the Bacteriophage Program. Portions herein identified by [*****] have been omitted pursuant to a request for confidential treatment under Rule 24b-2 of the Securities Exchange Act of 1934, as amended. A complete copy of this document has been filed separately with the Securities and Exchange Commission. Intellectual Property Committee (“IPC”) Evaluate all intellectual property issues in connection with the Bacteriophage Program; review and approve itemized budgets with respect to the foregoing.

  • Parties and Purpose This agreement (the “Agreement”) is entered by and between certain portfolios and classes thereof, specified below and in Schedule C, of Franklin Xxxxxxxxx Variable Insurance Products Trust, an open-end management investment company organized as a statutory trust under Delaware law (the “Trust”), Franklin/Xxxxxxxxx Distributors, Inc., a California corporation which is the principal underwriter for the Trust (the “Underwriter,” and together with the Trust, “we” or “us”), the insurance company identified on Schedule A (together “you”) and your distributor, on your own behalf and on behalf of each segregated asset account maintained by you that is listed on Schedule B, as that schedule may be amended from time to time (“Account” or “Accounts”). The purpose of this Agreement is to entitle you, on behalf of the Accounts, to purchase the shares, and classes of shares, of portfolios of the Trust (“Portfolios”) that are identified on Schedule C, consistent with the terms of the prospectuses of the Portfolios, solely for the purpose of funding benefits of your variable life insurance policies or variable annuity contracts (“Contracts”) that are identified on Schedule D. This Agreement does not authorize any other purchases or redemptions of shares of the Trust.

  • Construction Phase Services 3.1.1 – Basic Construction Services

  • Background and Purpose Executive was employed by the Company. Executive's employment is ending effective __________ under the conditions described in Section 3.1 of the Executive Change of Control Agreement ("Agreement") by and between Executive and the Company dated _____________, 2012. The purpose of this Release is to settle, and the parties hereby settle, fully and finally, any and all claims the Releasing Parties may have against the Released Parties, whether asserted or not, known or unknown, including, but not limited to, claims arising out of or related to Executive's employment, any claim for reemployment, or any other claims whether asserted or not, known or unknown, past or future, that relate to Executive's employment, reemployment, or application for reemployment.

  • Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.

  • Access to Work Locations Reasonable access to employee work locations shall be granted officers of the Association and their officially designated representatives for the purpose of processing grievances or contacting members of the Association concerning business within the scope of representation. Such officers or representatives shall not enter any work location without the consent of the City Manager. Access shall be restricted so as not to interfere with the normal operations of the department or with established safety or security requirements. Solicitation of membership and activities concerned with the internal management of the Association, such as collecting dues, holding membership meetings, campaigning for office, conducting elections and distributing literature, shall not be conducted during working hours.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!