IN ADDITION, AS TO ITS CONSTRUCTION CONTRACTS THE GRANTEE AGREES Sample Clauses

IN ADDITION, AS TO ITS CONSTRUCTION CONTRACTS THE GRANTEE AGREES. 1. When scheduling workers in each construction trade, the Grantee and its contractor or subcontractor agree to attempt in good faith to employ minority and female workers in each construction trade consistent with the applicable employment goal prescribed by N.J.A.C. 17:27-7.3; provided, however, that the Affirmative Action Office may, in its discretion, exempt a Grantee and its Contractor or Subcontractor from compliance with the good faith procedures prescribed by 1, 2 and 3 below, as long as the Affirmative Action Office is satisfied that the Grantee and contractor are scheduling workers provided by a union which provides evidence, in accordance with standards prescribed by the Affirmative Action Office, that its percentage of active "card carrying" members who are minority and female workers is equal to or greater than the applicable employment goal prescribed by N.J.A.C. 17:27-7.3, promulgated by the Treasurer pursuant to P.L. 1975, c. 127, as amended and supplemented from time to time. The Grantee and its contractor or subcontractor agree that a good faith effort shall include compliance with the following procedures: (a) If the Grantor or its contractor or subcontractor, as applicable, has a referral agreement or arrangement with a union for construction trade, the Grantee or its contractor or subcontractor, as applicable, shall, within three days of the contract award, seek assurances from the union that it will cooperate with the Grantee and its contractor or subcontractor as it fulfills its affirmative action obligations under this Grant and in accordance with the rules promulgated by the Treasurer pursuant to P.L. 1975, c. 127, as supplemented and amended from time to time. If the Grantee and its contractor or subcontractor are unable to obtain said assurances from the construction trade union at least five days prior to the commencement of construction work, the Grantee and its contractor or subcontractor agree to attempt to hire minority and female workers directly, consistent with the applicable employment goal. If the Grantee's or its contractor's or subcontractor's prior experience with a construction trade union, regardless of whether the union has provided said assurances, indicates a significant possibility that the trade union will not refer sufficient minority and female workers consistent with the applicable employment goal, the Grantee and its contractor or subcontractor agree to be prepared to hire minority and female workers direc...
Sample 1
AutoNDA by SimpleDocs

Related to IN ADDITION, AS TO ITS CONSTRUCTION CONTRACTS THE GRANTEE AGREES

  • Requirements Pertaining Only to Federal Grants and Subrecipient Agreements If this Agreement is a grant that is funded in whole or in part by Federal funds:

  • Reference to and Effect Upon the Credit Agreement (a) The Credit Agreement and the other Loan Documents shall remain in full force and effect, as amended hereby, and are hereby ratified and confirmed. (b) The execution, delivery and effectiveness of this Amendment shall not operate as a waiver of any right, power or remedy of Agent or any Lender under the Credit Agreement or any Loan Document, nor constitute a waiver or amendment of any provision of the Credit Agreement or any Loan Document, except as specifically set forth herein. Upon the effectiveness of this Amendment, each reference in the Credit Agreement to “this Credit Agreement,” “hereunder,” “hereof,” “herein” or words of similar import shall mean and be a reference to the Credit Agreement as amended hereby.

  • Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.

  • Enforcement of Due-on-Sale Clauses; Assumption and Modification Agreements; Certain Assignments (a) When any Mortgaged Property is conveyed by the Mortgagor, the Master Servicer or Subservicer, to the extent it has knowledge of such conveyance, shall enforce any due-on-sale clause contained in any Mortgage Note or Mortgage, to the extent permitted under applicable law and governmental regulations, but only to the extent that such enforcement will not adversely affect or jeopardize coverage under any Required Insurance Policy. Notwithstanding the foregoing: (i) the Master Servicer shall not be deemed to be in default under this Section 3.13(a) by reason of any transfer or assumption which the Master Servicer is restricted by law from preventing; and (ii) if the Master Servicer determines that it is reasonably likely that any Mortgagor will bring, or if any Mortgagor does bring, legal action to declare invalid or otherwise avoid enforcement of a due-on-sale clause contained in any Mortgage Note or Mortgage, the Master Servicer shall not be required to enforce the due-on-sale clause or to contest such action. (b) Subject to the Master Servicer's duty to enforce any due-on-sale clause to the extent set forth in Section 3.13(a), in any case in which a Mortgaged Property is to be conveyed to a Person by a Mortgagor, and such Person is to enter into an assumption or modification agreement or supplement to the Mortgage Note or Mortgage which requires the signature of the Trustee, or if an instrument of release signed by the Trustee is required releasing the Mortgagor from liability on the Mortgage Loan, the Master Servicer is authorized, subject to the requirements of the sentence next following, to execute and deliver, on behalf of the Trustee, the assumption agreement with the Person to whom the Mortgaged Property is to be conveyed and such modification agreement or supplement to the Mortgage Note or Mortgage or other instruments as are reasonable or necessary to carry out the terms of the Mortgage Note or Mortgage or otherwise to comply with any applicable laws regarding assumptions or the transfer of the Mortgaged Property to such Person; provided, however, none of such terms and requirements shall either (i) both (A) constitute a "significant modification" effecting an exchange or reissuance of such Mortgage Loan under the REMIC Provisions and (B) cause any portion of any REMIC formed under the Series Supplement to fail to qualify as a REMIC under the Code or (subject to Section 10.01(f)), result in the imposition of any tax on "prohibited transactions" or (ii) constitute "contributions" after the start-up date under the REMIC Provisions. The Master Servicer shall execute and deliver such documents only if it reasonably determines that (i) its execution and delivery thereof will not conflict with or violate any terms of this Agreement or cause the unpaid balance and interest on the Mortgage Loan to be uncollectible in whole or in part, (ii) any required consents of insurers under any Required Insurance Policies have been obtained and (iii) subsequent to the closing of the transaction involving the assumption or transfer (A) the Mortgage Loan will continue to be secured by a first mortgage lien pursuant to the terms of the Mortgage, (B) such transaction will not adversely affect the coverage under any Required Insurance Policies, (C) the Mortgage Loan will fully amortize over the remaining term thereof, (D) no material term of the Mortgage Loan (including the interest rate on the Mortgage Loan) will be altered nor will the term of the Mortgage Loan be changed and (E) if the seller/transferor of the Mortgaged Property is to be released from liability on the Mortgage Loan, such release will not (based on the Master Servicer's or Subservicer's good faith determination) adversely affect the collectability of the Mortgage Loan. Upon receipt of appropriate instructions from the Master Servicer in accordance with the foregoing, the Trustee shall execute any necessary instruments for such assumption or substitution of liability as directed in writing by the Master Servicer. Upon the closing of the transactions contemplated by such documents, the Master Servicer shall cause the originals or true and correct copies of the assumption agreement, the release (if any), or the modification or supplement to the Mortgage Note or Mortgage to be delivered to the Trustee or the Custodian and deposited with the Mortgage File for such Mortgage Loan. Any fee collected by the Master Servicer or such related Subservicer for entering into an assumption or substitution of liability agreement will be retained by the Master Servicer or such Subservicer as additional servicing compensation. (c) The Master Servicer or the related Subservicer, as the case may be, shall be entitled to approve a request from a Mortgagor for a partial release of the related Mortgaged Property, the granting of an easement thereon in favor of another Person, any alteration or demolition of the related Mortgaged Property (or, with respect to a Cooperative Loan, the related Cooperative Apartment) without any right of reimbursement or other similar matters if it has determined, exercising its good faith business judgment in the same manner as it would if it were the owner of the related Mortgage Loan, that the security for, and the timely and full collectability of, such Mortgage Loan would not be adversely affected thereby and that any portion of any REMIC formed under the Series Supplement would not fail to continue to qualify as a REMIC under the Code as a result thereof and (subject to Section 10.01(f)) that no tax on "prohibited transactions" or "contributions" after the startup day would be imposed on any such REMIC as a result thereof. Any fee collected by the Master Servicer or the related Subservicer for processing such a request will be retained by the Master Servicer or such Subservicer as additional servicing compensation. (d) Subject to any other applicable terms and conditions of this Agreement, the Trustee and Master Servicer shall be entitled to approve an assignment in lieu of satisfaction with respect to any Mortgage Loan, provided the obligee with respect to such Mortgage Loan following such proposed assignment provides the Trustee and Master Servicer with a "Lender Certification for Assignment of Mortgage Loan" in the form attached hereto as Exhibit M, in form and substance satisfactory to the Trustee and Master Servicer, providing the following: (i) that the substance of the assignment is, and is intended to be, a refinancing of such Mortgage; (ii) that the Mortgage Loan following the proposed assignment will have a rate of interest at least 0.25 percent below or above the rate of interest on such Mortgage Loan prior to such proposed assignment; and (iii) that such assignment is at the request of the borrower under the related Mortgage Loan. Upon approval of an assignment in lieu of satisfaction with respect to any Mortgage Loan, the Master Servicer shall receive cash in an amount equal to the unpaid principal balance of and accrued interest on such Mortgage Loan and the Master Servicer shall treat such amount as a Principal Prepayment in Full with respect to such Mortgage Loan for all purposes hereof.

  • Further Assurances; Change in Name or Jurisdiction of Origination, etc (i) The Borrower hereby authorizes and hereby agrees from time to time, at its own expense, promptly to execute (if necessary) and deliver all further instruments and documents, and to take all further actions, that may be necessary or desirable, or that the Administrative Agent may reasonably request, to perfect, protect or more fully evidence the security interest granted pursuant to this Agreement or any other Transaction Document, or to enable the Administrative Agent (on behalf of the Secured Parties) to exercise and enforce the Secured Parties’ rights and remedies under this Agreement and the other Transaction Document. Without limiting the foregoing, the Borrower hereby authorizes, and will, upon the request of the Administrative Agent, at the Borrower’s own expense, execute (if necessary) and file such financing statements or continuation statements, or amendments thereto, and such other instruments and documents, that may be necessary, or that the Administrative Agent may reasonably request, to perfect, protect or evidence any of the foregoing. (ii) The Borrower authorizes the Administrative Agent to file financing statements, continuation statements and amendments thereto and assignments thereof, relating to the Receivables, the Related Security, the related Contracts, Collections with respect thereto and the other Collateral without the signature of the Borrower. A photocopy or other reproduction of this Agreement shall be sufficient as a financing statement where permitted by law. (iii) The Borrower shall at all times be organized under the laws of the State of Delaware and shall not take any action to change its jurisdiction of organization. (iv) The Borrower will not change its name, location, identity or corporate structure unless (x) the Borrower, at its own expense, shall have taken all action necessary or appropriate to perfect or maintain the perfection of the security interest under this Agreement (including, without limitation, the filing of all financing statements and the taking of such other action as the Administrative Agent may request in connection with such change or relocation) and (y) if requested by the Administrative Agent, the Borrower shall cause to be delivered to the Administrative Agent, an opinion, in form and substance satisfactory to the Administrative Agent as to such UCC perfection and priority matters as the Administrative Agent may request at such time.

  • Collateral Protection Expenses Preservation of Collateral (a) If an Event of Default shall have occurred and be continuing, the Agent may discharge taxes and other encumbrances at any time levied or placed on any of the Collateral, make repairs thereto and pay any necessary filing fees. Each Grantor agrees to reimburse the Agent on demand for any and all expenditures so made. The Agent shall have no obligation to any Grantor to make any such expenditures, nor shall the making thereof relieve any Grantor of any default. (b) Anything herein to the contrary notwithstanding, each Grantor shall remain liable under each contract or agreement comprised in the Collateral to be observed or performed by such Grantor thereunder. The Agent shall not have any obligation or liability under any such contract or agreement by reason of or arising out of this Agreement or the receipt by the Agent of any payment relating to any of the Collateral, nor shall the Agent be obligated in any manner to perform any of the obligations of any Grantor under or pursuant to any such contract or agreement, to make inquiry as to the nature or sufficiency of any payment received by the Agent in respect of the Collateral or as to the sufficiency of any performance by any party under any such contract or agreement, to present or file any claim, to take any action to enforce any performance or to collect the payment of any amounts which may have been assigned to the Agent or to which the Agent may be entitled at any time or times. The Agent’s sole duty with respect to the custody, safe keeping and physical preservation of the Collateral in its possession, under Sections 9-207 and 9-208 of the UCC or otherwise, shall be to deal with such Collateral in the same manner as the Agent deals with similar property for its own account. (c) Each Grantor shall, to the extent reasonably necessary to preserve and maintain the Intellectual Property Collateral and the interest of the Agent therein, diligently pursue legal or other action to enforce the Intellectual Property Collateral and any licenses thereof.

  • Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. Does Vendor agree? Yes, Vendor agrees Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body.

  • Inconsistencies with Other Documents; Independent Effect of Covenants (a) In the event there is a conflict or inconsistency between this Agreement and any other Loan Document, the terms of this Agreement shall control; provided that, other than for purposes of Article XI, any provision of the other Loan Documents which imposes additional burdens on any Borrower or its Subsidiaries or further restricts the rights of such Borrower or its Subsidiaries or gives the Administrative Agent or any Lender additional rights shall not be deemed to be in conflict or inconsistent with this Agreement and shall be given full force and effect. (b) Each Borrower expressly acknowledges and agrees that each covenant contained in Article VIII, IX, or X hereof shall be given independent effect. Accordingly, no Borrower shall engage in any transaction or other act otherwise permitted under any covenant contained in Article VIII, IX, or X if, before or after giving effect to such transaction or act, such Borrower shall or would be in breach of any other covenant contained in Article VIII, IX, or X.

  • Pennsylvania Motor Vehicle Sales Finance Act Licenses The Indenture Trustee shall use its best efforts to maintain the effectiveness of all licenses required under the Pennsylvania Motor Vehicle Sales Finance Act in connection with this Indenture and the transactions contemplated hereby until the lien and security interest of this Indenture shall no longer be in effect in accordance with the terms hereof.

  • Retention or Repurchase of Assets Essential to Receiver (a) The Receiver may refuse to sell to the Assuming Institution, or the Assuming Institution agrees, at the request of the Receiver set forth in a written notice to the Assuming Institution, to assign, transfer, convey, and deliver to the Receiver all of the Assuming Institution's right, title and interest in and to, any Asset or asset essential to the Receiver as determined by the Receiver in its discretion (together with all Credit Documents evidencing or pertaining thereto), which may include any Asset or asset that the Receiver determines to be: (i) made to an officer, director, or other Person engaging in the affairs of the Failed Bank, its Subsidiaries or Affiliates or any related entities of any of the foregoing; (ii) the subject of any investigation relating to any claim with respect to any item described in Section 3.5(a) or (b), or the subject of, or potentially the subject of, any legal proceedings; (iii) made to a Person who is an Obligor on a loan owned by the Receiver or the Corporation in its corporate capacity or its capacity as receiver of any institution; (iv) secured by collateral which also secures any asset owned by the Receiver; or (v) related to any asset of the Failed Bank not purchased by the Assuming Institution under this Article III or any liability of the Failed Bank not assumed by the Assuming Institution under Article II. (b) Each such Asset or asset purchased by the Receiver shall be purchased at a price equal to the Repurchase Price thereof less the Related Liability Amount with respect to any Related Liabilities related to such Asset or asset, in each case determined as of the date of the notice provided by the Receiver pursuant to Section 3.6(a). The Receiver shall pay the Assuming Institution not later than the twentieth (20th) Business Day following receipt of related Credit Documents and Credit Files together with interest on such amount at the Settlement Interest Rate for the period from and including the date of receipt of such documents to and including the day preceding the day on which payment is made. The Assuming Institution agrees to administer and manage each such Asset or asset in accordance with usual and prudent banking standards and business practices until each such Asset or asset is purchased by the Receiver. All transfers with respect to Asset or assets under this Section 3.6 shall be made as provided in Section 9.6. The Assuming Institution shall transfer all such Asset or assets and Related Liabilities to the Receiver without recourse, and shall indemnify the Receiver against any and all claims of any Person claiming by, through or under the Assuming Institution with respect to any such Asset or asset, as provided in Section 12.4.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!