SEP CONSTRUCTION MANAGEMENT Sample Clauses

SEP CONSTRUCTION MANAGEMENT. The SFPUC will use the SEP Program Construction Manager to provide broad and strategic focus and integration across all project delivery elements including, but not limited to: assistance in developing top-level execution strategies; program auditing and reporting functions; oversight of program-level construction schedule and cost controls, program-level risk management, and program-level safety management; recommendations for construction contracting strategies; recommendations for the allocation of contingencies; and ongoing alignment of top-level strategies to successfully achieve programmatic and technical requirements. Other program construction management responsibilities include, but are not limited to, the following:  Provide overall SEP program-level CM oversight and supervision to ensure that project CM teams are conforming to the SFPUC’s goals and requirements in accordance with the CM Plan, Safety Approach, and CM Procedures, and to ensure program standardization, conformity, and consistency throughout the duration of SEP project construction.  Support the SSIP Deputy Director for Construction by providing SEP program-level oversight and supervision of CM activities including, but not limited to: progress, cost, and schedule controls; auditing and reporting functions; construction administration services and construction contracts management; construction risk management; construction safety; project interface coordination; shutdown schedule coordination; review and analysis of construction changes and claims; environmental compliance services and assistance in coordinating with regulatory agencies; public outreach and communications; startup and commissioning; and closeout.  Provide implementation and management of the CM Plan, Safety Approach, CM Procedures, and current project CM staffing plans and budgets, related contingencies, and escalation factors; continuously make recommendations for improvement and provide revisions as required and requested by the SSIP’s Deputy Director of Construction.  Use the SFPUC’s Construction Management Information System (CMIS) to provide quality assurance (QA) on CMIS utilization by project CM teams in order to oversee program-level construction activities and develop construction status/progress reports for the SEP (and for other wastewater projects, as needed).  Provide program-wide construction QA, including construction QA oversight of the individual SEP project CM teams.  Review existing project...
Sample 1
AutoNDA by SimpleDocs

Related to SEP CONSTRUCTION MANAGEMENT

  • Construction Management Landlord or its Affiliate or agent shall supervise the Work, make disbursements required to be made to the contractor, and act as a liaison between the contractor and Tenant and coordinate the relationship between the Work, the Building and the Building’s Systems. In consideration for Landlord’s construction supervision services, Tenant shall pay to Landlord a construction supervision fee equal to three percent (3%) of Tenant’s Costs specified in Section 7.

  • Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.

  • PRE-CONSTRUCTION PHASE SERVICES The Pre-Construction Phase shall be deemed to commence upon the date specified in a written Notice to Proceed with Pre-Construction Phase Services issued by Owner and shall continue through completion of the Construction Documents and procurement of all major Subcontractor agreements. Contractor is not entitled to reimbursement for any costs incurred for Pre-Construction Phase Services performed before issuance of the written Notice to Proceed. Pre-Construction Phase Services may overlap Construction Phase Services. Contractor shall perform the following Pre-Construction Phase Services:

  • Contract Construction 6.27.1 The parties acknowledge that each party and its counsel have reviewed this CONTRACT and that the normal rule of construction to the effect that any ambiguities are to be resolved against the drafting party shall not be employed in the interpretation of this CONTRACT or any amendment or exhibits hereto.

  • Law; Construction This Agreement and any claim, counterclaim or dispute of any kind or nature whatsoever arising out of or in any way relating to this Agreement (“Claim”), directly or indirectly, shall be governed by, and construed in accordance with, the internal laws of the State of New York.

  • Project Construction The Contractor agrees to provide continuous on-site supervision on each Job Order, while progress on the project is being accomplished. The Contractor’s Project Manager will ensure: 1. Coordination and providing supervision to all Subcontractor and workers; 2. Posting of the prevailing wage scale; 3. Maintaining a copy of the Contractors safety program manual made available to all construction personnel; 4. Conducting weekly on-site safety meetings; 5. Completing the daily labor and construction progress log on a daily basis and submit copies to the County on a daily basis. Copies of the previous day’s reports must be submitted by 9:00AM of the following day. a. Daily labor log is to include a listing of Subcontractor(s) and a count of workers by trade providing services for the day. b. Construction progress log is to include a narrative of the Work provided by trade(s). Narrative agrees to include the various areas of the jobsite where Work was performed and any problems or conditions that were encountered. c. In the event the Contractor fails to provide a daily log and/or construction progress log, the County may impose damages against the Contractor in the amount of fifty dollars ($50.00) for each log and deduct from the Contractor’s payment request, for each day the Contractor does not provide the documentation. 6. County may suspend Contractor operations if no Contractor Superintendent is observed. All delays caused by the suspension will be the responsibility of the Contractor. No time extension or claims for cost(s) associated with the suspension will be granted by the County.

  • Interconnection Facilities Engineering Procurement and Construction Interconnection Facilities, Network Upgrades, and Distribution Upgrades shall be studied, designed, and constructed pursuant to Good Utility Practice. Such studies, design and construction shall be based on the assumed accuracy and completeness of all technical information received by the Participating TO and the CAISO from the Interconnection Customer associated with interconnecting the Large Generating Facility.

  • Construction Management Fee The Construction Management Fee for the Project shall be either a ☒Lump Sum or ☐Not-To-Exceed Fee of Thirty-Six Thousand, Eight Hundred Forty-Six Dollars and Twenty-Six Cents ($36,846.26). NOTE: Allowances will be on a Not-To-Exceed basis. All unused funds will be returned to the School District at the time of construction closeout. Fee will be paid only on cost of work for these items. Exhibit C- Project Assignment Page 2 of 4

  • General Construction 20.2.1. Binding Nature.............................................. 20.2.2. Entire Agreement............................................ 20.2.3. Governing Law............................................... 20.2.4. Indulgences Not Waivers..................................... 20.2.5. Titles Not to Affect Interpretation......................... 20.2.6.

  • Construction Management Services a. A-E may be required to review and recommend approval of submittals, shop drawings, Request for Information (RFI) and/or calculations for temporary structures such as trench shoring, false work and other temporary structural forms. b. A-E may be required to review and advise the County Representative on the overall project schedule, including staging and completion dates, duration, milestones, and interfaces. Immediately notify Representative if the proposed work schedule does not conform to the contract documents, including the plans, specifications, and permits or that may require special inspection or testing, or work stoppage. c. Review on a monthly basis the project schedule and/or Critical Path Method (CPM) schedule submitted by the Construction Contractor. Make recommendations concerning the Construction Contractor’s adherence thereto. Recommend possible solutions to scheduling problems so as to complete the project on time, within budget, and in accordance with the contract drawings and specifications. d. Review scope of work and identify potential contract change orders. Prepare independent cost estimates for any changes resulting from design revisions or change in field conditions. Prepare and recommend for approval all contract change orders. e. Evaluate the merit of any potential claims or requests for equitable adjustment submitted by the Construction Contractor. Prepare analysis of potential claims include recommendations regarding settlement of the claims. f. Assist County staff in project related issues with other Agencies, or departments, engineering and material testing support firms, CEQA consultants, utilities agencies, etc. g. Assist in community outreach meetings and media relations h. Review for acceptance/approval of Storm Water Pollution Prevention Plan (SWPPP) in accordance with the general Permit of Discharges of Storm Water Associated with Construction Activity (Construction General Permit, including dewatering/diversion plans per the State’s DeMinimus Permit).

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!