USE OF SITE AND CLEAN UP Sample Clauses

USE OF SITE AND CLEAN UP. Design Build Entity shall confine operations at the Site to areas permitted by law, ordinances, permits, the Contract Documents, and, to the extent applicable, rules or regulations of the Court. Design Build Entity shall not unreasonably encumber the Site with materials or equipment 13.19.17.1. The Site may be an active Court site. If it is, Design Build Entity and its performance of the Work shall not interfere with the operations of the Court. Design Build Entity is responsible for coordinating with Court administrative and maintenance staff for access to any portion of the Site, minimizing disruption to Court operations (if an active courthouse), and obtaining copies of any Site access and other rules applicable to Work at the Court. Design Build Entity’s failure to comply with this section shall constitute a material breach of the Agreement. 13.19.17.2. Design Build Entity shall, during performance of the Work, keep the Site and surrounding area free from the accumulation of excess dirt, waste materials, and rubbish arising from the Work at the Site. Design Build Entity shall remove all excess dirt, waste material, and rubbish arising from the Work at the Site; tools; equipment; machinery; and surplus materials from the Site and surrounding area at the Final Completion of the Work. 13.19.17.3. Design Build Entity shall be responsible to maintain the site including access to work areas during winter months. This may include any dewatering activities, soil stabilization needed to maintain a workable jobsite, and allowing adequate labor and equipment access to the areas of Construction Work. 13.19.17.4. Design Build Entity shall grade the Site to drain, maintain excavations free of water, protect the Site from puddling, provide for drainage of storm water and such water as may be applied or discharged on the Site in the performance of the Work. Drainage facilities shall be adequate to prevent damage to the Work, the Site, and adjacent property.
Sample 1Sample 2Sample 3See All (4)
AutoNDA by SimpleDocs
USE OF SITE AND CLEAN UP. 4.7.1. The Contractor shall confine operations at the Site to areas permitted by law, ordinances or permits, subject to any restrictions or limitations set forth in the Contract Documents. The Contractor shall not unreasonably encumber the Site or adjoining areas with materials or equipment. The Contractor shall be solely responsible for providing security at the Site with all such costs included in the GMP. 4.7.2. The District shall be providing CM and PI site supervision Monday through Friday from 7:00 AM to 3:30 PM. Working hours shall conform to local laws, which includes no street parking, deliveries, hoisting, welding, etc. or equipment startup. Scheduled and limited exceptions such as utility shutdowns and tie-ins to existing work shall be performed during “off-hours”. All Work performed during off-hours must be coordinated and approved by the District, with a minimum of 48 hour notice. The Contractor is responsible for the costs of all overtime, shift time differentials, and other premium time costs required to achieve the schedule commitments. This includes, but is not limited to, work in excess of eight (8) hours per day, forty (40) hours per week, and/or work on Saturdays, Sundays and Holidays. If Contractor is behind schedule or not working full shifts in accordance with the hours indicated above, they shall be considered behind schedule and responsible for delay impacts. 4.7.3. The Contractor shall at all times keep the Site and all adjoining areas free from the accumulation of any waste material or rubbish caused or generated by performance of the Work. Contractor shall be aware of and take appropriate measure to avoid nuisances. Should the Project Inspector determine that any waste materials, rubbish, or other stored materials have become a nuisance; the Contractor will remedy the condition immediately upon oral and/or written notice. Contractor shall separately contain hazardous and unsanitary waste materials from other waste and mark each container appropriately and dispose of legally. Contractor shall maintain the Site in a “broom-clean” standard on a daily basis. Prior to completion of the Work, Contractor shall remove from the Site all rubbish, waste material, excess excavated material, tools, Construction Equipment, machinery, surplus material and any other items which are not the property of the District under the Contract Documents. If the Contractor fails to clean up as provided for in the Contract Documents, the District may do so,...
Sample 1Sample 2See All (4)
USE OF SITE AND CLEAN UP. 3.24.1 The Design Build Entity shall confine operations at the Project site to areas permitted by law, ordinances, permits, and the Contract Documents. The Design Build Entity shall not unreasonably encumber the Project site with materials or equipment. 3.24.2 The Design Build Entity shall, during performance of work on the Project, keep the Project site and surrounding area free from the accumulation of excess dirt, waste materials, and rubbish caused by the Design Build Entity. The Design Build Entity shall remove all excess dirt, waste material, and rubbish caused by the Design Build Entity; tools; equipment; machinery; and surplus materials from the Project site and surrounding area at the completion of the Project. 3.24.3 Personnel of the Design Build Entity and Subcontractors shall not occupy, live upon, or otherwise make use of the Project site during any time that work is not being performed at the Project site, except as otherwise provided in the Contract Documents.
Sample 1Sample 2
USE OF SITE AND CLEAN UP. 3.13.1 Contractor shall confine operations at the Project site to areas permitted by law, ordinances, permits, and the Contract Documents. Contractor shall not unreasonably encumber the Project site with materials or equipment. 3.13.2 Contractor shall, during performance of the Work, keep the Project site and surrounding area free from the accumulation of excess dirt, waste materials, and rubbish caused by Contractor. Contractor shall remove all excess dirt, waste material, and rubbish caused by the Contractor; tools; equipment; machinery; and surplus materials from the Project site and surrounding area at the completion of the Work. 3.13.3 Personnel of Contractor and Subcontractors shall not occupy, live upon, or otherwise make use of the Project site during any time that Work is not being performed at the Project site, except as otherwise provided in the Contract Documents.
Sample 1Sample 2
USE OF SITE AND CLEAN UP. Contractor shall confine its operations to areas permitted by the Contract Documents and keep the Project site clean and free from unreasonable accumulation of excess dirt, materials, or waste caused by Contractor.
Sample 1

Related to USE OF SITE AND CLEAN UP

  • Markings If permitted by applicable Law, on or reasonably promptly after the Closing Date, Owner will cause to be affixed to, and maintained in, the cockpit of the Airframe and on each Engine, in each case, in a clearly visible location, a placard of a reasonable size and shape bearing the legend: “Subject to a security interest in favor of Wilmington Trust, National Association, not in its individual capacity but solely as Mortgagee.” Such placards may be removed temporarily, if necessary, in the course of maintenance of the Airframe or Engines. If any such placard is damaged or becomes illegible, Owner shall promptly replace it with a placard complying with the requirements of this Section.

  • Use of Site 4.13.1 The Contractor shall confine operations at the site to areas permitted by law, including areas designated for operations or prohibited from operations by any applicable permit and or regulation, ordinances, permits and the Contract Documents and shall not unreasonably encumber the site with any materials or equipment.

  • Materials of Environmental Concern have not been transported or disposed of from the Properties in violation of, or in a manner or to a location that could give rise to liability under, any Environmental Law, nor have any Materials of Environmental Concern been generated, treated, stored or disposed of at, on or under any of the Properties in violation of, or in a manner that could give rise to liability under, any applicable Environmental Law;

  • Use of Hazardous Materials Tenant shall not cause or permit any Hazardous Materials to be used, stored, discharged, released or disposed of in the Premises or cause any Hazardous Materials to be used, stored, discharged, released or disposed of in, from, under or about, the Property, or any other land or improvements in the vicinity of the Property, excepting only the types and minor quantities of Hazardous Materials which are normally used in connection with Tenant’s permitted use, operation and maintenance of the Premises and then only in strict accordance with all Legal Requirements, including all Environmental Laws (“Permitted Substances”). Tenant shall, at its own expense, procure, maintain in effect and comply with all conditions of any and all permits, licenses, and other governmental and regulatory approvals required for Tenant’s use of Hazardous Materials at the Premises, including, without limitation, discharge of appropriately treated materials or wastes into or through any sanitary sewer serving the Building. Tenant shall in all respects handle, treat, deal with and manage any and all Tenant’s Hazardous Materials in total conformity with all Environmental Laws and prudent industry practices regarding management of such Hazardous Materials. Without limiting the foregoing, if any Tenant’s Hazardous Materials result in contamination of the Building, or any soil or groundwater in, under or about the Property in each case to the extent the presence of same amounts to a violation of any Legal Requirement or poses a threat to human health or safety, Tenant, at its expense, shall promptly take all actions necessary to return the Building and/or the Property, to the condition existing prior to the appearance of the Tenant’s Hazardous Material, subject to Landlord’s right to approve Tenant’s proposed remediation method. On or prior to the Termination Date, Tenant shall cause all Tenant’s Hazardous Materials in, on, under or about the Building to be removed in accordance with and in compliance with all Legal Requirements. Tenant shall promptly notify Landlord and obtain Landlord’s written approval before taking any remedial action in response to the presence of any Tenant’s Hazardous Materials or entering into any settlement agreement, consent decree or other compromise with respect to any claims relating to Tenant’s Hazardous Materials.

  • Malicious Use of Orphan Glue Records Registry Operator shall take action to remove orphan glue records (as defined at xxxx://xxx.xxxxx.xxx/en/committees/security/sac048.pdf) when provided with evidence in written form that such records are present in connection with malicious conduct.

  • Use of FIIOC’s and FSC's Name The Trust shall not use the name of FIIOC and FSC in any Prospectus, sales literature or other material relating to the Trust or any Fund of the Trust in a manner not consented to by FIIOC and FSC prior to use; provided, however, that FIIOC and FSC shall approve all uses of its name which merely refer in accurate terms to its appointments, duties or fees hereunder or which are required by the Securities and Exchange Commission ("SEC" or “Commission”) or a state securities commission; and further, provided that in no event shall such approval be unreasonably withheld.

  • SERVICES NOT EXCLUSIVE/USE OF NAME Your services to the Fund pursuant to this Agreement are not to be deemed to be exclusive, and it is understood that you may render investment advice, management and other services to others, including other registered investment companies, provided, however, that such other services and activities do not, during the term of this Agreement, interfere in a material manner, with your ability to meet all of your obligations with respect to rendering services to the Fund. The Company and you acknowledge that all rights to the name “RiverNorth” or any variation thereof belong to you, and that the Company is being granted a limited license to use such words in its Fund name or in any class name. In the event you cease to be the adviser to the Fund, the Company’s right to the use of the name “RiverNorth” shall automatically cease on the ninetieth day following the termination of this Agreement. The right to the name may also be withdrawn by you during the term of this Agreement upon ninety (90) days’ written notice by you to the Company. Nothing contained herein shall impair or diminish in any respect, your right to use the name “RiverNorth” in the name of, or in connection with, any other business enterprises with which you are or may become associated. There is no charge to the Company for the right to use this name.

  • Selection of Subcontractors, Procurement of Materials and Leasing of Equipment The contractor shall not discriminate on the grounds of race, color, religion, sex, national origin, age or disability in the selection and retention of subcontractors, including procurement of materials and leases of equipment. The contractor shall take all necessary and reasonable steps to ensure nondiscrimination in the administration of this contract. a. The contractor shall notify all potential subcontractors and suppliers and lessors of their EEO obligations under this contract. b. The contractor will use good faith efforts to ensure subcontractor compliance with their EEO obligations.

  • Exclusive Use (A) After the Occupancy Date, Lessee expressly agrees and warrants that the Leased Premises will be used exclusively as a Champps Restaurant or other casual dining sit-down restaurant. In any other such case, after obtaining Lessor's prior written consent, such consent not to be unreasonably withheld or delayed, Lessee may conduct any lawful business from the Leased Premises. Lessee acknowledges and agrees that any other use without the prior written consent of Lessor will constitute a default under and a violation and breach of this Lease. Lessee agrees: To open for business within a reasonable period of time after completion of construction of the contemplated Improvements; to operate all of the Leased Premises during the Term or Renewal Terms during regular and customary hours for businesses similar to the permitted exclusive use stated herein, unless prevented from doing so by causes beyond Lessee's control or due to remodeling; and to conduct its business in a professional and reputable manner. (B) If the Leased Premises are not operated as a Champps Restaurant or other casual dining sit-down restaurant or other permitted use hereunder, or remain closed for thirty (30) consecutive days (unless such closure results from reasons beyond Lessee's reasonable control) and in the event Lessee fails to pay Rent when due or fulfill any other obligation hereunder, then Lessee shall be in default hereunder and Lessor may, at its option, cancel this Lease by giving written notice to Lessee or exercise any other right or remedy that Lessor may have; provided, however, that closings shall be reasonably permitted for replacement of trade fixtures or during periods of repair after destruction or due to remodeling.

  • Storage of Materials Borrower shall cause all materials supplied for or intended to be utilized in the construction of the Improvements but not affixed to or incorporated into the Property to be stored on the Property or at such other location as may be approved by Lender in writing, with adequate safeguards to prevent loss, theft, damage or commingling with other materials not intended to be utilized in the construction of the Improvements.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!