Vacation Schedules (a) Employees shall submit their vacation requests to the supervisor on or before:
Vacation Schedule 1. Vacation periods shall be fixed by the Employer to suit the requirements of his business, but as far as possible and practicable, vacations will be given during the summer months, and for employees with school-age children, during the school vacations. Vacation periods shall be unbroken unless by mutual consent between Employer and employee, or where it is impractical. Grievances relating to this Section shall be subject to the Adjustment and Arbitration Procedure in this Agreement.
Vacation Scheduling (a) With the exception of authorized vacation carryover under Clause 18.6, the scheduling and completion of vacations shall be on a calendar-year basis.
Unit Weekend Schedule A unit weekend schedule may be developed in order to meet the Hospital’s need for weekend staff, and individual nurses’ preference for a weekend work schedule. A unit weekend schedule is defined as a schedule in which a full-time nurse works a weekly average of thirty (30) hours and is paid for 37.5 hours at her or his regular straight time hourly rate. The schedule must include two 11.25 hour tours, which fall within a weekend period as determined by the Hospital and the Association. A nurse working a weekend schedule will work every weekend except as provided for in the provisions below. If the Hospital and the Association agree to a unit weekend schedule, the introduction of that schedule and the manner in which the position(s) are filled, shall be determined by the local parties and recorded in the Appendix of Local Provisions. This unit schedule may be discontinued by either party with notice as determined within the Appendix of Local Provisions. The opportunity for an individual nurse to discontinue this schedule shall be resolved by the local parties:
Construction Schedules 10.1 Within seven (7) days of the University’s issuance of a purchase order, the Contractor shall submit to the Project Coordinator three (3) copies of a Construction Schedule for this Project. The Schedule shall be in bar chart form and shall include all aspects of the work, the interrelationship of the various trades and the critical path of the job. The schedule shall include a timeline for the submission, review and approval of shop drawings for critical path items and delivery and installation dates for those same critical path, or long lead time items, (such as electrical transformers and elevator). The Schedule shall coincide with the Contractor’s approved Schedule of Values. The Schedule shall indicate a completion date in advance of the date established for Substantial Completion. The Schedule shall be acceptable to the Architect/Engineer and the Project Coordinator. It shall be revised and reissued at the beginning of every month for the duration of the project. This monthly update progress Schedule shall include a summary comparison of the original schedule and the latest updated schedule (previous month) showing all activity description and dates. These comparison schedules shall be in the form of a summary bar chart, an activity listing report and actual to target comparisons. The reports may include critical activities, float time, duration of each activity, dates of each activity and the network logic (including successors and predecessors of each activity). Included with the written report and electronic copy of the schedule submission noting the above referenced requirements. Failure to provide the Architect/Engineer, or the Project Coordinator with an acceptable, revised Schedule, within seven (7) days of the receipt of a written request, may result in the withholding of the Contractor’s monthly progress payments until such a Schedule is received.
Compensation Schedule Except as otherwise provided herein, employees shall be compensated within the pay range assigned to the classification of the position in which they are employed and in accordance with the pertinent conditions of employment enumerated in this Agreement. Sec. 503 REGULAR PAY DAY: Employees shall be paid on or about the Friday following the end of the biweekly payroll period.
Work Schedules Workweeks and work shifts of different numbers of hours may be established by the Employer in order to meet business and customer service needs, as long as the work schedules meet federal and state laws.
Alternate Work Schedules Workweeks and work shifts of different numbers of hours may be established for overtime-eligible employees by the Employer in order to meet business and customer service needs, as long as the alternate work schedules meet federal and state law. When there is a holiday, employees may be required to switch from their alternate work schedules to regular work schedules.
Salary Schedules (a) The salary schedules shall be incorporated into this Agreement as Appendix V.
Regular Work Schedules The regular work schedule for overtime-eligible employees will not be more than forty (40) hours in a workweek, with two (2) consecutive calendar days off and starting and ending times as determined by the requirements of the position and the Employer. The Employer may adjust the regular work schedule with prior notice to the employee.
