Change Order (5) The Change Order is then submitted to the Project Manager who immediately processes the CO with OPC as required by Bulletin 3.5 and BGS’ Contracting Plan.
Change Orders Any alteration or deviation from the Services mentioned or any other contractual specifications that result in a revision of this Agreement shall be executed and attached to this Agreement as a change order (“Change Order”).
Approval Process Tenant shall notify Landlord whether it approves of the submitted working drawings within three business days after Landlord’s submission thereof. If Tenant disapproves of such working drawings, then Tenant shall notify Landlord thereof specifying in reasonable detail the reasons for such disapproval, in which case Landlord shall, within five business days after such notice, revise such working drawings in accordance with Tenant’s objections and submit the revised working drawings to Tenant for its review and approval. Tenant shall notify Landlord in writing whether it approves of the resubmitted working drawings within one business day after its receipt thereof. This process shall be repeated until the working drawings have been finally approved by Landlord and Tenant. If Tenant fails to notify Landlord that it disapproves of the initial working drawings within three business days (or, in the case of resubmitted working drawings, within one business day) after the submission thereof, then Tenant shall be deemed to have approved the working drawings in question. Any delay caused by Tenant’s unreasonable withholding of its consent or delay in giving its written approval as to such working drawings shall constitute a Tenant Delay Day (defined below). If the working drawings are not fully approved (or deemed approved) by both Landlord and Tenant by the 15th business day after the delivery of the initial draft thereof to Tenant, then each day after such time period that such working drawings are not fully approved (or deemed approved) by both Landlord and Tenant shall constitute a Tenant Delay Day.
Completion of Requests A Request for a Loan will not be regarded as having been duly completed unless:
Notice to Proceed Work shall not commence on this Project until the Director has issued a written Notice to Proceed to the Recipient. Such Notice will not be issued until the Director is assured that the Recipient has complied with the Recipient's responsibilities concerning OEPA plan approval, when applicable. A Notice to Proceed shall be required for all project prime contractors or direct procurement initiated by the Recipient following execution of this Agreement.
Legal Action Notice A prompt report of any legal actions pending or threatened in writing against Borrower or any of its Subsidiaries that could result in damages or costs to Borrower or any of its Subsidiaries of, individually or in the aggregate, One Hundred Thousand Dollars ($100,000) or more; and
Governing Law; Submission to Process EXCEPT TO THE EXTENT THAT THE LAW OF ANOTHER JURISDICTION IS EXPRESSLY ELECTED IN A TRANSACTION DOCUMENT, THIS AGREEMENT AND THE OTHER TRANSACTION DOCUMENTS, SHALL BE GOVERNED BY AND CONSTRUED IN ACCORDANCE WITH THE INTERNAL LAWS OF THE STATE OF NEW YORK, WITHOUT REGARD TO PRINCIPLES OF CONFLICTS OF LAW. EACH OF BIONOVA AND SAVIA HEREBY IRREVOCABLY SUBMITS ITSELF AND EACH OTHER RELATED PERSON TO THE NON-EXCLUSIVE JURISDICTION OF THE STATE AND FEDERAL COURTS SITTING IN THE STATE OF NEW YORK AND THE COUNTY OF NEW YORK AND AGREES AND CONSENTS THAT SERVICE OF PROCESS MAY BE MADE UPON IT OR ANY OF ITS SUBSIDIARIES IN ANY LEGAL PROCEEDING RELATING TO THE TRANSACTION DOCUMENTS BY ANY MEANS ALLOWED UNDER NEW YORK OR FEDERAL LAW. EACH OF BIONOVA AND SAVIA IRREVOCABLY WAIVES, TO THE FULLEST EXTENT PERMITTED BY APPLICABLE LAW, ANY OBJECTION THAT IT MAY NOW OR HEREAFTER HAVE TO THE LAYING OF THE VENUE OF ANY SUCH PROCEEDING BROUGHT IN SUCH A COURT AND ANY CLAIM THAT ANY SUCH PROCEEDING BROUGHT IN SUCH A COURT HAS BEEN BROUGHT IN AN INCONVENIENT FORUM.
Purchase Order A Customer may use purchase orders to buy commodities or contractual services pursuant to the Contract and, if applicable, the Contractor must provide commodities or contractual services pursuant to purchase orders. Purchase orders issued pursuant to the Contract must be received by the Contractor no later than the close of business on the last day of the Contract’s term. The Contractor is required to accept timely purchase orders specifying delivery schedules that extend beyond the Contract term even when such extended delivery will occur after expiration of the Contract. Purchase orders shall be valid through their specified term and performance by the Contractor, and all terms and conditions of the Contract shall survive the termination or expiration of the Contract and apply to the Contractor’s performance. The duration of purchase orders for recurring deliverables shall not exceed the expiration of the Contract by more than twelve months. Any purchase order terms and conditions conflicting with these Special Contract Conditions shall not become a part of the Contract.
Notice of Decision The Plan Administrator shall notify the claimant in writing of its decision on review. The Plan Administrator shall write the notification in a manner calculated to be understood by the claimant. The notification shall set forth:
