Design Program Sample Clauses

Design Program. Design Program means the overall goals and design objectives of the Project, the aesthetic considerations, and the functional requirements including allocations of space with uses and adjacency relationships for all areas/spaces, operational objectives and such standards of design that TFC may require for all architectural and engineering disciplines in the design and construction of the Project.
Sample 1Sample 2Sample 3See All (5)
AutoNDA by SimpleDocs
Design Program. DB shall provide all design Services required of DB as designated in the Design Program. DB shall report in writing to TFC any deviations between TFC-provided information or programs and the final Construction documents presented.
Sample 1
Design Program. (a) By the later of the date of satisfaction of the last of the conditions precedent required to be satisfied under clause 2.7 and 31 January 1996, the Company and the Trustee shall submit a detailed design program to the State and the Independent Reviewer.
Sample 1
Design Program. MCD agrees to use all commercially reasonable efforts to complete the Design Program by the end of May 1997. The parties agree that the target cost to produce each 1500cc motorcycle Engine shall be Four Thousand Pounds (4,000), and the target costs to produce each 600cc motorcycle Engine shall be One Thousand Eight Hundred Pounds (1,800). The parties agree that the estimated cost of designing both Engines is approximately Seventy Thousand Pounds (70,000). The Company hereby agrees to pay MCD the sum of Seventy Thousand Pounds (70,000) in consideration of MCD's continuing compliance with the Design Program. Such amount will be payable in seven (7) equal installments of Ten Thousand Pounds (10,000) each, with the first such installment being due and payable on November 15, 1996, and the remaining installments being due and payable on the first day of each succeeding month, such installment payments shall be contingent upon and subject to MCD's continued compliance with the Design Program. Upon each installment payment made by the Company pursuant to this Section 2, the Company shall obtain and retain all right, title and interest in and to the Specifications, the Engines and all Intellectual Property therein. MCD also agrees to sell the Company all of MCD's rights, title and interest in the 600cc Motorcycle Frame, including the exclusive right to design, produce, market and sell frames based on the 600cc Motorcycle Frame, and, in consideration therefor, the Company agrees to pay MCD the sum of Twenty-Five Thousand Pounds (25,000) on November 15, 1996. MCD further agrees to produce one fully-operational 600cc Prototype Motorcycle as part of the Design Program. Except for reasonable travel expenses incurred by MCD in its performance of this Agreement which costs shall be paid for by the Company and except as otherwise provided in this Agreement, MCD shall be responsible for all costs and expenses incurred in carrying out the Design Program. MCD agrees to consult with the Company on a regular basis regarding the progress of the Design Program, and will give the Company the opportunity to review and approve the functional specifications prior to commencing the engineering phase of the Design Program. In connection with the Design Program, MCD agrees to assist the Company in creating an owners' manual for the 1500cc Motorcycle Engine and the 600cc Prototype Motorcycle which the Company will distribute to the purchasers and end-users of such products. MCD also agr...
Sample 1
Design Program. To the extent Tenant has not previously approved Tenant’s program (the “Program”) for the Building and improvements to be constructed on the Land prior to the execution of this Lease (and included in Exhibit B-1 attached hereto and made a part hereof for all purposes), Landlord will prepare and deliver to Tenant for Tenant’s approval the remainder of the Program within thirty (30) days from the Effective Date of this Lease. The Program is subject to Tenant’s approval, which approval shall not be unreasonably withheld. In the event Tenant fails to disapprove any part of the Program delivered by Landlord to Tenant after execution of this Lease within five (5) days after the date of delivery thereof, Tenant will be deemed to have approved the same. Upon approval by Landlord and Tenant, the remainder of the Program will be added to Exhibit B-1 of this Lease.
Sample 1
Design Program. The Contractor compiles design program according to approved project program, design review stage agreed in item 5.3.1 and time schedule for review meeting of design stage organized by the Employer. Design program is implemented under the Employer’s consent. The Employer’s consent does not relieve the Contractor’s contractual liabilities.
Sample 1
Design Program. (a) The Developer must develop a draft design program which sets out the target dates for delivery of the Design Documentation (Public Works and Integration Works) and provide that draft design program to the State for comment in accordance with clause 6.1(b).
Sample 1
AutoNDA by SimpleDocs
Design Program 
Sample 1

Related to Design Program

  • Tenant Improvement Plans Any work proposed by Tenant (the “Tenant Improvements”) shall be subject to Landlord’s reasonable prior approval and shall be subject to the other terms and conditions of this Exhibit C; provided that it will be reasonable for Landlord to withhold its approval or consent (as and when applicable under this Exhibit C) if Landlord’s Mortgagee has not consented to the matter that is the subject of such approval or consent. All architectural, engineering and other design fees shall be paid by Tenant. Tenant shall use its architect, engineers and other design professionals, all of whom shall comply with any applicable licensing or governmental requirements of the City of Seattle and the State of Washington; Tenant’s architect shall be approved by Landlord (“Tenant’s Architect”), which approval shall not be unreasonably withheld, conditioned or delayed. Landlord shall also be entitled to receive a copy of the agreement between Tenant and Tenant’s Architect (the “Architect Agreement”). Tenant shall cause Tenant’s Architect to prepare a draft space plan (the “Space Plan”) for the Tenant Improvements and shall submit the proposed Space Plan to Landlord for the latter’s approval (not to be unreasonably withheld) in a time period to allow Tenant to timely complete its Tenant Improvements under this Lease. Landlord shall deliver to Tenant any written objections, questions or comments of Landlord with regard to the Space Plan within ten (10) business days of receipt; Landlord’s consent thereto shall be deemed given if not denied in writing within said ten (10) business day period. If Landlord denies its approval, it shall specify the reasons for doing so in detail. Tenant shall cause the Space Plan to be revised to address such written comments and shall resubmit said Space Plan to Landlord for approval. Such process shall continue until Landlord has approved the Space Plan. Tenant’s Architect shall then prepare working drawings and specifications for the Tenant Improvements, including architectural, structural, plumbing, mechanical, electrical, and fire protection drawings as required, suitable for permit application (the “Working Drawings”) and shall submit the proposed Working Drawings to Landlord for the latter’s approval in a time period to allow Tenant to timely complete its Tenant Improvements under this Lease. The Space Plan and Working Drawings shall be subject to Landlord’s approval, which Landlord agrees shall not be unreasonably withheld, conditioned, or delayed. Landlord shall not be deemed to have acted unreasonably if it withholds its approval thereof because, in Landlord’s reasonable opinion, the work, as described in any such item: (i) is likely to adversely affect Building Systems, the structure of the Building or the safety of the Building and/or their occupants; (ii) might impair Landlord’s ability to furnish services to Tenant or other tenants in the Building; (iii) would materially increase the cost of operating the Building; (iv) would violate any governmental laws, rules or ordinances (or interpretations thereof); (v) contains or uses hazardous or toxic materials or substances; (vi) would negatively affect the appearance of the Building; (vii) is reasonably likely to adversely affect another tenant’s premises; or (viii) is prohibited by any ground lease affecting the Building or any mortgage, trust deed or other instrument encumbering the Building. Landlord shall deliver to Tenant any written objections, questions or comments of Landlord with regard to the Working Drawings, within ten (10) business days of Landlord’s receipt of the Working Drawings; Landlord’s consent thereto shall be deemed given if not denied in writing within said ten (10) business day period. If Landlord denies its approval, it shall specify the reasons for doing so in detail. Tenant shall cause the Working Drawings to be revised to address such written comments and shall resubmit said Working Drawings to Landlord for approval. Landlord may, when approving the Tenant Improvement Plans, elect to require Tenant to remove any Non-Standard Improvements which are made to the Premises. If Landlord so elects, Tenant shall, at its own cost, restore the Premises to the condition designated by Landlord in its election, before the last day of the Term. Such process shall continue until both parties have approved the Working Drawings. Landlord’s approval of the Space Plan and/or the Working Drawings shall not be deemed any representation or warranty that the same comply with applicable codes.

  • Development Plans 4.3.1 For each Licensed Indication and corresponding Licensed Product in the Field, Licensee will prepare and deliver to Licensor a development plan and budget (each a “Development Plan”). The initial Development Plans for each Licensed Indication will be delivered within […***…] after the Grant Date for such Licensed Indication.

  • Project Scope The physical scope of the Project shall be limited to only those capital improvements as described in Appendix A of this Agreement. In the event that circumstances require a change in such physical scope, the change must be approved by the District Committee, recorded in the District Committee's official meeting minutes, and provided to the OPWC Director for the execution of an amendment to this Agreement.

  • Space Plans Prior to drafting any Construction Drawings, Tenant shall furnish Landlord with Tenant's final space plans for the Premises ("Space Plans"). The Space Plans shall show locations of all proposed improvements, including partitions, cabinetry, equipment and fixtures, shall identify materials and finishes by location, and shall specify the location of any proposed structural floor penetrations, the location and extent of floor loading in excess of Building capacity, if any, any special HVAC requirements, the location and description of any special plumbing requirements, and any special electrical requirements. In addition, the Space Plans shall show telephone and telecommunications facilities, and computer and electronic data facilities. Landlord shall approve or disapprove the Space Plans by written notice given to Tenant within ten (10) business days after receipt of the Space Plans. Landlord shall not unreasonably withhold its approval of the Space Plans, provided that, without limiting the generality of the foregoing, Landlord shall be entitled to withhold its consent to the Space Plans if, in Landlord's good faith judgment, any one or more of the following situations exist: (a) the proposed Tenant Improvements will adversely affect the exterior appearance of the Buildings; or (b) the proposed Tenant Improvements may impair the structural strength of the Buildings, adversely affect any Building Systems or materially adversely affect the value of the Buildings; or (c) the specifications for the proposed Tenant Improvements are not consistent with, or would detract from, the character or image of the Project. If Landlord disapproves the Space Plans, Landlord shall return the Space Plans to Tenant with a statement of Landlord's reasons for disapproval, or specifying any required corrections and/or revisions. Landlord shall approve or disapprove of any revisions to the Space Plans by written notice given to Tenant within five (5) business days after receipt of such revisions. This procedure shall be repeated until Landlord approves the Space Plans.

  • Maintenance Program LESSEE's Maintenance Program

  • Construction Plans Tenant shall prepare final plans and specifications for the Tenant Improvements that (a) are consistent with and are logical evolutions of the Approved Schematic Plans and (b) incorporate any other Tenant-requested (and Landlord-approved) Changes (as defined below). As soon as such final plans and specifications ("Construction Plans") are completed, Tenant shall deliver the same to Landlord for Landlord's approval, which approval shall not be unreasonably withheld, conditioned or delayed. All such Construction Plans shall be submitted by Tenant to Landlord in electronic .pdf, CADD and full-size hard copy formats, and shall be approved or disapproved by Landlord within ten (10) business days after delivery to Landlord. Landlord's failure to respond within such ten (10) business day period shall be deemed approval by Landlord. If the Construction Plans are disapproved by Landlord, then Landlord shall notify Tenant in writing of its objections to such Construction Plans, and the parties shall confer and negotiate in good faith to reach agreement on the Construction Plans. Promptly after the Construction Plans are approved by Landlord and Tenant, two (2) copies of such Construction Plans shall be initialed and dated by Landlord and Tenant, and Tenant shall promptly submit such Construction Plans to all appropriate Governmental Authorities for approval. The Construction Plans so approved, and all change orders approved (to the extent required) by Landlord, are referred to herein as the "Approved Plans."

  • Project Plan Development of Project Plan Upon the Authorized User’s request, the Contractor must develop a Project Plan. This Project Plan may include Implementation personnel, installation timeframes, escalation procedures and an acceptance plan as appropriate for the Services requested. Specific requirements of the plan will be defined in the RFQ. In response to the RFQ, the Contractor must agree to furnish all labor and supervision necessary to successfully perform Services procured from this Lot. Project Plan Document The Contractor will provide to the Authorized User, a Project Plan that may contain the following items: • Name of the Project Manager, Contact Phone Numbers and E-Mail Address; • Names of the Project Team Members, Contact Phone Numbers and E-Mail Address; • A list of Implementation milestones based on the Authorized User’s desired installation date; • A list of responsibilities of the Authorized User during system Implementation; • A list of designated Contractor Authorized Personnel; • Escalation procedures including management personnel contact numbers; • Full and complete documentation of all Implementation work; • Samples of knowledge transfer documentation; and • When applicable, a list of all materials and supplies required to complete the Implementation described in the RFQ. Materials and Supplies Required to Complete Implementation In the event that there are items required to complete an Implementation, the Contractor may request the items be added to its Contract if the items meet the scope of the Contract. Negotiation of Final Project Plan If the Authorized User chooses to require a full Project Plan, the State further reserves the right for Authorized Users to negotiate the final Project Plan with the apparent RFQ awardee. Such negotiation must not substantively change the scope of the RFQ plan, but can alter timeframes or other incidental factors of the final Project Plan. The Authorized User will provide the Contractor a minimum of five (5) business days’ notice of the final negotiation date. The Authorized User reserves the right to move to the next responsible and responsive bidder if Contractor negotiations are unsuccessful.

  • APPROVAL OF PLANS AND SPECIFICATIONS The Plans and Specifications will conform to the requirements and conditions set out by applicable law or any effective restrictive covenant, and to all governmental authorities which exercise jurisdiction over the Leased Premises or the construction thereon.

  • Final Plans On or before thirty (30) days following the date of full execution of this Lease, Landlord shall submit to Tenant two (2) sets of Landlord’s proposed space and construction plans and specifications prepared by Landlord’s architect, for the Tenant Improvements, Within three (3) business days after receipt of Landlord’s plans and specifications Tenant shall either: (a) evidence its approval by endorsement on one (1) set of said plans and specifications (and return such signed or initialed set to Landlord); or (b) indicate those revisions or corrections which Tenant requires and the reasons therefor; provided Landlord shall not be obligated to accept any revisions which Landlord shall reasonably determine: (i) do not conform to the standards of design, motif and decor reasonably established or adopted by Landlord for the Building; (ii) would subject Landlord or the Premises to any additional cost, expense, liability, violation, fine, penalty, or forfeiture; would adversely affect the reputation, character, or nature of the Building; (iii) would provide for or require any installation of work which is or might be unlawful, create an unsound or dangerous condition, adversely affect the structural soundness of the Premises or Building; (iv) interfere with or abridge the use and enjoyment of any adjoining or other space in the Building, or (v) is of a special use or nature with little or no residual value (unless Tenant agrees to pay for such improvements and the removal thereof upon the expiration or earlier termination of this Lease). Landlord shall, within five (5) days thereafter, submit four (4) sets of proposed plans and specifications, as so revised or corrected, to Tenant for its approval in accordance with this paragraph, which plans will then be considered the final plans (the “Final Plans”). The Final Plans may subsequently be amended by Tenant provided that significant changes will require Landlord’s prior written approval, which approval shall be given or reasonably refused within five (5) business days after receipt of such amended plans and specifications and, provided further that if such change order will delay the anticipated Commencement Date specified in Section 1 of the Lease the change order shall be considered a Tenant Delay (as hereinafter defined). The parties will work cooperatively to complete the plan approval process expeditiously.

  • Development Plan document specifying the work program, schedule, and relevant investments required for the Development and the Production of a Discovery or set of Discoveries of Oil and Gas in the Contract Area, including its abandonment.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!