Direct Labor Cost Sample Clauses

Direct Labor Cost. A. Direct labor cost percentage for change orders shall be established by the nature of the work and shall be agreed to by the Contractor and the Owner prior to the commencement of the additional work.
Sample 1Sample 2
Direct Labor Cost. This category of expenses shall include (provided the Guaranteed Maximum Not-to-Exceed Compensation is not exceeded) and are limited to the following cost items: 4.4.1 Wages and employee benefits as may be payable, paid for labor, other than the Project site supervisory and office employees, in the direct employ of the Contractor and used for performing the Contract work;
Sample 1
Direct Labor Cost. Represent those actual costs, exclusive of overhead and profit, reasonably and necessarily incurred and paid by the CM/GC in the construction performance phase services of this Contract, from the date of the Notice to Proceed until the completion of the Project, for payroll payments made to its employees working on the Project site, as described and defined in the Contract Documents.
Sample 1
Direct Labor Cost. Direct Labor Cost means salaries and wages (basic, premium and incentive) paid to personnel, but does not include indirect payroll related costs or fringe benefits.
Sample 1
Direct Labor Cost a. The Consultant and each subconsultant shall be compensated for the services of its personnel on the basis of reasonable, actual paid Direct Labor Costs (chargeable salaries without indirect payroll related costs or fringe benefits) as incurred by the Consultant and subconsultant’s personnel for the time such personnel are directly utilized on this Project. b. A schedule of the Consultant and each subconsultant’s Direct Labor Salary Costs per hour is set forth by individual and classification in Attachment B, for the current year (2020) for each key individual who is currently assigned to the Project. The Direct Labor Salary Costs in Attachment B will be updated as required over the term of this Agreement. c. Actual Direct Labor Costs shall be computed at straight time for engineering, technical and non-technical employees directly utilized on the Project and shall not exceed $75.00 per hour. The Authority may waive, by written agreement, the maximum direct labor costs per hour for specific individual(s) dedicated to the Project. d. The Consultant and subconsultant agree that the salaries and costs of temporary personnel (non-employees) assigned to the Project shall not be calculated as part of the Direct Labor Costs and shall be reimbursed as Other Direct Costs. e. If it is the usual practice for officers, partners, or principals of the Consultant and/or subconsultant to perform certain basic technical project work, they may be compensated for the time they are actually engaged on the project, but only at a rate of pay commensurate with the labor classification customarily performing that type of work, provided that written approval is obtained from the Division of the Authority administering the Agreement prior to the use of said individuals. Payment to or compensation of any officers, partners, principals or employees of the firm for their administrative duties in managing the Consultant or subconsultant’s firm shall not be billed as a salary or Direct Labor Cost. f. The weighted averages of chargeable salaries by labor classification over the term of this Agreement for all personnel (including both key and non-key individuals) of the Consultant firm and each subconsultant firm, are incorporated in and set forth in Attachment E, Table E5. Inclusion in any table of salary rates or ranges in excess of $75.00 per hour does not constitute a waiver by the Authority of the maximum payable direct labor hourly rate of $75.00 unless otherwise approved by the A...
Sample 1
Direct Labor Cost. Direct Labor Costs shall be based on the wage rates of assigned employees and the actual number of hours devoted to providing the Service. Direct Labor Costs include certain indirect labor costs such as the costs of paid, excused absences, such as vacations, sick pay and holidays.
Sample 1
Direct Labor Cost. This category of expenses shall include (provided the GMP is not exceeded) and are limited to the following cost items: 3.11.1.1 Wages and employee benefits as may be payable, paid for labor, and Project site supervisory and office employees, in the direct employ of the CM/GC and used for performing the Contract work; 3.11.1.2 Reasonable travel and lodging expenses of CM/GC's officers or employees incurred in the discharge of duties connected with the Project. Relocation costs of CM/GC's employees in connection with this Project shall not be reimbursable.
Sample 1
Direct Labor Cost. Represent those actual costs, exclusive of overhead and profit, reasonably and necessarily incurred and paid by the Contractor in the construction performance phase services of this Contract, from the date of the Notice to Proceed until the completion of the Project, for payroll payments made to its employees working on the Project site, as described and defined in the Contract Documents.
Sample 1

Related to Direct Labor Cost

  • Labor Costs 2.1 Wages of construction workers directly employed by the Construction Manager to perform the construction of the Work at the site or, with the Owner’s prior approval, at off-site workshops.

  • Labor Cooperation The Parties shall enhance their communication and cooperation on labor, social security and environment issues through Memorandum of Understanding on Labor Cooperation between the Government of the People's Republic of China and the Government of the Republic of Peru.

  • Labor-Management Cooperation When an Appointing Authority initiates a planning process or management study which is anticipated to result in layoff, the Appointing Authority will meet and confer with the Local Union during the decision planning phase and again during the implementation planning phase. The Appointing Authority and the Local Union shall enter into negotiations regarding a Memoranda of Understanding upon request of either party to modify this Agreement regarding the implementation plans which shall include, but are not limited to, the following: • Length of layoff notice; • Job and retraining opportunities; • Alternative placement methods; • Early retirement options pursuant to M.S. 43A.24, Subd. 2(i); • Bumping/vacancy options for part-time employees to preserve their insurance eligibility or contribution; and • Other methods of mitigating layoff or their effect on employees.

  • DIRECT PERSONNEL EXPENSE 4.1. Direct Personnel Expense of employees engaged on the Project by the ARCHITECT/ENGINEER includes ARCHITECT/ENGINEERS, other engineers, designers, job captains, draftsmen, specification writers and typists, in consultation, research and design in producing Drawings, Specifications and other documents pertaining to the Project, and in services during construction at the site. 4.2. Direct Personnel Expense includes actual cost and of mandatory and customary financial benefits paid.

  • Child Labor The Contractor represents and warrants that neither it, its parent entities (if any), nor any of the Contractor’s subsidiary or affiliated entities (if any) is engaged in any practice inconsistent with the rights set forth in the Convention on the Rights of the Child, including Article 32 thereof, which, inter alia, requires that a child shall be protected from performing any work that is likely to be hazardous or to interfere with the child’s education, or to be harmful to the child’s health or physical, mental, spiritual, moral, or social development.

  • Labor Harmony The parties acknowledge that it is of the utmost importance to City, Tenant, and all those occupying or to occupy space in the Domestic and International Terminals that there be no interruption in the progress of the construction work. Accordingly, City and Tenant agree as follows: (a) In any contract or undertaking which Tenant may make with a contractor for work in the Premises, provision shall be made for the dismissal from the job of workmen whose work is unskilled or otherwise objectionable, in the Director’s (and, for this purpose, “the Director” shall include a reference to the Airport’s Architect) reasonable judgment. Tenant shall cause any such workmen to be discharged from the project within twenty-four (24) hours after Director shall give notice to Tenant requiring such discharge. (b) Tenant shall use, and Tenant shall require its contractor and subcontractors to use, their respective best efforts to prevent work stoppages on the Premises, and/or elsewhere on the Airport, to the extent attributable to work being performed on the Premises, irrespective of the reason of any such stoppage. In the event that the conduct or presence of any employee(s) of Tenant or Tenant’s contractor(s) or subcontractor(s) causes a labor dispute or work stoppage, Tenant shall have such employee(s) immediately removed from the Airport upon Director’s request. (c) Tenant shall include, and shall cause its contractor to include, the following clause in all contracts with its general contractors and subcontractors: There shall be no manifestations on the project of any dispute between any labor organization and any Tenant contractor or subcontractor, including but not limited to, any area standards picketing against said contractor or subcontractor. Should there be any manifestation of a labor dispute between any Tenant contractor or subcontractor and any union, which results in a stoppage of work on the part of said contractor or subcontractor’s employees or the employees of any other employer or supplier on the project or at the Airport, which in the sole judgment of the Director will cause, or is likely to cause, unreasonable delay in the progress of construction or operation of any business at the Airport, then upon written notice from Director, Tenant shall declare the contractor or subcontractor in default of its contract, and upon such notice, Tenant shall have the right to take such steps as are necessary to finish the uncompleted portion of the work to be performed by the contractor or subcontractor. (d) Without limiting the generality of indemnities elsewhere in this Lease, Tenant shall indemnify, defend, and hold harmless City and each City Entity for any and all Losses which arise from the actions taken pursuant to this Section 7.9.

  • Payment for Labor and Materials (a) Borrower will promptly pay when due all bills and costs for labor, materials, and specifically fabricated materials ("LABOR AND MATERIAL COSTS") incurred in connection with the Property and never permit to exist beyond the due date thereof in respect of the Property or any part thereof any lien or security interest, even though inferior to the liens and the security interests hereof, and in any event never permit to be created or exist in respect of the Property or any part thereof any other or additional lien or security interest other than the liens or security interests hereof except for the Permitted Encumbrances. (b) After prior written notice to Lender, Borrower, at its own expense, may contest by appropriate legal proceeding, promptly initiated and conducted in good faith and with due diligence, the amount or validity or application in whole or in part of any of the Labor and Material Costs, provided that (i) no Event of Default has occurred and is continuing under the Loan Agreement, the Note, this Security Instrument or any of the other Loan Documents, (ii) Borrower is permitted to do so under the provisions of any other mortgage, deed of trust or deed to secure debt affecting the Property, (iii) such proceeding shall suspend the collection of the Labor and Material Costs from Borrower and from the Property or Borrower shall have paid all of the Labor and Material Costs under protest, (iv) such proceeding shall be permitted under and be conducted in accordance with the provisions of any other instrument to which Borrower is subject and shall not constitute a default thereunder, (v) neither the Property nor any part thereof or interest therein will be in danger of being sold, forfeited, terminated, canceled or lost, and (vi) Borrower shall have furnished the security as may be required in the proceeding, or as may be reasonably requested by Lender to insure the payment of any contested Labor and Material Costs, together with all interest and penalties thereon.

  • LABOR AND MATERIALS 4.4.1 Unless otherwise provided in the Contract Documents, the Contractor shall provide and pay for all labor, materials, equipment, tools, construction equipment and machinery, water, heat, utilities, transportation, and other facilities and services necessary for the proper execution and completion of the Work, whether temporary or permanent and whether or not incorporated or to be incorporated in the Work. Contractor guarantees that materials shall be of the best quality, that work shall be completed in a neat and workmanlike manner, that equipment will be installed in a first class manner, and that all aspects of the project will be delivered in good working order complete and perfect in every respect and that all systems and materials necessary to make the project a complete operating utility as contemplated by the above description of the project is included in the Contract price. 4.4.2 The Contractor shall a t all times enforce strict discipline and good order among his employees and shall not employ on the Work any unfit person or anyone not skilled in the task assigned to him.

  • Working and Labor Synergies The Contractor shall be responsible for maintaining a tranquil working relationship between the Contractor work force, the Contractor Parties and their work force, State employees, and any other contractors present at the work site. The Contractor shall quickly resolve all labor disputes which result from the Contractor's or Contractor Parties’ presence at the work site, or other action under their control. Labor disputes shall not be deemed to be sufficient cause to allow the Contractor to make any claim for additional compensation for cost, expenses or any other loss or damage, nor shall those disputes be deemed to be sufficient reason to relieve the Contractor from any of its obligations under the Contract.

  • Travel Expense Any EMPLOYEE who must use his personal automobile or otherwise provide his own transportation when on school district business shall be reimbursed by the BOARD according to the amount established by current BOARD policy.

Most Referenced Clauses

Most Referenced Definitions