Property Owner Responsibilities Sample Clauses

Property Owner Responsibilities. The Property Owner agrees to the following:
Sample 1Sample 2Sample 3See All (5)
AutoNDA by SimpleDocs
Property Owner Responsibilities. 3.1 The Property Owner shall provide and is responsible for all maintenance of the designated stormwater treatment facilities as shown on the Property, including, but not limited to, sediment removal and disposal, maintenance of inlet and outlet works, trash and debris removal, vector control, and management of vegetation in accordance with the plan requirements in order to insure that all such facilities remain in proper working condition in accordance with approved design standards and all applicable legal requirements. In accordance with Section 16.210.100.G of the Overland Park Municipal Code, the Property Owner shall make records of the installation and of all maintenance and repairs, and shall retain the records for at least five years. These records shall be made available to the City during inspection of the facility and at other reasonable times upon request. 3.2 The Property Owner agrees to actively pursue measures to prevent unauthorized activities pursuant to Chapter 16.210 of the Overland Park Municipal Code which interfere with the function of the stormwater treatment facility. 3.3 In Accordance with Section 16.210.100 of the Overland Park Municipal Code, the Property Owner agrees to submit an inspection report to the City at a minimum interval of one (1) year following initial certification and subsequently every two (2) years thereafter. The inspection report shall be completed and sealed by a registered professional engineer in the State of Kansas, unless the Director of Planning and Development Services approves other qualified professionals to perform these duties. Such inspection report shall document each item, including, but not limited to, the need for removal of sediment, litter, and other debris, grass cutting, removal of undesirable vegetation, and replacement of vegetation that is part of the stormwater treatment facility. Any maintenance needs found must be addressed in a timely manner and documentation submitted showing that required maintenance has been performed. Maintenance certifications shall be submitted on a form approved by the City and shall include photographs documenting the condition of the facility at the time of the inspection.
Sample 1Sample 2
Property Owner Responsibilities. Regardless whether an Association is created or not, the Property Owner: 3.1 Shall provide and is responsible for all maintenance of the designated stormwater treatment facilities as shown on the Property, including, but not limited to, sediment removal and disposal, maintenance of inlet and outlet works, trash and debris removal, vector control, and management of vegetation in accordance with the plan requirements, in order to ensure that all such facilities remain in proper working condition in accordance with approved design standards and all applicable legal requirements. The Property Owner shall make records of the installation and all maintenance and repairs and shall retain the records for at least five years. These records shall be made available to the County during inspection of the facility and at other reasonable times upon request. 3.2 Agrees to actively pursue measures to prevent unauthorized activities that interfere with the function of the stormwater treatment facility. 3.3 Agrees to submit an inspection report to the County at a minimum interval of one (1) year following initial certification and subsequently every two (2) years thereafter. The inspection report shall be completed and sealed by a registered professional engineer in the State of Maryland unless the Director of Public Works approves other qualified professionals to perform these duties. Such inspection report shall document each item, including, but not limited to, the need for removal of sediment, litter, and other debris, grass cutting, removal of undesirable vegetation, and replacement of vegetation that is part of the stormwater treatment facility. Any maintenance needs found must be addressed in a timely manner, and documentation submitted showing that required maintenance has been performed. Maintenance certifications shall be submitted on a form approved by the County and shall include photographs documenting the condition of the facility at the time of the inspection.
Sample 1Sample 2
Property Owner Responsibilities. The Property owner agrees that it will keep the City informed about and proposed changes in the use or occupancy of the property and continue to make a good faith effort to develop a plan for compliance with the applicable fire code as the circumstances and current Covid -19 Federal and State situation develops and allows. A. Within thirty (30) days of the Effective Date, the Property Owner shall: (i)_cease to use the Property as a Fraternity including removing any markings, letters, signs or representations of any kind from the property that identify the use as a Fraternity; (ii), remove all references to the property being used as a Fraternity from websites including but not limited to the Delta Chi Eastern Washington Chapter webpage, social medial webpages, Barrister Capital Corporation (BCC) website; and (iii) cease all fraternity related activities on the property. B. Within the Term (Section 8) and prior to using, advertising, or occupying the Property as a Fraternity, the Property Owner shall: 1. Submit a building application to the City Building Department to correct the matters as set forth in the Correction Letter and submit to the Planning Department a conditional use permit application (CMC 23.080.020) to occupy the Property as a Fraternity. 2. Complete all work and improvements required under the conditions of the Building Permit and Conditional Use Permit to obtain a certificate of occupancy from the City.
Sample 1
Property Owner Responsibilities. 1. Regular Inspections: Inspections shall be performed at least twice a year or more regularly as listed below. In the event of a sale or a transfer of property, the original set of inspection records or a copy of the original inspection records shall be provided to the new property owner. BMP Inspection reports shall be generated and kept on file for five (5) years. BMP Reports shall be made available to the City of Charleston within seven
Sample 1
Property Owner Responsibilities. As a prerequisite to participation in the Sign Program, the Owner of the Project Location must agree to allow the Project to take place. In some instances, the Owner may be a different person/entity from the Applicant, in which case, the Owner will be required to sign this Agreement to acknowledge its terms and to provide permission for the improvements to be made at the Project Location. Owner must agree to perform all of the below actions in relation to the Project. If the Applicant is the Owner of the Project Location, the Applicant must perform all of the below actions and take on any other responsibilities and obligations of “Owner” set forth in this Agreement. In addition to any other responsibilities set forth in the Agreement, the Owner shall: A. Should the Project be permitted under the Mesa Sign Code and in fact extend into the Right-Of-Way, execute an encroachment permit; B. Maintain open communication with the City and Applicant about the Project; C. Notify all tenants of the schedule of maintenance or installation; D. Take any necessary safety precautions to ensure the Owner’s invitees, guests, employees and customers remain safe during maintenance or installation activities; E. Not enter into any agreements that prevent the completion of the Project; F. Work with the City on fulfilling any obligations related to the SRPMIC grant; G. Work with the City to promote and publicize the Project’s sign improvements and the Sign Program by, as reasonably requested by the City, participating in publicity and events related to the Sign Program; and H. Pay all taxes arising out of any benefit, income, or other advantage the Owner is deemed by a taxing authority to receive from the Project.
Sample 1
Property Owner Responsibilities. 1) Regular Inspections: Inspections shall be performed at least twice a year or more regularly as listed below. In the event of a sale or a transfer of property, the original set of inspection records or a copy of the original inspection records shall be provided to the new property owner. BMP Inspection reports shall be generated and kept on file for five (5) years. BMP Reports shall be made available to the County of Charleston within seven (7) business days upon written request. If such reports are generated by a third party, the reports shall remain the Property Owner’s (or Owners’) responsibility to maintain. 2) Routine Maintenance: Maintenance activities needed on a routine basis are listed below. All activities listed below shall be performed at the frequency specified below or more frequently as needed.
Sample 1
AutoNDA by SimpleDocs
Property Owner Responsibilities. To keep culverts under the property owner’s driveway(s) clear of debris, roots and trash, insuring the unimpeded flow of runoff water. Culvert pipes should be of adequate size per Xxxxx County regulations for driveway approaches.
Sample 1

Related to Property Owner Responsibilities

  • Owner Responsibilities The project owner or the engineer or architect of record acting as the owner’s agent shall fund special inspection services.

  • Engineer Responsibilities No subcontract relieves the Engineer of any responsibilities under this contract.

  • Member Responsibilities The Member’s responsibilities shall include, but are not limited to: 3.17.1. Inform the CONTRACTOR of the loss or theft of ID cards, 3.17.2. Present ID cards when using health care services, 3.17.3. Be familiar with the CONTRACTOR’s Health Plan Procedures to the best of their abilities, 3.17.4. Call or contact the CONTRACTOR to obtain information and have questions clarified, 3.17.5. Provide participating network Providers with accurate and complete medical information, 3.17.6. Follow the prescribed course of care recommended by the Provider or let the Provider know the reasons the treatment cannot be followed, as soon as possible, And 3.17.7. Make every effort to keep a scheduled appointment or cancel an appointment in advance of when it is scheduled.

  • Customer Responsibilities Notwithstanding the above, Customer agrees that except as provided by this DPA, Customer is responsible for its secure use of the Services, including securing its account authentication credentials, protecting the security of Customer Data when in transit to and from the Services and taking any appropriate steps to securely encrypt or backup any Customer Data uploaded to the Services.

  • Construction Responsibilities The party named in Article 1, Responsible Parties, under AGREEMENT is responsible for the following: A. Advertise for construction bids, issue bid proposals, receive and tabulate the bids, and award and administer the contract for construction of the Project. Administration of the contract includes the responsibility for construction engineering and for issuance of any change orders, supplemental agreements, amendments, or additional work orders that may become necessary subsequent to the award of the construction contract. In order to ensure federal funding eligibility, projects must be authorized by the State prior to advertising for construction. B. If the State is the responsible party, the State will use its approved contract letting and award procedures to let and award the construction contract. C. If the Local Government is the responsible party, the Local Government shall submit its contract letting and award procedures to the State for review and approval prior to letting. D. If the Local Government is the responsible party, the State must concur with the low bidder selection before the Local Government can enter into a contract with the vendor. E. If the Local Government is the responsible party, the State must review and approve change orders. F. Upon completion of the Project, the party responsible for constructing the Project will issue and sign a “Notification of Completion” acknowledging the Project’s construction completion and submit certification(s) sealed by a professional engineer(s) licensed in the State of Texas. G. For federally funded contracts, the parties to this Agreement will comply with federal construction requirements cited in 23 CFR Part 635 and with requirements cited in 23 CFR Part 633, and shall include the latest version of Form “FHWA-1273” in the contract bidding documents. If force account work will be performed, a finding of cost effectiveness shall be made in compliance with 23 CFR 635, Subpart B.

  • User Responsibilities i. Users are required to follow good security practices in the selection and use of passwords; ii. Users shall ensure that unattended equipment is protected; and iii. Users shall adopt a clear desk policy for papers and removable storage media and a clear screen policy for information processing facilities.

  • OWNER’S RESPONSIBILITIES 2.1. The Owner shall designate in writing a project coordinator to act as OWNER's representative with respect to the services to be rendered under this Agreement (hereinafter referred to as the "Project Coordinator"). The Project Coordinator shall have authority to transmit instructions, receive information, interpret and define OWNER's policies and decisions with respect to CONTRACTOR's services for the Project. However, the Project Coordinator is not authorized to issue any verbal or written orders or instructions to the CONTRACTOR that would have the effect, or be interpreted to have the effect, of modifying or changing in any way whatever: (a) The scope of services to be provided and performed by the CONTRACTOR hereunder; (b) The time the CONTRACTOR is obligated to commence and complete all such services; or (c) The amount of compensation the OWNER is obligated or committed to pay the CONTRACTOR. 2.2. The Project Coordinator shall: (a) Review and make appropriate recommendations on all requests submitted by the CONTRACTOR for payment for services and work provided and performed in accordance with this Agreement; (b) Arrange for access to and make all provisions for CONTRACTOR to enter the Project site to perform the services to be provided by CONTRACTOR under this Agreement; and (c) Provide notice to CONTRACTOR of any deficiencies or defects discovered by the OWNER with respect to the services to be rendered by CONTRACTOR hereunder. 2.3. CONTRACTOR acknowledges that access to the Project Site, to be arranged by OWNER for CONTRACTOR, may be provided during times that are not the normal business hours of the CONTRACTOR. 3.1. Services to be rendered by CONTRACTOR shall be commenced subsequent to the execution of this Agreement upon written Notice to Proceed from OWNER for all or any designated portion of the Project and shall be performed and completed by September 30, 2005. Based on the mutual agreement of both parties, this contract may be renewed a maximum of two one-year periods thereafter. 3.2. Should CONTRACTOR be obstructed or delayed in the prosecution or completion of its services as a result of unforeseeable causes beyond the control of CONTRACTOR, and not due to its own fault or neglect, including but not restricted to acts of God or of public enemy, acts of government or of the OWNER, fires, floods, epidemics, quarantine regulations, strikes or lock-outs, then CONTRACTOR shall notify OWNER in writing within five (5) working days after commencement of such delay, stating the cause or causes thereof, or be deemed to have waived any right which CONTRACTOR may have had to request a time extension. 3.3. No interruption, interference, inefficiency, suspension or delay in the commencement or progress of CONTRACTOR's services from any cause whatsoever, including those for which OWNER may be responsible in whole or in part, shall relieve CONTRACTOR of its duty to perform or give rise to any right to damages or additional compensation from OWNER. XXXXXXXXXX's sole remedy against OWNER will be the right to seek an extension of time to its schedule. This paragraph shall expressly apply to claims for early completion, as well as claims based on late completion. Provided, however, if through no fault or neglect of the CONTRACTOR, the services to be provided hereunder have not been completed within 18 months of the date hereof, the CONTRACTOR's compensation may be equitably adjusted, with respect to those services that have not yet been performed, to reflect the incremental increase in costs experienced by CONTRACTOR after expiration of said 18 month period. 3.4. Should the CONTRACTOR fail to commence, provide, perform or complete any of the services to be provided hereunder in a timely and reasonable manner, in addition to any other rights or remedies available to the OWNER hereunder, the OWNER at its sole discretion and option may withhold any and all payments due and owing to the CONTRACTOR until such time as the CONTRACTOR resumes performance of its obligations hereunder in such a manner so as to reasonably establish to the OWNER's satisfaction that the CONTRACTOR's performance is or will shortly be back on schedule.

  • Contractor Responsibilities 19.1. Contractor shall perform national criminal history checks for Ohio, Indiana, and Kentucky, and 10-panel drug screening tests on all prospective employees performing work under this RFP or coming onto a CMHA property and any resulting contract and provide summaries of the results to the Authority if requested. For the purposes of this section, the term “employees” includes contractor. Prospective employees whose criminal background check discloses a misdemeanor or felony involving crimes of moral turpitude, sexual offenses or harm to persons or property shall not be employed to perform work under this RFP or any resulting contract. Contractor is required to perform drug screening of all employees and to ensure acceptable test results. Criminal history and drug screening checks will be completed at the sole expense of the contractor. Any employee of the Contractor suspected of being under the influence of drugs and or alcohol will be reported to the appropriate personnel at CMHA and/or other local law enforcement. If the employee is determined to be under the influence of drugs or alcohol in any form or manner, or believed by proper authority to be dealing in illicit sale of alcohol or drugs they will be removed and shall not be allowed to return to any job site on the Authority’s property. The Contractor’s contract may be suspended and/or terminated should such a situation occur or if the Contractor fails to submit results pursuant to this section. 19.1.1. If CMHA requests additional drug screening, the test shall be performed within 24 hours and the summary shall be sent directly to CMHA from the testing facility. 19.2. Contractor(s) shall provide uniforms and ID Badges identifying Contractor for all employees working on CMHA’s properties. No employees will be allowed on CMHA’s properties out of uniform and without his/her ID badge on his/her person. Contractor(s) must submit a picture of the uniform and a sample of his/her ID badge if requested by CMHA. 19.3. Contractor’s personnel shall be neat and conduct all work in a professional and efficient manner. If any employee of Contractor is deemed unacceptable by CMHA, Contractor shall immediately replace such personnel with an acceptable substitute to CMHA. 19.4. Contractor(s) shall practice acceptable safety precautions so as not to cause harm to any persons or property while performing services under this RFP or any resulting contract. Contractor(s) shall follow industry safety standards, and use only industry approved safety equipment in accordance with the manufacturer’s specifications in the performance of all duties. 19.5. Contractor(s) shall pay all of its employees, including any and all approved Sub-Contractors, at least the legal minimum wages as determined by the United States Department of Labor and the United States Department of Housing and Urban Development and Department of Labor Prevailing Wage. Wage Determinations can be accessed via the Department of Labor website, xxx.xxxx.xxx. 19.6. Upon completion of the work, Contractor(s) shall clean up the area where the work was performed and Contractor(s) shall remove any debris generated by the products and/or services at CMHA premises. At no time, will Contractor(s) discard debris into any CMHA refuse container. 19.7. Contractor(s) shall clearly mark all work areas that might reasonably be expected to endanger the health and safety of residents, guests, or any other persons. Contractor(s) will provide such signs, markers and barricades as required to identify all work areas and minimize inherent dangers. 19.8. The contractor shall be responsible for notifying CMHA immediately of any damages (i.e. fire, container leaking) deemed to be a health or safety hazard whether the damage is caused by the contractor or other means. 19.9. The Contractor shall be responsible for safeguarding all CMHA property provided for Contractor use. At the close of each workday, CMHA facilities, property and materials shall be inspected and secured.

  • ARCHITECT’S RESPONSIBILITIES § 2.1 The Architect shall provide professional services as set forth in this Agreement. The Architect represents that it is properly licensed in the jurisdiction where the Project is located to provide the services required by this Agreement, or shall cause such services to be performed by appropriately licensed design professionals. § 2.2 The Architect shall perform its services consistent with the professional skill and care ordinarily provided by architects practicing in the same or similar locality under the same or similar circumstances. The Architect shall perform its services as expeditiously as is consistent with such professional skill and care and the orderly progress of the Project. § 2.3 The Architect shall identify a representative authorized to act on behalf of the Architect with respect to the Project. § 2.4 Except with the Owner’s knowledge and consent, the Architect shall not engage in any activity, or accept any employment, interest or contribution that would reasonably appear to compromise the Architect’s professional judgment with respect to this Project. § 2.5 The Architect shall maintain the following insurance until termination of this Agreement. If any of the requirements set forth below are in addition to the types and limits the Architect normally maintains, the Owner shall pay the Architect as set forth in Section 11.9. § 2.5.1 Commercial General Liability with policy limits of not less than « » ($ « » ) for each occurrence and « » ($ « » ) in the aggregate for bodily injury and property damage. § 2.5.2 Automobile Liability covering vehicles owned, and non-owned vehicles used, by the Architect with policy limits of not less than « » ($ « » ) per accident for bodily injury, death of any person, and property damage arising out of the ownership, maintenance and use of those motor vehicles, along with any other statutorily required automobile coverage. § 2.5.3 The Architect may achieve the required limits and coverage for Commercial General Liability and Automobile Liability through a combination of primary and excess or umbrella liability insurance, provided such primary and excess or umbrella liability insurance policies result in the same or greater coverage as the coverages

  • Vendor Responsibilities Note: NO EXCEPTIONS OR REVISIONS WILL BE CONSIDERED IN C-M, O-S, V-W. Indemnification

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!