Rooftop Solar Sample Clauses

Rooftop Solar. The Supplier shall develop a design for a new photovoltaic system. It is the responsibility of the Supplier to assess the buildings structural integrity, roof condition and shading limitations. The Supplier shall cause the following: The System shall comprise of waterproof and anchored mechanical fasteners. Mounting System design needs to meet applicable local building code requirements with respect to wind factors. Solar system installation should not void the roof warranty. Conduit penetrations shall be minimized. System shall be fixed tilt with an orientation that maximizes annual savings. All roof access points for the System shall be securely locked at the end of each day. System layout shall meet local fire department, code and ordinances required for roof access. Design and engineer the System to occupy the available roof areas to the building footprints as detailed on the site plans. The System solar arrays shall not exceed the dimensions of the areas provided. All proposals should provide the exact dimensions of the installed arrays so that it is clear the arrays will not exceed the allotted space. No Exceptions. The system should also be designed taking into consideration the electrical demand and load patterns, the illustrated installation location, available solar resources, existing site conditions, and other relevant factors. The design of the System will be subject to final approval by our electrical engineer (“Engineer”). The Supplier may not proceed with construction until designs have received final approval and the Engineer has issued a formal construction Notice to Proceed. The Supplier shall maintain a set of drawings for the System and related Service, with all (Engineer approved) design changes made during construction. Upon completion of construction, the Supplier shall submit final design documents, including, at a minimum, drawings that are updated to reflect all changes, with details of PV system structural support, all roof penetrations, electrical single-line diagrams, and complete product literature for review by the Engineer. A structural professional engineer shall sign and stamp the structural drawings, and a professional electrical engineer shall sign and stamp the electrical drawings. Three hard copies shall be submitted, as well as a CD with electronic copies of all documents. Supplier should provide design documents that provide the following minimum information: Timeline/Project Schedule. System description. Key equipm...
Sample 1
AutoNDA by SimpleDocs
Rooftop Solar. ‌ It is the responsibility of the Proposer to assess the building’s structural integrity, roof condition, and shading limitations. • Mounting systems shall limit roof penetrations or be fully ballasted. Mounting system design needs to meet applicable local building code requirements with respect to snow and wind loading factors. • Solar system installation must not void the roof warranty. • Conduit penetrations shall be minimized. • All roof access points shall be securely locked at the end of each day during construction or O&M activities. • System layout shall meet local fire department, code and ordinance requirements for roof access.
Sample 1

Related to Rooftop Solar

  • Communications Equipment (a) Subject to the provisions of this Section 3.5, Tenant shall have the non-exclusive right, at its sole cost and expense and for Tenant’s use, to install, maintain and operate upon the roof of the Building one (1) or a reasonable and necessary additional number of transmitters and/or receiver antennas or dishes approved by Landlord, which approval shall not be unreasonably withheld or delayed (collectively, the “Communications Equipment”) for use by Tenant in the conduct of its business; provided that such Communications Equipment may not materially compromise the aesthetics or appearance of the Building nor shall Landlord be required to incur any expense in accommodating the Communications Equipment. The Communications Equipment must be (i) designed, installed and operated in compliance with all Legal Requirements, and (ii) installed and operated so as not to adversely affect or impact structural, mechanical, electrical, elevator, or other systems serving the Building or customary telephone service for the Building and so as not to cause injury to persons or property, and without limitation of the foregoing, so as not to void or impair any applicable roof warranty. Upon the expiration or termination of this Lease, Tenant shall remove the Communications Equipment and repair any damage to the Building caused by the installation, maintenance, use or removal of the Communications Equipment. (b) Landlord hereby grants to Tenant the right to install (at Tenant’s sole cost and expense) any additional equipment required to operate the Communications Equipment and to connect the Communications Equipment to Tenant’s other machinery and equipment located in the Leased Premises (e.g., conduits and cables) in the shafts, ducts, chases and utility closets located in the core of the building (“Additional Equipment”), which Additional Equipment shall be deemed a part of the Communications Equipment for all purposes of this Section 3.5; provided that (i) the use of such space in the Building core by Tenant (except customary chases for cabling) may not materially adversely affect the marketability of the remaining space on any floor of the Building, and (ii) to the extent any such Additional Equipment occupies space (other than space in customary chases for the Building) that would have otherwise been Net Rentable Area on a floor of the Building, such space shall be included within the Net Rentable Area of the Leased Premises and Tenant shall be obligated to pay Annual Basic Rent and Additional Rent with respect to such space as if such space was included in the Leased Premises. Tenant’s use of such space in the Building core shall be subject to the provisions of this Lease relating to Tenant’s use of Common Areas of the Building. (c) Subject to the Building Rules and other reasonable rules relating to Building security and safety that may be promulgated by Landlord pertaining to access by tenants to the roof of the Building and provided Tenant does not unreasonably disturb any other tenants of the Building, Tenant and Tenant’s contractors shall have reasonable access to the Communications Equipment and the Additional Equipment for purposes of operating, servicing, repairing or otherwise maintaining said equipment. (d) Nothing contained in this Section 3.5 shall be deemed to prohibit or restrict any other individual or entity, including Landlord or any other tenant of the Building, from installing communications equipment on the roof of the Building or to use the roof for any other purpose. (e) In connection with its installation, repair, maintenance and removal of any Communications Equipment and Additional Equipment, Tenant, at Tenant’s sole cost and expense, shall comply with all applicable Building Rules and Legal Requirements and repair any damage to the Building caused by such installation, repair, maintenance or removal. In the event that the placement of Tenant’s Communications Equipment or Additional Equipment interferes with Landlord’s performance of any repair or maintenance to the Common Areas, including the roofs of the Buildings, any costs incurred by Landlord to temporarily or permanently relocate and reinstall Tenant’s Communications Equipment or Additional Equipment shall be included in the cost of such repair or maintenance as a Operating Expense. (f) Tenant’s Communications Equipment and Additional Equipment existing as of the Commencement Date are hereby deemed to be approved by Landlord. Any changes to the existing Communications Equipment and/or Additional Equipment by Tenant shall first be approved by Landlord, which approval will not be unreasonably withheld or delayed. (g) If Landlord shall place on the roof of any Building communications equipment of its own, or shall grant to any third party the right to locate and maintain any such equipment, all such equipment shall be located, designed and operated so as not to interfere with signals to and from Tenant’s Communications Equipment and Additional Equipment, the installation of which, in accordance with this Section 3.5, predates the installation of such other equipment. Similarly, any Communications Equipment and Additional Equipment hereafter installed by Tenant shall be located and designed so as not to interfere with signals to and from such other equipment belonging to Landlord or to third parties, that may have previously been installed. The party responsible for the communications equipment which interferes with equipment previously installed by others shall be required, at its or their expense, to take all measures necessary to eliminate the source of interference caused by such party’s equipment.

  • Network Interconnection Architecture Each Party will plan, design, construct and maintain the facilities within their respective systems as are necessary and proper for the provision of traffic covered by this Agreement. These facilities include but are not limited to, a sufficient number of trunks to the point of interconnection with the tandem company, and sufficient interoffice and interexchange facilities and trunks between its own central offices to adequately handle traffic between all central offices within the service areas at a P.01 grade of service or better. The provisioning and engineering of such services and facilities will comply with generally accepted industry methods and practices, and will observe the rules and regulations of the lawfully established tariffs applicable to the services provided.

  • Access Toll Connecting Trunk Group Architecture 9.2.1 If CSTC chooses to subtend a Verizon access Tandem, CSTC’s NPA/NXX must be assigned by CSTC to subtend the same Verizon access Tandem that a Verizon NPA/NXX serving the same Rate Center Area subtends as identified in the LERG. 9.2.2 CSTC shall establish Access Toll Connecting Trunks pursuant to applicable access Tariffs by which it will provide Switched Exchange Access Services to Interexchange Carriers to enable such Interexchange Carriers to originate and terminate traffic to and from CSTC’s Customers. 9.2.3 The Access Toll Connecting Trunks shall be two-way trunks. Such trunks shall connect the End Office CSTC utilizes to provide Telephone Exchange Service and Switched Exchange Access to its Customers in a given LATA to the access Tandem(s) Verizon utilizes to provide Exchange Access in such LATA. 9.2.4 Access Toll Connecting Trunks shall be used solely for the transmission and routing of Exchange Access to allow CSTC’s Customers to connect to or be connected to the interexchange trunks of any Interexchange Carrier which is connected to a Verizon access Tandem.

  • Signage All signs, notices and graphics of every kind or character, visible in or from public corridors, the Building Common Area or the exterior of the Premises shall be subject to Landlord’s prior written approval, not to be unreasonably withheld, conditioned or delayed. Without limiting the foregoing and subject to Landlord’s prior approval of the plans and specifications thereof (including, without limitation, the design, location, and size), Tenant shall have the right (“Exterior Signage Rights”) to install tenant identification signage on the exterior of the Building (the “Sign”), at Tenant’s sole cost and expense and in accordance with all applicable Laws (including any requirements set forth by the applicable agencies in the City and County of San Francisco) (the “Signage Requirements”). Tenant shall erect the Sign in accordance with the plans and specifications approved by Landlord, in a good and workmanlike manner, and at all times thereafter, Tenant shall maintain, at its sole cost and expense, the Sign in a good, clean and safe condition and in accordance with the Signage Requirements, including all repairs and replacements thereto. Upon the occurrence of any event of default and/or upon the termination or earlier expiration of this Lease, Tenant shall promptly remove the Sign, in which event Tenant shall be responsible for and shall repair any damage to the Building resulting therefrom. Tenant’s Exterior Signage Rights hereunder are personal to Dolby California, and, except with respect to an assignment to a Tenant Affiliate or Dolby Entity in connection with an assignment of this Lease, may not be assigned or transferred without the prior written consent of Landlord, which consent may be given or withheld or given upon conditions in Landlord’s sole and absolute discretion. Tenant shall be responsible for obtaining all permits and approvals (governmental and private) necessary for the installation and maintenance of the Sign. If Tenant fails to remove the Sign as required under this Section 32, Landlord shall have the right, at Tenant’s expense, to remove the Sign. Tenant shall indemnify, defend and protect Landlord and the Landlord Parties and hold Landlord and the Landlord Parties harmless from and against any and all, proceedings, losses, costs, damages, causes of action, liabilities, injuries or expenses arising out of or related to Tenant’s exercise of the Exterior Signage Rights granted hereunder, including, without limitation, any claims of injury to or death of persons or damage to property occurring or resulting directly or indirectly from the installation or maintenance of the Sign on the Building.

  • Scope of Interconnection Service 1.3.1 The NYISO will provide Energy Resource Interconnection Service and Capacity Resource Interconnection Service to Interconnection Customer at the Point of Interconnection. 1.3.2 This Agreement does not constitute an agreement to purchase or deliver the Interconnection Customer’s power. The purchase or delivery of power and other services that the Interconnection Customer may require will be covered under separate agreements, if any, or applicable provisions of NYISO’s or Connecting Transmission Owner’s tariffs. The Interconnection Customer will be responsible for separately making all necessary arrangements (including scheduling) for delivery of electricity in accordance with the applicable provisions of the ISO OATT and Connecting Transmission Owner’s tariff. The execution of this Agreement does not constitute a request for, nor agreement to, provide Energy, any Ancillary Services or Installed Capacity under the NYISO Services Tariff or any Connecting Transmission Owner’s tariff. If Interconnection Customer wishes to supply or purchase Energy, Installed Capacity or Ancillary Services, then Interconnection Customer will make application to do so in accordance with the NYISO Services Tariff or Connecting Transmission Owner’s tariff.

  • SATELLITE DISH Subject to compliance with all applicable Legal Requirements, Tenant shall have the exclusive right to place, from time to time, satellite dishes, antennae and other communication or transmission devices (such devices being referred to as the “Satellite Dishes”) on the roof of each of the Buildings. Additionally, Tenant shall have the right to install such wire, conduits, cables and other materials as necessary to connect the Satellite Dishes to Tenant’s allied machinery and equipment in the Premises (the Satellite Dishes and any such connecting material being collectively referred to as the “Satellite Dish Facilities”). However, prior to the installation of any Satellite Dish Facilities, Tenant, at its expense, shall be required to provide Landlord with a certification by a registered professional structural engineer that the structural system of the roof is adequate to support the superimposed loads produced by any Satellite Dishes at the location on the roof of such Satellite Dishes and Tenant, at its expense, shall be required to provide Landlord with satisfactory assurance that the existing construction materials of the roof (such as the roof membrane) shall be protected from the Satellite Dishes. At the expiration or earlier termination of the Lease, Tenant, at its expense, may remove the Satellite Dish Facilities belonging to Tenant, but Tenant shall remove any Satellite Dish Facilities belonging to an unaffiliated third party. Any work required to restore the roof of any other part of the Buildings from any damage occasioned by the installation, maintenance or removal of the Satellite Dish Facilities shall be borne by Tenant, and Tenant shall indemnify and hold harmless Landlord from any costs, expenses, liabilities and the like, including reasonable attorneys’ fees, occasioned by any damage to property and injury or death to persons caused by such installation, maintenance or removal, except to the extent caused by the negligence, willful misconduct or breach of this Lease of Landlord. Tenant shall be responsible for the installation of all Satellite Dish Facilities (including the attachment thereto to the roof) and for all costs and expenses arising from and relating to the Satellite Dish Facilities and the installation, operation, maintenance and repair thereof, and, if Tenant elects to remove the Satellite Dish Facilities, or for those Satellite Dish Facilities for which removal is required, for the removal thereof. The installation, maintenance and removal of the Satellite Dish Facilities shall be performed by contractors and workers first approved by Landlord, which approval will not be unreasonably withheld or delayed. However, Landlord reserves the right to require Tenant, at Tenant’s expense, to use Landlord’s roofing contractor in connection therewith if, in Landlord’s reasonable judgment, the Landlord’s roof warranty may be affected by any such work. Landlord agrees that Tenant and engineering and maintenance personnel reasonably approved by Landlord shall have access to the Satellite Dish Facilities in order to install, operate, maintain, inspect and remove, as required, the Satellite Dish Facilities. Landlord shall not unreasonably interfere with or impair the use, operation, maintenance or repair of the Satellite Dish Facilities. Tenant may sublease to unaffiliated third parties rooftop rights for the installation of Satellite Dish Facilities, without Landlord’s consent, but Tenant shall give Landlord written notice of the existence of any such subleases from time to time upon Landlord’s request. All revenues derived from such third party subleases shall belong to Tenant. The Satellite Dish Facilities shall not be considered a part of the Premises for the purpose of determining Tenant’s rental obligations under the Lease and no Rent therefor shall be charged during the Term (including any renewal period specifically provided under this Lease). However, Tenant’s use of the Satellite Dish Facilities is otherwise subject to all of the terms and conditions of this Lease with respect to Tenant’s use and occupancy of the Premises, including, without limitation, Sections 9, 22 and 31.

  • Configuration Management The Contractor shall maintain a configuration management program, which shall provide for the administrative and functional systems necessary for configuration identification, control, status accounting and reporting, to ensure configuration identity with the UCEU and associated cables produced by the Contractor. The Contractor shall maintain a Contractor approved Configuration Management Plan that complies with ANSI/EIA-649 2011. Notwithstanding ANSI/EIA-649 2011, the Contractor’s configuration management program shall comply with the VLS Configuration Management Plans, TL130-AD-PLN-010-VLS, and shall comply with the following:

  • Television Equipment Recycling Program If this Contract is for the purchase or lease of covered television equipment, then Contractor certifies that it is compliance with Subchapter Z, Chapter 361 of the Texas Health and Safety Code related to the Television Equipment Recycling Program.

  • Dark Fiber Loop 2.8.4.1 Dark Fiber Loop is an unused optical transmission facility, without attached signal regeneration, multiplexing, aggregation or other electronics, from the demarcation point at an End User’s premises to the End User’s serving wire center. Dark Fiber Loops may be strands of optical fiber existing in aerial or underground structure. BellSouth will not provide line terminating elements, regeneration or other electronics necessary for AFN to utilize Dark Fiber Loops.

  • Installation, Maintenance, Testing and Repair Unless otherwise agreed in writing by the Parties, to the extent required by Applicable Law, Interconnection provided by a Party shall be equal in quality to that provided by such Party to itself, any subsidiary, affiliates or third party. If either Party is unable to fulfill its obligations under this Section 14.2, it shall notify the other Party of its inability to do so and will negotiate alternative intervals in good faith. The Parties agree that to the extent required by Applicable Law, the standards to be used by a Party for isolating and clearing any disconnections and/or other outages or troubles shall be at parity with standards used by such Party with respect to itself, any subsidiary, affiliate or third party.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!