Suspension of Work by Contractor Sample Clauses

Suspension of Work by Contractor. The Contractor shall not suspend Work without written permission of the Owner except as provided for in this Paragraph 16.
Sample 1Sample 2Sample 3See All (4)
AutoNDA by SimpleDocs
Suspension of Work by Contractor. 16.4.2.1 Contractor may, by giving fifteen (15) days notice in writing to GEC, suspend the carrying out of the Work or any part thereof if GEC fails to pay Contractor any undisputed amount due under any invoice within twenty (20) days after the amount becomes payable under this Agreement, unless prior to the end of the fifteen (15) days notice period GEC has paid the overdue amount. During any such suspension Contractor shall properly protect and secure the Work in such manner, as GEC shall require. Unless otherwise instructed by GEC, Contractor shall during any such suspension maintain its staff and labor on or near the Site ready to proceed with the Work immediately upon receipt of the overdue amount. A suspension by Contractor shall constitute a Change entitling Contractor to a Change Order to make appropriate adjustments under the Agreement as provided in Section 6.5. 16.4.2.2 Upon payment by GEC of such overdue amount, Contractor shall examine the Equipment affected by the suspension and shall, at GEC’s expense, make good any deterioration or damage, to or of such Equipment that may have occurred during the suspension (unless resulting from any breach by Contractor of its obligations to protect and secure the Work) and shall proceed with the Work previously suspended.
Sample 1Sample 2
Suspension of Work by Contractor. 16.4.2.1 Contractor may, by giving fifteen (15) days notice in writing to Owner, suspend the carrying out of the Work or any part thereof if Owner fails to pay Contractor any undisputed amount due under any invoice within thirty (30) days after the amount becomes payable under this Agreement, unless prior to the end of the fifteen (15) days notice period Owner has paid the overdue amount. During any such suspension Contractor shall properly protect and secure the Work in such manner as Owner shall require. Unless otherwise instructed by Owner, Contractor shall during any such suspension maintain its staff and labor on or near the Site ready to proceed with the Work immediately upon receipt of the overdue amount. 16.4.2.2 Upon payment by Owner of such overdue amount, Contractor shall examine the Equipment affected by the suspension and shall, at Owner’s expense, make good any deterioration or damage, to or of such Equipment that may have occurred during the suspension (unless resulting from any breach by Contractor of its obligations to protect and secure the Work) and shall proceed with the Work previously suspended.
Sample 1Sample 2
Suspension of Work by Contractor. Contractor, with thirty (30) days written notice to Owner, may suspend all or part of the Work provided that: (i) Owner has failed for sixty (60) consecutive days to pay Contractor amounts, associated with the Work to be suspended, determined to be due Contractor in accordance with the Contract Documents, or (ii) Owner has failed to meet its obligations in the resolution of disputed claim with Contractor, as provided in Article 14, for a consecutive period of ninety (90) days. (iii) Owner should be guilty of a substantial violation of any provision of this Contract
Sample 1
Suspension of Work by Contractor. Should the Work be stopped by any public authority for a period of thirty days or more, through no fault of Contractor, or should the Work be stopped through act of neglect of the Owner for a period of seven days, or should the Owner fail to pay the Contractor any payment within seven days after it is due, the Contractor, upon seven days written notice to the Owner, may stop work or terminate the Agreement and recover from Owner payment for all Work executed. This provision does not limit Contractor’s damages from Owner’s breach.
Sample 1
Suspension of Work by Contractor. The Contractor shall not suspend Work without written permission of the Owner except as provided for in this Paragraph. The Contractor may suspend Work upon written notice to the Owner if: A. The Work is stopped pursuant to an order of any court or other public authority having jurisdiction, through no act or fault of the Contractor or a Subcontractor or their agents or employees or any other person performing any of the Work under a contract with the Contractor; or B. The Work is stopped as a result of an act of government, such as a declaration of a national emergency making materials unavailable; or C. After ten (10) business days, notice to the Owner of the Engineer’s failure to act on a request for Payment as provided in Paragraph 5.03, the Engineer still fails to act within that ten (10) business day period; or D. After ten (10) business days, notice to the Owner of his failure to make timely payment on an approved Certificate for Payment, the Owner still does not make payment within that ten (10) business day period. Timely as used herein means within the time periods provided in this Contract.
Sample 1
Suspension of Work by Contractor a) The Employer may without prejudice to his right against the contractor in respect of any delay or inferior workmanship or otherwise or to any claims for damages in respect of any breaches of the contract and without prejudice to any rights or remedies under any of the provisions of this contract or otherwise and whether the date for completion has or has not elapsed by notice absolutely determine the contract in any of the following cases: i) If the contractor having been given by the Engineer a notice to rectify, reconstruct or replace any defective work or that the work is being performed in any inefficient or otherwise improper or unworkman-like manner shall omit to comply with the requirements of such notice for a period of seven days thereafter or if the contractor shall delay or suspend the execution of the work so that in the judgment of the Employer (which shall be final and binding) he will be unable to ensure completion of the work by the date for completion or he has already failed to complete the work by the date. ii) If the contractor being a company shall pass a resolution or the court shall make an order that the company shall be wound up or if a receiver or a manager on behalf of a creditor shall be appointed or if circumstances shall arise which entitle the court of creditor to appoint a receiver or a manager or which entitle the court to make a winding up order. iii) If the contractor commits breach of any of the terms and conditions of this contract. iv) If the contractor commits any acts mentioned in Clause-13 hereof. b) When the contractor has made himself liable for action under any of the cases aforesaid, the Employer shall have the following powers: i) To determine or rescind the contract as aforesaid (of which termination or rescission notice in writing to the contractor under the hand of the Employer shall be conclusive evidence) Upon such determination or rescission the security deposit of the contractor shall be liable to be forfeited and shall be absolutely at the disposal of the Employer. ii) The Engineer may employ labour paid by the Employer and to supply materials to carry out the work or any part of the work debiting the contractor with the cost of the labour and the price of the materials (of the amount of which cost and price certified by the Engineer shall be final and conclusive against the contractor) and crediting him with the value of the work done in all respect in the same manner at the same rates as if it had ...
Sample 1
AutoNDA by SimpleDocs
Suspension of Work by Contractor 
Sample 1

Related to Suspension of Work by Contractor

  • Suspension of Work The Department may, at its sole discretion, suspend any or all activities under the Contract, at any time, when it is in the best interest of the State of Florida to do so. The Customer may suspend a resulting contract or purchase order, at any time, when in the best interest of the Customer to do so. The Department or Customer will provide the Contractor written notice outlining the particulars of the suspension. After receiving a suspension notice, the Contractor must comply with the notice and will cease the performance of the Contract or purchase order. Suspension of work will not entitle the Contractor to any additional compensation. The Contractor will not resume performance of the Contract or purchase order until so authorized by the Department.

  • Statement of Work The Statement of Work to which Grantee is bound is incorporated into and made a part of this Grant Agreement for all purposes and included as Attachment A.

  • Suspension of Work and Termination 15.01 Owner May Suspend Work A. At any time and without cause, Owner may suspend the Work or any portion thereof for a period of not more than 60 consecutive days by written notice to Contractor and Engineer. Such notice will fix the date on which Work will be resumed. Contractor shall resume the Work on the date so fixed. Contractor shall be entitled to an adjustment in the Contract Price or an extension of the Contract Times, or both, directly attributable to any such suspension.

  • CORRECTION OF WORK 13.2.1 The Contractor shall be responsible for correcting all Work which the Architect has found to be defective or which fails to conform to the Contract Documents whether observed be- fore or after Substantial Completion and whether or not fabricated, installed or completed. The Contractor shall bear all costs of correcting such rejected Work, including compensation for the Architect's and the State’s additional services made necessary thereby. 13.2.2 If, within one year after the Date of Substantial Completion of the Work or designated portion thereof or within one year after acceptance by the State of designated equipment or within such longer period of time as may be prescribed by law or by the terms of any applicable special warranty required by the Contract Documents, any of the Work is found to be defective or not in accordance with the Contract Documents, the Contractor shall correct it promptly after receipt of a written notice from the State to do so unless the State has previously given the Contractor a written acceptance of such condition. This obligation shall survive termination of the Contract. The State shall give such notice promptly after discovery of the condition. 13.2.3 The Contractor shall remove from the site all portions of the Work which are defective or non-conforming and which have not been corrected under Subparagraphs 4.5.1, 13.2.1 and 13.2.4 If the Contractor fails to correct defective or nonconforming Work as provided in Subparagraphs 4.5.1, 13.2.1 and 13.2.2, the State may correct it in accordance with Paragraph 13.2.5 If the Contractor does not proceed with the correction of such defective or non- conforming Work within a reasonable time fixed by written notice from the Architect, the State may remove it and may store the materials or equipment at the expense of the Contractor. If the Contractor does not pay the cost of such removal and storage within ten days thereafter, the State may upon ten additional days written notice sell such Work at auction or at private sale and shall account for the net proceeds thereof, after deducting all the costs that should have been borne by the Contractor, including compensation for the Architect's and the State’s additional services and expenses made necessary thereby. If such proceeds of sale do not cover all costs which the Contractor should have borne, the difference shall be charged to the Contractor and an appropriate Change Order shall be issued. If the payments then or thereafter due the Contractor are not sufficient to cover such amount, the Contractor shall pay the difference to the State. 13.2.6 The Contractor shall bear the cost of making good all work of the State or separate contractors destroyed or damaged by such correction or removal. 13.2.7 Nothing contained in this Paragraph 13.2 shall be construed to establish a period of limitation with respect to any other obligation which the Contractor might have under the

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!